UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
(Mark One)
FORM
|
|
REGISTRATION STATEMENT PURSUANT TO SECTION 12(b) OR (g) OF THE SECURITIES EXCHANGE ACT OF 1934 |
|
OR |
|
|
|
ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
|
For the fiscal year ended |
|
|
OR |
|
|
|
TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
|
For the transition period from ____________ to ____________ |
|
|
OR |
|
|
|
SHELL COMPANY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
|
Date of event requiring this shell company report ____________ |
|
Commission file number
|
|
|
(Exact name of Registrant as specified in its charter) |
|
(Translation of Registrant’s name into English) |
|
Republic of the |
|
(Jurisdiction of incorporation or organization) |
|
|
|
(Address of principal executive offices) |
|
|
|
(Name, Telephone, E-mail and/or Facsimile number and Address of Company Contact Person) |
|
Title of each class
|
|
Trading Symbol(s)
|
|
Name of each exchange
on which registered
|
|
|
|
|
|
The
|
|
|
|
|
The
|
|
NONE
|
|
(Title of class)
|
|
NONE
|
|
(Title of class)
|
Indicate the number of outstanding shares of each of the issuer’s classes of capital or common stock as of the close of the period covered by the annual report.
As of December 31, 2024,
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act.
|
Yes |
☐ |
|
☒ |
If this report is an annual or transition report, indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934.
|
Yes |
☐ |
|
☒ |
Note – Checking the box above will not relieve any registrant required to file reports pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 from their obligations under those Sections.
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.
|
|
☒ |
No |
☐ |
Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (Sec.232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files).
|
|
☒ |
No |
☐ |
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.
|
Large accelerated filer ☐ |
Accelerated filer ☐ |
|
|
Emerging growth company |
If an emerging growth company that prepares its financial statements in accordance with U.S. GAAP, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards† provided pursuant to Section 13(a) of the Exchange Act. ☐
† The term “new or revised financial accounting standard” refers to any update issued by the Financial Accounting Standards Board to its Accounting Standards Codification after April 5, 2012.
Indicate by check mark whether the registrant has filed a report on and attestation to its management’s assessment of the effectiveness of its
internal control over financial reporting under Section 404(b) of the Sarbanes-Oxley Act (15 U.S.C. 7262(b)) by the registered public accounting firm that prepared or issued its audit report.
Indicate by check mark which basis of accounting the registrant has used to prepare the financial statements included in this filing:
|
☒ |
|
|
☐ |
International Financial Reporting Standards as issued by the International Accounting Standards Board |
|
☐ |
Other |
If “Other” has been checked in response to the previous question, indicate by check mark which financial statement item the registrant has elected to follow:
|
☐ |
Item 17 |
☐ |
Item 18 |
If this is an annual report, indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).
|
Yes |
|
No |
☒ |
(APPLICABLE ONLY TO ISSUERS INVOLVED IN BANKRUPTCY PROCEEDINGS DURING THE PAST FIVE YEARS)
Indicate by check mark whether the registrant has filed all documents and reports required to be filed by Sections 12, 13 or 15(d) of the
Securities Exchange Act of 1934 subsequent to the distribution of securities under a plan confirmed by a court. N/A
|
Yes |
☐ |
No |
☐ |
|
1
|
||
|
ITEM 1.
|
1
|
|
|
ITEM 2.
|
1
|
|
|
ITEM 3.
|
1
|
|
|
ITEM 4.
|
31 |
|
|
ITEM 4A.
|
48 |
|
|
ITEM 5.
|
48 |
|
|
ITEM 6.
|
59 |
|
|
ITEM 7.
|
61 |
|
|
ITEM 8.
|
64 |
|
|
ITEM 9.
|
64 |
|
|
ITEM 10.
|
64 |
|
|
ITEM 11.
|
81 |
|
|
ITEM 12.
|
81 |
|
| 82 |
||
|
ITEM 13.
|
82 |
|
|
ITEM 14.
|
82 |
|
|
ITEM 15.
|
82 |
|
|
ITEM 16.
|
83 |
|
|
ITEM 16A.
|
83 |
|
|
ITEM 16B.
|
84 |
|
|
ITEM 16C.
|
84 |
|
|
ITEM 16D.
|
84 |
|
|
ITEM 16E.
|
84 |
|
|
ITEM 16F.
|
84 |
|
|
ITEM 16G.
|
85 |
|
|
ITEM 16H.
|
85 |
|
|
ITEM 16I.
|
85 |
|
|
ITEM 16J.
|
86 |
|
|
ITEM 16K.
|
86 |
|
| 86 |
||
|
ITEM 17.
|
86 |
|
|
ITEM 18.
|
86 |
|
|
ITEM 19.
|
87 |
| ● |
our ability to maintain or develop new and existing customer relationships with major refined product importers and exporters, major crude oil companies and major commodity traders, including our ability to
enter into long-term charters for our vessels;
|
| ● |
our future operating and financial results;
|
| ● |
our future vessel acquisitions, our business strategy and expected and unexpected capital spending or operating expenses, including any dry-docking, crewing, bunker costs and insurance costs;
|
| ● |
our financial condition and liquidity, including our ability to pay amounts that we owe and to obtain financing in the future to fund capital expenditures, acquisitions and other general corporate
activities;
|
| ● |
oil and chemical tanker industry trends, including fluctuations in charter rates and vessel values and factors affecting vessel supply and demand;
|
| ● |
our ability to take delivery of, integrate into our fleet, and employ any newbuildings we may acquire or order in the future and the ability of shipyards to deliver vessels on a timely basis;
|
| ● |
the aging of our vessels and resultant increases in operation and dry-docking costs;
|
| ● |
the ability of our vessels to pass classification inspections and vetting inspections by oil majors and big chemical corporations;
|
| ● |
significant changes in vessel performance, including increased vessel breakdowns;
|
| ● |
the creditworthiness of our charterers and the ability of our contract counterparties to fulfill their obligations to us;
|
| ● |
our ability to repay outstanding indebtedness, to obtain additional financing and to obtain replacement charters for our vessels, in each case, at commercially acceptable rates or at all;
|
| ● |
changes to governmental rules and regulations or actions taken by regulatory authorities and the expected costs thereof;
|
| ● |
our ability to comply with additional costs and risks related to our environmental, social and governance policies;
|
| ● |
potential liability from litigation and our vessel operations, including purported discharge of pollutants;
|
| ● |
changes in general economic and business conditions;
|
| ● |
general domestic and international political conditions, potential disruption of shipping routes due to accidents, political events, including “trade wars,” piracy, acts by terrorists or other hostilities
or conflicts, including the war in Ukraine, the war between Israel and Hamas or the Houthi crisis in and around the Red Sea;
|
| ● |
changes in production of or demand for oil and petroleum products and chemicals, either globally or in particular regions;
|
| ● |
the strength of world economies and currencies, including fluctuations in charterhire rates and vessel values;
|
| ● |
potential liability from future litigation and potential costs due to our vessel operations, including due to any environmental damage and vessel collisions;
|
| ● |
the length and severity of public health threats, epidemics and pandemics and other disease outbreaks and their impact on the demand for commercial seaborne transportation and the condition of the financial
markets and governmental responses thereto; and
|
| ● |
and other important factors discussed in “Item 3. Key Information—D. Risk Factors” or described from time to time in the reports filed by us with the U.S. Securities and Exchange Commission, or the SEC.
|
| ITEM 1. |
IDENTITY OF DIRECTORS, SENIOR MANAGEMENT AND ADVISERS
|
| ITEM 2. |
OFFER STATISTICS AND EXPECTED TIMETABLE
|
| ITEM 3. |
KEY INFORMATION
|
| A. |
[Reserved]
|
| B. |
Capitalization and Indebtedness
|
| C. |
Reasons for the Offer and Use of Proceeds
|
| D. |
Risk Factors
|
| ● |
The international tanker industry has historically been both cyclical and volatile.
|
| ● |
The current state of the world financial market and current economic conditions could have a material adverse impact on our results of operations, financial condition and cash flows.
|
| ● |
Our financial results may be adversely affected by the outbreak of epidemic and pandemic diseases, and the related governmental responses thereto.
|
| ● |
The market value of our vessels, and those we may acquire in the future, may fluctuate significantly, which could cause us to incur losses if we decide to sell them following a decline in their market
values or we may be required to write down their carrying value, which will adversely affect our earnings.
|
| ● |
An over-supply of tanker capacity may lead to reductions in asset prices, charter hire rates and profitability.
|
| ● |
Volatility of SOFR could affect our profitability, earnings and cash flows.
|
| ● |
We are subject to complex laws and regulations, including environmental regulations that can adversely affect the cost, manner or feasibility of doing business.
|
| ● |
Climate change and greenhouse gas restrictions may adversely impact our operations and markets.
|
| ● |
Increasing growth of electric vehicles could lead to a decrease in trading and the movement of crude oil and petroleum products worldwide.
|
| ● |
Our vessels may suffer damage due to the inherent operational risks of the tanker industry and we may experience unexpected dry-docking costs, which may adversely affect our business and financial
condition.
|
| ● |
We are subject to international safety regulations and requirements imposed by classification societies and the failure to comply with these regulations may subject us to increased liability, may adversely
affect our insurance coverage and may result in a denial of access to, or detention in, certain ports.
|
| ● |
If our vessels call on ports located in countries or territories that are the subject of sanctions or embargoes imposed by the U.S. government or other governmental authorities, it could lead to monetary
fines or adversely affect our business, reputation and the market for our common shares.
|
| ● |
Political instability, terrorist or other attacks, war, international hostilities and public health threats can affect the tanker industry, which may adversely affect our business.
|
| ● |
Acts of piracy on ocean-going vessels could adversely affect our business.
|
| ● |
Increased inspection procedures and tighter import and export controls could increase costs and disrupt our business.
|
| ● |
We rely on our information systems to conduct our business, and failure to protect these systems against security breaches could adversely affect our business and results of operations. Additionally, if
these systems fail or become unavailable for any significant period of time, our business could be harmed.
|
| ● |
Our financing arrangements contain restrictive covenants that may limit our liquidity and corporate activities, which could limit our operational flexibility and have an adverse effect on our financial
condition and results of operations.
|
| ● |
Servicing current and future debt will limit funds available for other purposes and could impair our ability to react to changes in our business.
|
| ● |
Our President, Chief Executive Officer and Director has significant influence over us, and a trust established for the benefit of his family may be deemed to beneficially own, directly or indirectly, 100%
of our Series D Preferred Shares, and thereby to control the outcome of matters on which our shareholders are entitled to vote.
|
| ● |
We have been subject to litigation in the past and may be subject to similar or other litigation in the future.
|
| ● |
Any limitation in the availability or operation of our vessels could have a material adverse effect on our business, results of operations and financial condition.
|
| ● |
We expect to be dependent on a limited number of customers for a large part of our revenues, and failure of such counterparties to meet their obligations could cause us to suffer losses or negatively impact
our results of operations and cash flows.
|
| ● |
If we fail to manage our planned growth properly, we may not be able to successfully expand our market share.
|
| ● |
Delays or defaults by the shipyards in the construction of any newbuildings could increase our expenses and diminish our net income and cash flows.
|
| ● |
Our ability to obtain additional debt financing may be dependent on our ability to charter our vessels, the performance of our charters and the creditworthiness of our charterers.
|
| ● |
The industry for the operation of tanker vessels and the transportation of oil, petroleum products and chemicals is highly competitive and we may not be able to compete for charters with new entrants or
established companies with greater resources.
|
| ● |
We maintain cash with a limited number of financial institutions, including financial institutions that may be located in Greece, which will subject us to credit risk.
|
| ● |
We may be unable to attract and retain key management personnel and other employees in the international tanker shipping industry, which may negatively impact the effectiveness of our management and our
results of operations.
|
| ● |
If labor interruptions are not resolved in a timely manner, they could have a material adverse effect on our business, results of operations, cash flows, financial condition and available cash.
|
| ● |
A drop in spot charter rates may provide an incentive for some charterers to default on their charters, which could affect our cash flow and financial condition.
|
| ● |
An increase in operating costs could decrease earnings and available cash.
|
| ● |
The aging of our fleet may result in increased operating costs in the future, which could adversely affect our earnings.
|
| ● |
Rising fuel prices may adversely affect our profits.
|
| ● |
Inflation could adversely affect our operating results and financial condition.
|
| ● |
Unless we set aside reserves or are able to borrow funds for vessel replacement, our revenue will decline at the end of a vessel’s useful life, which would adversely affect our business, results of
operations and financial condition.
|
| ● |
Purchasing and operating secondhand vessels may result in increased operating costs and vessels off-hire, which could adversely affect our earnings.
|
| ● |
Our recent acquisition of a megayacht entails certain risks and uncertainties associated with our entry into ownership of a new class of vessels, and we may not manage such risks successfully.
|
| ● |
We may not have adequate insurance to compensate us if we lose any vessels that we acquire.
|
| ● |
We may be subject to increased premium payments, or calls, as we obtain some of our insurance through protection and indemnity associations.
|
| ● |
Increasing regulation as well as scrutiny and changing expectations from investors, lenders and other market participants with respect to our Environmental, Social and Governance (“ESG”) policies may impose
additional costs on us or expose us to additional risks.
|
| ● |
A shift in consumer demand from crude oil and petroleum products towards other energy sources or changes to trade patterns for crude oil and refined petroleum products may have a material adverse effect on
our business.
|
| ● |
Technological innovation and quality and efficiency requirements from our customers could reduce our charter hire income and the value of our vessels.
|
| ● |
The smuggling of drugs or other contraband onto our vessels may lead to governmental claims against us.
|
| ● |
Maritime claimants could arrest our vessels or vessels we may acquire, which could interrupt our cash flow.
|
| ● |
Governments could requisition our vessels or vessels we acquire during a period of war or emergency, resulting in loss of earnings.
|
| ● |
U.S. federal tax authorities could treat us as a “passive foreign investment company,” which could have adverse U.S. federal income tax consequences to U.S. shareholders.
|
| ● |
Failure to comply with the U.S. Foreign Corrupt Practices Act of 1977, or FCPA, could result in fines, criminal penalties, and an adverse effect on our business.
|
| ● |
We may be subject to U.S. federal income tax on our U.S. source income, which would reduce our earnings.
|
| ● |
We are a “foreign private issuer,” which could make our common shares less attractive to some investors or otherwise harm our stock price.
|
| ● |
The market price and trading volume of our common shares may continue to be highly volatile, which could lead to a loss of all or part of a shareholder’s investment.
|
| ● |
There is no guarantee of a continuing public market for you to resell our common shares.
|
| ● |
The NYSE may delist our common shares from its exchange which could limit your ability to make transactions in our securities and subject us to additional trading restrictions.
|
| ● |
We have issued common shares in the past through various transactions and we may do so in the future without shareholder approval, which may dilute our existing shareholders, depress the trading price of
our securities and impair our ability to raise capital through subsequent equity offerings.
|
| ● |
We may be unable to successfully consummate a planned spin-off of certain of our assets or to achieve some or all of the benefits that we expect to achieve from the spin-off and may incur significant risks
associated with the spin-off.
|
| ● |
We are incorporated in the Republic of the Marshall Islands, which does not have a well-developed body of corporate law and as a result, shareholders may have fewer rights and protections under Marshall
Islands law than under a typical jurisdiction in the United States.
|
| ● |
It may not be possible for investors to serve process on or enforce U.S. judgments against us.
|
| ● |
Our By-laws provide that the High Court of the Republic of Marshall Islands shall be the sole and exclusive forum for certain disputes between us and our shareholders, which could limit our shareholders’
ability to obtain a favorable judicial forum for disputes with us or our directors, officers, or employees.
|
| ● |
We may not achieve the intended benefits of having a forum selection provision if it is found to be unenforceable.
|
| ● |
Anti-takeover provisions in our organizational documents could have the effect of discouraging, delaying or preventing a merger, amalgamation or acquisition, which could reduce the market price of our
common shares.
|
| ● |
Our Fleet Manager, on whom we are dependent to perform the day-to-day management of our fleet, may have conflicts of interest between us and its other clients and is a privately held company and there may
be limited or no publicly available information about it.
|
| ● |
supply and demand for oil, petroleum products and chemicals carried;
|
| ● |
changes in oil production and refining capacity resulting in shifts in trade flows for oil products;
|
| ● |
oil prices;
|
| ● |
the distance oil, petroleum products and chemicals are to be moved by sea;
|
| ● |
any restrictions on crude oil production imposed by the OPEC and non-OPEC oil producing countries;
|
| ● |
global and regional economic and political conditions, including “trade wars” and developments in international trade, national oil reserves policies, fluctuations in industrial and agricultural production,
armed conflicts and work stoppages;
|
| ● |
increases in the production of oil in areas linked by pipelines to consuming areas, the extension of existing, or the development of new pipeline systems in markets we may serve, or the conversion of
existing non-oil pipelines to oil pipelines in those markets;
|
| ● |
worldwide and regional availability of refining capacity and inventories;
|
| ● |
environmental and other legal and regulatory developments;
|
| ● |
economic slowdowns caused by public health events or inflationary pressures and resultant governmental responses;
|
| ● |
currency exchange rates;
|
| ● |
weather, natural disasters and other acts of God;
|
| ● |
increased use of renewable and alternative sources of energy;
|
| ● |
competition from alternative sources of energy, other shipping companies and other modes of transportation; and
|
| ● |
international sanctions, embargoes, import and export restrictions, nationalizations, piracy and wars or other conflicts, including the wars between Russia and Ukraine and between Israel and Hamas or the
Houthi crisis in and around the Red Sea.
|
| ● |
the number of newbuilding deliveries;
|
| ● |
current and expected newbuilding orders for vessels;
|
| ● |
the scrapping rate of older vessels;
|
| ● |
the availability of financing for new or secondhand tankers;
|
| ● |
the price of steel;
|
| ● |
speed of vessel operation;
|
| ● |
vessel freight rates, which are affected by factors that may affect the rate of newbuilding, swapping and laying up of vessels;
|
| ● |
the price of steel and vessel equipment;
|
| ● |
technological advances in the design, capacity, propulsion technology, and fuel consumption efficiency of vessels;
|
| ● |
potential conversion of vessels for alternative use;
|
| ● |
changes in environmental and other regulations that may limit the useful lives of vessels;
|
| ● |
port or canal congestion;
|
| ● |
national or international regulations that may effectively cause reductions in the carrying capacity of vessels or early obsolescence of tonnage;
|
| ● |
environmental concerns and regulations, including ballast water management, low sulfur fuel consumption regulations, and reductions in CO₂ emissions;
|
| ● |
the number of vessels that are out of service at a given time, namely those that are laid-up, dry-docked, awaiting repairs or otherwise not available for hire, including those that are in dry-dock for the
purpose of installing exhaust gas cleaning systems, known as scrubbers; and
|
| ● |
changes in global petroleum and chemical production.
|
| ● |
general economic and market conditions affecting the shipping industry;
|
| ● |
prevailing level of charter rates;
|
| ● |
competition from other shipping companies;
|
| ● |
types, sizes and ages of vessels;
|
| ● |
the availability of other modes of transportation;
|
| ● |
supply and demand for vessels;
|
| ● |
shipyard capacity and slot availability;
|
| ● |
cost of newbuildings;
|
| ● |
price of steel;
|
| ● |
exchange rate levels;
|
| ● |
number of tankers scrapped;
|
| ● |
governmental or other regulations; and
|
| ● |
technological advances and the development, availability, and cost of nuclear power, natural gas, coal, renewable energy, and other alternative sources of energy.
|
| • |
IMO Data Collection System (DCS): Since 2019, the IMO data collection system, or the IMO DCS, which requires vessels above 5,000 gross tons to report consumption data for
fuel oil, hours under way and distance travelled. This IMO DCS covers any maritime activity carried out by ships, including dredging, pipeline laying, and offshore installations. Data is reported annually to the flag state, which is used
to calculating a ship’s operational carbon intensity indicator (CII).
|
| • |
Amendments to MARPOL Annex VI: Beginning in January 2023, Annex VI imposed reporting requirements in connection with the implementation of the Energy Efficiency Existing
Ship Index, or EEXI, and carbon intensity indicator, or CII, framework, which amendments became effective on May 1, 2024. Beginning in January 2023, Annex VI requires EEXI and CII certification. The first annual reporting was to be
completed in 2023, with initial ratings given in 2024.
|
| • |
Net zero greenhouse emissions in the EU by 2050: in 2021, the EU adopted a European Climate Law (Regulation (EU) 2021/1119), establishing the aim of reaching net zero
greenhouse gas emissions in the EU by 2050, with an intermediate target of reducing greenhouse gas emissions by at least 55% by 2030, compared to 1990 levels. In July 2021, the European Commission launched the “Fit for 55” to support the
climate policy agenda. As of January 2019, large ships calling at EU ports have been required to collect and publish data on carbon dioxide emissions and other information.
|
| • |
Maritime emissions trading scheme in force on January 1, 2024: the maritime emissions trading scheme, or ETS, is to apply gradually over the period from 2024 to 2026. 40%
of allowances would have to be surrendered in 2025 for the year 2024; 70% of allowances would have to be surrendered in 2026 for the year 2025; and 100% of allowances would have to be surrendered in 2027 for the year 2026. Compliance is
to be on a companywide (rather than per ship) basis and “shipping company” is defined widely to capture both the ship owner and any contractually appointed commercial operator/ship manager/bareboat charterer who not only assume full
compliance for ETS but also under the ISM Code. If the latter contractual arrangement is entered into this needs to be reflected in a certified mandate signed by both parties and presented to the administrator of the scheme. The cap under
the ETS would be set by taking into account EU MRV system emissions data for the years 2018 and 2019, adjusted, from year 2021 and is to capture 100% of the emissions from intra-EU maritime voyages; 100% of emissions from ships at berth
in EU ports and 50% of emissions from voyages which start or end at EU ports (but the other destination is outside the EU). Furthermore, the newly passed EU Emissions Trading Directive 2023/959/EC makes clear that all maritime allowances
would be auctioned and there will be no free allocation. 78.4 million emissions allowances are to be allocated specifically to maritime. New systems, personnel, data management systems, costs recovery mechanisms, revised service agreement
terms and emissions reporting procedures will have to be put in place to prepare for and manage the administrative aspect of ETS compliance. The cost of compliance, and of our future EU emissions and costs to purchase an allowance for
emissions (if we must purchase in order to comply) are unknown and difficult to predict, and are based on a number of factors, including the size of our fleet, our trips within and to and from the EU, and the prevailing cost of
allowances.
|
| ● |
maintain a consolidated leverage ratio of not more than 75%;
|
| ● |
maintain minimum free liquidity of $0.5 million per operating vessel but not less than $4.0 million in aggregate; and
|
| ● |
assure no change of control of the company takes place, except with the lessor’s/lender’s prior written consent.
|
| ● |
increase our vulnerability to general economic downturns and adverse competitive and industry conditions;
|
| ● |
require us to dedicate a substantial portion, if not all, of our cash flow from operations to payments on our indebtedness, thereby reducing the availability of our cash flow to fund working capital,
capital expenditures and other general corporate purposes;
|
| ● |
limit our flexibility in planning for, or reacting to, changes in our business and the industry in which we operate;
|
| ● |
place us at a competitive disadvantage compared to competitors that have less debt or better access to capital;
|
| ● |
limit our ability to raise additional financing on satisfactory terms or at all; and
|
| ● |
adversely impact our ability to comply with the financial and other restrictive covenants of our current or future financing arrangements, which could result in an event of default under such agreements.
|
| ● |
generate excess cash flow for investment without jeopardizing our ability to cover current and foreseeable working capital needs (including debt service);
|
| ● |
raise equity and obtain required financing for our existing and new operations;
|
| ● |
identify opportunities in the tanker sector and other seaborne transportation sectors or related sectors;
|
| ● |
locate and acquire suitable vessels;
|
| ● |
identify and consummate acquisitions or joint ventures;
|
| ● |
integrate any acquired business successfully with our existing operations;
|
| ● |
our manager’s ability to hire, train and retain qualified personnel and crew to manage and operate our growing business and fleet;
|
| ● |
enhance our customer base; and
|
| ● |
manage expansion.
|
| • |
fluctuations in interest rates;
|
| • |
fluctuations in the availability or the price of oil and chemicals;
|
| • |
fluctuations in foreign currency exchange rates;
|
| • |
announcements by us or our competitors;
|
| • |
changes in our relationships with customers or suppliers;
|
| • |
actual or anticipated fluctuations in our semi-annual and annual results and those of other public companies in our industry;
|
| • |
changes in United States or foreign tax laws;
|
| • |
international sanctions, embargoes, import and export restrictions, nationalizations, piracy and wars or other conflicts, including the war in Ukraine.
|
| • |
actual or anticipated fluctuations in our operating results from period to period;
|
| • |
shortfalls in our operating results from levels forecast by securities analysts;
|
| • |
market conditions in the shipping industry and the general state of the securities markets;
|
| • |
business interruptions caused by the outbreak of epidemic and pandemic disease or the war in Ukraine;
|
| • |
mergers and strategic alliances in the shipping industry;
|
| • |
changes in government regulation;
|
| • |
a general or industry-specific decline in the demand for, and price of, shares of our common shares resulting from capital market conditions independent of our operating performance;
|
| • |
the loss of any of our key management personnel;
|
| • |
our failure to successfully implement our business plan;
|
| • |
issuance of shares; and
|
| • |
stock splits / reverse stock splits.
|
| • |
actual or anticipated fluctuations in our results and those of other public companies in our industry;
|
| • |
mergers and strategic alliances in the shipping industry;
|
| • |
market conditions in the shipping industry and the general state of the securities markets;
|
| • |
changes in government regulation;
|
| • |
shortfalls in our operating results from levels forecast by securities analysts; and
|
| • |
announcements concerning us or our competitors.
|
| ● |
our existing shareholders’ proportionate ownership interest in us will decrease;
|
| ● |
the amount of cash available for dividends payable on the shares of our common shares may decrease;
|
| ● |
the relative voting strength of each previously outstanding common share may be diminished; and
|
| ● |
the market price of the shares of our common shares may decline.
|
| • |
authorizing our Board of Directors to issue “blank check” preferred stock without stockholder approval;
|
| • |
providing for a classified Board of Directors with staggered, three-year terms;
|
| • |
prohibiting cumulative voting in the election of directors;
|
| • |
authorizing the removal of directors only for cause and only upon the affirmative vote of the holders of at least 80% of the outstanding shares of our capital stock entitled to vote for the directors;
|
| • |
prohibiting shareholder action by written consent unless the written consent is signed by all shareholders entitled to vote on the action;
|
| • |
limiting the persons who may call special meetings of shareholders;
|
| • |
establishing advance notice requirements for nominations for election to our Board of Directors or for proposing matters that can be acted on by shareholders at shareholder meetings; and
|
| • |
restricting business combinations with interested shareholders.
|
| • |
continue to operate our vessels and service our customers;
|
| • |
renew existing charters upon their expiration;
|
| • |
obtain new charters;
|
| • |
obtain financing on commercially acceptable terms;
|
| • |
obtain insurance on commercially acceptable terms;
|
| • |
maintain satisfactory relationships with our customers and suppliers; and
|
| • |
successfully execute our growth strategy.
|
| A. |
History and Development of the Company
|
| B. |
Business Overview
|
|
Name
|
Deadweight
|
Charterer
|
End of firm
period
|
Charterer’s
Optional Periods
|
Gross Rate fixed period/
options
|
|
M/T Eco Marina Del Rey
|
50,000
|
WECO Tankers A/S
|
May 2027
|
1 year
|
$20,500 / $22,500
|
|
Name
|
Deadweight
|
Charterer
|
End of firm
period
|
Charterer’s
Optional Periods
|
Gross Rate fixed period/
options
|
|
M/T Eco Bel Air
|
157,000
|
Trafigura
|
December 10, 2025
|
-
|
$24,000
|
|
M/T Eco Beverly Hills
|
157,000
|
Trafigura
|
December 1, 2025
|
-
|
$24,000
|
|
Name
|
Deadweight
|
Charterer
|
End of firm
period
|
Charterer’s
Optional Periods
|
Gross Rate fixed
period/
options
|
|
M/T Eco Oceano CA
|
157,000
|
Central Tankers Chartering
|
March 2037
|
none
|
$24,500
|
|
M/T Eco West Coast
|
157,000
|
Clearlake
|
January 2027
|
1+1 years
|
$32,850 / $34,750 / $36,750
|
|
M/T Eco Malibu
|
157,000
|
Clearlake
|
March 2027
|
1+1 years
|
$32,850 / $34,750 / $36,750
|
|
Name
|
Deadweight
|
Charterer
|
End of firm
period
|
Charterer’s Optional
Periods
|
Gross Rate fixed period/
options
|
|
M/T Julius Caesar
|
300,000
|
Trafigura
|
January 2028
|
1+1 years
|
$36,000 up to January 2025 and $41,500 afterwards / $44,000 / $46,000
|
|
M/T Legio X Equestris
|
300,000
|
Trafigura
|
March 2028
|
1+1 years
|
$35,750 up to March 2025 and $41,500 afterwards / $44,000 / $46,000
|
|
Name
|
Deadweight
|
Charterer
|
End of firm period
|
Charterer’s
Optional Periods
|
Gross Rate fixed period/
options
|
|
M/T Eco Yosemite Park
|
50,000
|
Clearlake
|
August 2031
|
1+1 years
|
$19,500 / $18,650 / $19,900
|
|
M/T Eco Joshua Park
|
50,000
|
Clearlake
|
August 2031
|
1+1 years
|
$19,500 / $18,650 / $19,900
|
| (i) |
injury to, destruction or loss of, or loss of use of, natural resources and related assessment costs;
|
| (ii) |
injury to, or economic losses resulting from, the destruction of real and personal property;
|
| (iii) |
net loss of taxes, royalties, rents, fees or net profit revenues resulting from injury, destruction or loss of real or personal property, or natural resources;
|
| (iv) |
loss of subsistence use of natural resources that are injured, destroyed or lost;
|
| (v) |
lost profits or impairment of earning capacity due to injury, destruction or loss of real or personal property or natural resources; and
|
| (vi) |
net cost of increased or additional public services necessitated by removal activities following a discharge of oil, such as protection from fire, safety or health hazards, and loss of subsistence use of
natural resources.
|
| C. |
Organizational Structure
|
| D. |
Property, Plants and Equipment
|
| ITEM 4A. |
UNRESOLVED STAFF COMMENTS
|
| ITEM 5. |
OPERATING AND FINANCIAL REVIEW AND PROSPECTS
|
| A. |
Operating Results
|
|
2023
|
2024
|
|||||||
|
FLEET DATA
|
||||||||
|
Total number of vessels at end of period (including leased vessels)
|
8
|
8
|
||||||
|
Average number of vessels(1)
|
8
|
8
|
||||||
|
Total calendar days for fleet
|
2,920
|
2,928
|
||||||
|
Total available days for fleet
|
2,920
|
2,886
|
||||||
|
Total operating days for fleet
|
2,920
|
2,885
|
||||||
|
Total time charter days for fleet
|
2,920
|
2,885
|
||||||
|
Fleet utilization
|
100.00
|
%
|
99.97
|
%
|
||||
|
2023
|
2024
|
|||||||
|
AVERAGE DAILY RESULTS
|
||||||||
|
Time charter equivalent(2)
|
$
|
27,856
|
$
|
29,157
|
||||
|
Vessel operating expenses(3)
|
$
|
6,345
|
$
|
6,518
|
||||
|
General and administrative expenses(4)
|
$
|
2,293
|
$
|
2,564
|
||||
| (1) |
Average number of vessels is the number of vessels that constituted our fleet (including chartered in vessels) for the relevant period, as measured by the sum of the number of days each vessel was a part of
our fleet during the period divided by the number of calendar days in that period.
|
| (2) |
Time charter equivalent rate, or TCE rate, is a measure of the average daily revenue performance of a vessel. Our definition of TCE may not be the same as reported by other companies in the shipping
industry or other industries. Our method of calculating TCE rate is determined by dividing TCE revenues by operating days for the relevant time period. TCE revenues are revenues minus voyage expenses. Voyage expenses primarily consist of
port, canal and fuel costs that are unique to a particular voyage, which would otherwise be paid by the charterer under a time charter contract, but are payable by us in the case of a voyage charter, as well as commissions. TCE revenues
and TCE rate, non-U.S. GAAP measures, are standard shipping industry performance measures that provide additional supplemental information in conjunction with shipping revenues, the most directly comparable U.S. GAAP measure. We use TCE
rates and TCE revenues to compare period-to-period changes in our performance and it assists investors and our management in evaluating our financial performance. The following table reconciles our net revenues from vessel to TCE rate.
|
| (3) |
Operating expenses include crew wages and related costs, insurance, repairs and maintenance, spares and consumable stores, tonnage taxes and value added tax, or VAT, and other miscellaneous expenses. Daily
vessel operating expenses are calculated by dividing vessel operating expenses by fleet calendar days for the relevant time period. Our ability to control our fixed and variable expenses, including our daily vessel operating expenses,
also affects our financial results.
|
| (4) |
Daily general and administrative expenses are calculated by dividing general and administrative expenses by fleet calendar days for the relevant time period.
|
|
U.S. dollars in thousands, except average daily time charter equivalent and total operating days
|
2023
|
2024
|
||||||
|
On a consolidated basis
|
||||||||
|
Total Revenues
|
82,949
|
86,127
|
||||||
|
Less:
|
||||||||
|
Voyage expenses
|
(1,609
|
)
|
(2,008
|
)
|
||||
|
Time charter equivalent revenues
|
81,340
|
84,119
|
||||||
|
Total operating days
|
2,920
|
2,885
|
||||||
|
Average Daily Time Charter Equivalent (TCE)
|
$
|
27,856
|
$
|
29,157
|
||||
|
EBITDA*
|
||||||||
|
U.S. dollars in thousands
|
2023
|
2024
|
||||||
|
EBITDA
|
43,058
|
41,399
|
||||||
|
(Expressed in thousands of U.S. Dollars)
|
2023
|
2024
|
||||||
|
Net income
|
6,066
|
5,034
|
||||||
|
Add: Vessel depreciation
|
14,349
|
13,336
|
||||||
|
Add: Interest and finance costs
|
22,989
|
23,496
|
||||||
|
Less: Interest income
|
(346
|
)
|
(467
|
)
|
||||
|
EBITDA
|
43,058
|
41,399
|
||||||
| • |
management of our financial resources, including banking relationships, i.e., administration of SLBs, bank loans and bank accounts;
|
| • |
management of our accounting system and records and financial reporting;
|
| • |
administration of the legal and regulatory requirements affecting our business and assets; and
|
| • |
management of the relationships with our service providers and customers.
|
| • |
charter rates and periods of charter hire for our tankers;
|
| • |
utilization of our tankers (earnings efficiency);
|
| • |
levels of our tanker’s operating expenses and dry-docking costs;
|
| • |
depreciation and amortization expenses;
|
| • |
financing costs; and
|
| • |
fluctuations in foreign exchange rates.
|
|
(Expressed in thousands of U.S. Dollars)
|
Year Ended December 31,
|
change
|
||||||||||||||
|
2023
|
2024
|
YE23 v YE24
|
||||||||||||||
|
$
|
|
% | ||||||||||||||
|
Total charter revenues
|
82,949
|
86,127
|
3,178
|
4
|
%
|
|||||||||||
|
Voyage expenses
|
1,609
|
2,008
|
399
|
25
|
%
|
|||||||||||
|
Operating lease Expense
|
10,840
|
10,869
|
29
|
0
|
%
|
|||||||||||
|
Vessel operating expenses
|
18,527
|
19,086
|
559
|
3
|
%
|
|||||||||||
|
Dry-docking costs
|
-
|
3,152
|
3,152
|
100
|
%
|
|||||||||||
|
Vessel depreciation
|
14,349
|
13,336
|
(1,013
|
)
|
-7
|
%
|
||||||||||
|
Management fees-related parties
|
2,200
|
2,266
|
66
|
3
|
%
|
|||||||||||
|
General and administrative expenses
|
6,697
|
7,506
|
809
|
12
|
%
|
|||||||||||
|
Operating income
|
28,727
|
27,904
|
(823
|
)
|
-3
|
%
|
||||||||||
|
Interest and finance costs
|
(22,989
|
)
|
(23,496
|
)
|
(507
|
)
|
2
|
%
|
||||||||
|
Interest income
|
346
|
467
|
121
|
35
|
%
|
|||||||||||
|
Equity gain/(loss) in unconsolidated joint ventures
|
(18
|
)
|
159
|
177
|
100
|
%
|
||||||||||
|
Total other expenses, net
|
(22,661
|
)
|
(22,870
|
)
|
(209
|
)
|
1
|
%
|
||||||||
|
Net income
|
6,066
|
5,034
|
(1,032
|
)
|
-17
|
%
|
||||||||||
| 1. |
Total charter revenues
|
| 2. |
Vessel depreciation
|
| 3. |
General and administrative expenses
|
| 4. |
Voyage expenses
|
| 5. |
Dry-docking costs
|
| 6. |
Interest and finance costs
|
| B. |
Liquidity and Capital Resources
|
| C. |
Research and Development, Patents and Licenses, Etc.
|
| D. |
Trend Information
|
| E. |
Critical Accounting Estimates
|
| A. |
Directors and Senior Management
|
|
Name
|
Age
|
Position
|
||
|
Evangelos J. Pistiolis
|
52
|
Director, President, Chief Executive Officer
|
||
|
Alexandros Tsirikos
|
50
|
Director, Chief Financial Officer
|
||
|
Konstantinos Patis
|
51
|
Chief Technical Officer
|
||
|
Vangelis G. Ikonomou
|
60
|
Chief Operating Officer
|
||
|
Konstantinos Karelas
|
51
|
Independent Non-Executive Director
|
||
|
Stavros Emmanuel
|
82
|
Independent Non-Executive Director
|
||
|
Paolo Javarone
|
52
|
Independent Non-Executive Director
|
| B. |
Compensation
|
| C. |
Board Practices
|
| D. |
Employees
|
| E. |
Share Ownership
|
| F. |
Disclosure of a registrant’s action to recover erroneously awarded compensation.
|
| A. |
Major Shareholders
|
|
Name and Address of Beneficial Owner
|
Number of Shares Owned
|
Percentage
of Class
|
Percentage
of Total
Voting Power
|
||||||
|
Lax Trust (1)
|
100,000 Series D Preferred Shares (1)
|
100
|
%
|
95.58
|
%
|
||||
|
3 Sororibus Trust(2)
|
2,930,718 Common Shares
|
63.35
|
%
|
2.80
|
%
|
||||
|
Evangelos J. Pistiolis(3)
|
440,711 Common Shares
|
9.53
|
%
|
0.42
|
%
|
||||
|
Executive officers, directors and key employees(4)
|
0 Common Shares
|
0
|
%
|
0.00
|
%
|
||||
| (1) |
The Lax Trust is an irrevocable trust established for the benefit of certain family members of Mr. Evangelos J. Pistiolis, our President, Chief Executive Officer and Director. The business address of the
Lax Trust is Level 3, 18 Stanley Street, Auckland 1010, New Zealand. As a prerequisite for the Navigare Lease, Mr. Evangelos J. Pistiolis personally guaranteed the performance of the bareboat charters entered in connection with the lease,
under certain circumstances, and in exchange, we amended the Certificate of Designations governing the terms of the Series D Preferred Shares, to adjust the voting rights per share of Series D Preferred Shares such that during the term of
the Navigare Lease, the combined voting power controlled by Mr. Evangelos J. Pistiolis and the Lax Trust does not fall below a majority of our total voting power, irrespective of any new common or preferred stock issuances, and thereby
complying with a relevant covenant of the bareboat charters entered in connection with the Navigare Lease. The above percentage of total voting power is based on 100,000,000 votes carried by the outstanding Series D Preferred Share (1,000
votes per Series D Preferred Share held).
|
| (2) |
The above information is derived, in part, from the Amendment No. 39 to the 13D/A filed with the SEC on February 14, 2024. 3 Sororibus Trust is an irrevocable trust established for the benefit of certain
family members of Mr. Evangelos J. Pistiolis. The business address of 3 Sororibus Trust is 31 Kitiou Kyprianou, 3036, Limassol, Cyprus. 3 Sororibus Trust is the sole shareholder of Family Trading Inc., or Family Trading, a Marshall
Islands corporation, and may be deemed to beneficially own all of the common shares beneficially owned by Family Trading.
|
| (3) |
The above information is derived, in part, from the Amendment No. 39 to the 13D/A filed with the SEC on February 14, 2024.
|
| (4) |
Excludes the shares held by Mr. Evangelos J. Pistiolis that are reported elsewhere in this table.
|
| B. |
Related Party Transactions
|
| C. |
Interests of Experts and Counsel
|
| A. |
Consolidated Statements and Other Financial Information
|
| B. |
Significant Changes
|
| A. |
Share Capital
|
| B. |
Memorandum and Articles of Association
|
| ● |
prior to the date of the transaction that resulted in the shareholder becoming an interested shareholder, the Board approved either the business combination or the transaction that resulted in the
shareholder becoming an interested shareholder;
|
| ● |
upon consummation of the transaction that resulted in the shareholder becoming an interested shareholder, the interested shareholder owned at least 85% of the voting stock of the corporation outstanding at
the time the transaction commenced;
|
| ● |
at or subsequent to the date of the transaction that resulted in the shareholder becoming an interested shareholder, the business combination is approved by the Board and authorized at an annual or special
meeting of shareholders by the affirmative vote of at least 66 2/3% of the outstanding voting stock that is not owned by the interested shareholder; and
|
| ● |
the shareholder became an interested shareholder prior to the consummation of the initial public offering.
|
| ● |
not be redeemable;
|
| ● |
entitle holders to quarterly dividend payments in an amount per share equal to the aggregate per share amount of all cash dividends, and the aggregate per share amount (payable in kind) of all non-cash
dividends or other distributions other than a dividend payable in our common shares or a subdivision of our outstanding common shares (by reclassification or otherwise), declared on our common shares since the immediately preceding
quarterly dividend payment date; and
|
| ● |
entitle holders to one vote on all matters submitted to a vote of our shareholders.
|
| ● |
Flip In. If an Acquiring Person obtains beneficial ownership of 15% or more of our common shares, then each Right will entitle the holder thereof to purchase, for the
Exercise Price, a number of our common shares (or, in certain circumstances, cash, property or other of our securities) having a then-current market value of twice the Exercise Price. However, the Rights are not exercisable following the
occurrence of the foregoing event until such time as the Rights are no longer redeemable by us, as further described below.
|
| ● |
Flip Over. If, after an Acquiring Person obtains 15% or more of our common shares, (i) we merge into another entity; (ii) an acquiring entity merges into us; or (iii) we
sell or transfer 50% or more of its assets, cash flow or earning power, then each Right (except for Rights that have previously been voided as set forth above) will entitle the holder thereof to purchase, for the Exercise Price, a number
of our common shares of the person engaging in the transaction having a then-current market value of twice the Exercise Price.
|
| ● |
Notional Shares. Shares held by affiliates and associates of an Acquiring Person, including certain entities in which the Acquiring Person beneficially owns a majority of
the equity securities, and Notional Common Shares (as defined in the Rights Agreement) held by counterparties to a Derivatives Contract (as defined in the Rights Agreement) with an Acquiring Person, will be deemed to be beneficially owned
by the Acquiring Person.
|
| C. |
Material Contracts
|
| D. |
Exchange controls
|
| E. |
Taxation
|
| (1) |
we are organized in a foreign country, or our “country of organization,” that grants an “equivalent exemption” to corporations organized in the United States; and
|
| (2) |
either
|
| A. |
more than 50% of the value of our stock is owned, directly or indirectly, by individuals who are “residents” of our country of organization or of another foreign country that grants an “equivalent
exemption” to corporations organized in the United States (each such individual a “qualified shareholder” and such individuals collectively, “qualified shareholders”), which we refer to as the “50% Ownership Test,” or
|
| B. |
our stock is “primarily and regularly traded on an established securities market” in our country of organization, in another country that grants an “equivalent exemption” to U.S. corporations, or in the
United States, which we refer to as the “Publicly-Traded Test.”
|
| ● |
We have, or are considered to have, a fixed place of business in the United States involved in the earning of shipping income; and
|
| ● |
substantially all of our U.S.-source shipping income is attributable to regularly scheduled transportation, such as the operation of a vessel that follows a published schedule with repeated sailings at
regular intervals between the same points for voyages that begin or end in the United States, or, in the case of leasing income, is attributable to such fixed place of business in the United States.
|
| ● |
at least 75% of our gross income for such taxable year consists of passive income (e.g., dividends, interest, capital gains and rents derived other than in the active conduct of a rental business); or
|
| ● |
at least 50% of the average value of the assets held by the corporation during such taxable year produce, or are held for the production of, passive income.
|
| ● |
the excess distribution or gain would be allocated ratably over the Non-Electing Holder’s aggregate holding period for the common shares;
|
| ● |
the amount allocated to the current taxable year and any taxable year before we became a PFIC would be taxed as ordinary income; and
|
| ● |
the amount allocated to each of the other taxable years would be subject to tax at the highest rate of tax in effect for the applicable class of taxpayer for that year, and an interest charge for the deemed
tax deferral benefit would be imposed with respect to the resulting tax attributable to each such other taxable year.
|
| ● |
the gain is effectively connected with a trade or business conducted by the Non-U.S. Holder in the United States. If the Non-U.S. Holder is entitled to the benefits of a U.S. income tax treaty with respect
to that gain, that gain is taxable only if it is attributable to a permanent establishment maintained by the Non-U.S. Holder in the United States; or
|
| ● |
the Non-U.S. Holder is an individual who is present in the United States for 183 days or more during the taxable year of disposition and other conditions are met.
|
| ● |
fail to provide an accurate taxpayer identification number;
|
| ● |
are notified by the IRS that you have failed to report all interest or dividends required to be shown on your U.S. federal income tax returns; or
|
| ● |
in certain circumstances, fail to comply with applicable certification requirements.
|
| F. |
Dividends and Paying Agents
|
| G. |
Statement by Experts
|
| H. |
Documents on Display
|
| I. |
Subsidiary Information
|
| J. |
Annual Report to Security Holders
|
| ITEM 14. |
MATERIAL MODIFICATIONS TO THE RIGHTS OF SECURITY HOLDERS AND USE OF PROCEEDS
|
| a) |
Disclosure Controls and Procedures
|
| b) |
Management’s Annual Report on Internal Control over Financial Reporting
|
| ● |
Pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of our assets;
|
| ● |
Provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that our receipts and
expenditures are being made only in accordance with authorizations of Company’s management and directors; and
|
| ● |
Provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of our assets that could have a material effect on the financial statements.
|
| c) |
Attestation Report of the Registered Public Accounting Firm
|
| d) |
Changes in Internal Control over Financial Reporting
|
| ITEM 16A. |
AUDIT COMMITTEE FINANCIAL EXPERT
|
|
U.S. dollars in thousands,
|
Year Ended
|
|||||||
|
2023
|
2024
|
|||||||
|
Audit Fees
|
410.3
|
342.0
|
||||||
| ITEM 16D. |
EXEMPTIONS FROM THE LISTING STANDARDS FOR AUDIT COMMITTEES
|
| ITEM 16F. |
CHANGE IN REGISTRANT’S CERTIFYING ACCOUNTANT
|
| ITEM 16G. |
CORPORATE GOVERNANCE
|
| • |
Audit Committee. The NYSE requires, among other things, that a listed company has an audit committee with a minimum of three independent members, at least one of whom
meets certain standards of financial sophistication. As permitted under Marshall Islands law, our audit committee consists of three independent directors but we do not designate any one audit commit member as meeting the standards of
financial sophistication.
|
| • |
Meetings of Directors. In lieu of holding a meeting of our Board of Directors on at least a quarterly basis and a regularly scheduled meetings of the independent
directors, including at least annually in executive session without the presence of non-independent directors and management, we will comply with the provisions of Marshall Islands law and our bylaws, which do not require such regularly
scheduled meetings.
|
| • |
Shareholder Approval of Equity Compensation Plans. The NYSE requires listed companies to obtain prior shareholder approval to adopt or materially revise any equity
compensation plan. As permitted under Marshall Islands law, we do not need prior shareholder approval to adopt or revise equity compensation plans.
|
| • |
Share Issuances. In lieu of obtaining shareholder approval prior to the sale, issuance, or potential issuance of common stock (or securities
convertible into common stock) at a price less than the greater of book or market value which together with sales by officers, directors or principal shareholders of the issuer equals 20% or more of presently outstanding common stock
and the sale, issuance, or potential issuance of common stock (or securities convertible into common stock) equal to 20% or more of presently outstanding stock for less than the greater of book or market value of the stock, we will
comply with the provisions of Marshall Islands law, which allows our Board of Directors to approve share issuances.
|
| • |
Proxy Statements. As a foreign private issuer, we are not required to solicit proxies or provide proxy statements to the NYSE pursuant to Marshall Islands law. Consistent
with Marshall Islands law and as provided in our bylaws, we will notify our shareholders of meetings between 15 and 60 days before the meeting. This notification will contain, among other things, information regarding business to be
transacted at the meeting. In addition, our bylaws provide that shareholders must give us between 120 and 180 days’ advance notice to properly introduce any business at a meeting of the shareholders.
|
| ITEM 16H. |
MINE SAFETY DISCLOSURE
|
| ITEM 16I. |
DISCLOSURE REGARDING FOREIGN JURISDICTIONS THAT PREVENT INSPECTIONS
|
|
ITEM 16J.
|
INSIDER TRADING POLICIES
|
|
ITEM 16K.
|
CYBERSECURITY
|
|
|
(i)
|
Continuous monitoring of cybersecurity threats, both internal and external. through the use of data analytics and network monitoring systems.
|
|
|
(ii)
|
|
|
|
(iii)
|
Overall assessment of cybersecurity incidents materiality and potential impact on the company’s operations and financial condition by our senior
management team and our board of directors, in cooperation, if considered necessary, with specialized external consultants.
|
|
|
(iv)
|
|
|
|
(v)
|
Training and Awareness – we have various information technology policies relating to cybersecurity. We also provide employee training that is
administered on a periodic and on a case-by-case basis that reinforces our information technology policies, standards and practices, as well as the expectation that employees comply with these policies and identify and report potential
cybersecurity risks.
|
|
ITEM 17.
|
FINANCIAL STATEMENTS
|
|
ITEM 18.
|
FINANCIAL STATEMENTS
|
|
Number
|
Description of Exhibits
|
|
1.1
|
|
|
1.2
|
|
|
1.3
|
|
|
1.4
|
|
|
1.5
|
|
|
1.6
|
|
|
1.7
|
|
|
1.8
|
|
|
1.9
|
|
| 1.10 |
|
|
1.11
|
|
|
1.12
|
|
|
1.13
|
|
|
1.14
|
|
|
2.1
|
|
|
2.2
|
|
|
2.3
|
|
2.4
|
|
2.5
|
|
|
2.6
|
|
|
2.7
|
|
|
2.8
|
|
|
4.1
|
|
|
4.2
|
|
|
4.3
|
|
|
4.4
|
|
|
4.5
|
|
|
4.6
|
|
|
4.7
|
|
|
4.8
|
|
|
4.9
|
|
|
4.10
|
|
|
4.11
|
|
|
4.12
|
|
4.13
|
|
|
4.14
|
|
|
4.15
|
|
|
4.16
|
|
|
4.17
|
|
|
4.18
|
|
4.19
|
|
|
4.20
|
|
|
4.21
|
|
|
4.22
|
|
|
4.23
|
|
|
4.24
|
|
|
4.25
|
|
|
4.26
|
|
|
4.27
|
|
|
4.28
|
|
4.29
|
|
|
4.30
|
|
|
4.31
|
|
|
4.32
|
|
4.33
|
|
|
4.34
|
|
|
4.35
|
|
|
4.36
|
|
|
4.37
|
|
|
4.38
|
|
|
4.39
|
|
|
8.1
|
|
|
11.1
|
|
|
12.1
|
|
|
12.2
|
|
|
13.1
|
|
|
13.2
|
|
|
15.1
|
|
|
15.2
|
|
|
97.1
|
|
|
101
|
The following materials from the Company’s Annual Report on Form 20-F for the fiscal year ended December 31, 2024, formatted in Inline eXtensible Business Reporting Language (iXBRL):
(i) Consolidated Balance Sheets as of December 31, 2023 and 2024; (ii) Consolidated Statements of Comprehensive Income/(Loss) for the years ended December 31, 2022, 2023 and 2024; (iii) Consolidated Statements of Stockholders’ Equity for
the years ended December 31, 2022, 2023 and 2024; (iv) Consolidated Statements of Cash Flows for the years ended December 31, 2022, 2023 and 2024; and (v) Notes to Consolidated Financial Statements
|
|
104
|
Cover Page Interactive Data File (formatted as Inline XBRL and contained in Exhibit 101
|
| * |
Filed herewith
|
|
TOP SHIPS INC.
|
||
|
(Registrant)
|
||
|
Date: April 14, 2025
|
By:
|
/s/ Evangelos J. Pistiolis
|
|
Evangelos J. Pistiolis
|
||
|
President, Chief Executive Officer, and Director
|
||
TOP SHIPS INC.
INDEX TO CONSOLIDATED FINANCIAL STATEMENTS
REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM
|
December 31, |
December 31, |
|||||||
|
2023 |
2024 |
|||||||
|
ASSETS |
||||||||
|
|
||||||||
|
CURRENT ASSETS: |
||||||||
|
|
||||||||
|
Cash and cash equivalents |
||||||||
|
Restricted cash (Note 6)
|
||||||||
|
Trade accounts receivable |
||||||||
|
Prepayments and other |
||||||||
|
Right of use assets from operating leases (Note 6)
|
||||||||
|
Deposit asset (Note 6)
|
||||||||
|
Inventories |
||||||||
|
Total current assets |
||||||||
|
FIXED ASSETS: |
||||||||
|
Vessels, net (Note 4) |
||||||||
|
Right of use assets from operating leases (Note 6) |
||||||||
|
Other fixed assets, net |
||||||||
|
Total fixed assets |
||||||||
|
OTHER NON-CURRENT ASSETS: |
||||||||
|
Restricted cash (Note 7) |
||||||||
|
Advances for asset acquisitions to related party (Note 5)
|
||||||||
|
Investments in unconsolidated joint ventures (Note 16) |
||||||||
|
Trade accounts receivable, non-current
|
||||||||
|
Deposit asset (Note 6) |
||||||||
|
Deferred Charges
|
||||||||
|
Total non-current assets |
||||||||
|
Total assets |
||||||||
|
LIABILITIES, MEZZANINE EQUITY AND STOCKHOLDERS’ EQUITY |
||||||||
|
CURRENT LIABILITIES: |
||||||||
|
Current portion of long-term debt (Note 7) |
||||||||
|
Due to (Note 5) |
||||||||
|
Accounts payable |
||||||||
|
Accrued liabilities |
||||||||
|
Unearned revenue |
||||||||
|
Current portion of Operating lease liabilities (Note 6) |
||||||||
|
Current portion of Vessel fair value participation liability (Note 7)
|
||||||||
|
Total current liabilities |
||||||||
|
NON-CURRENT LIABILITIES: |
||||||||
|
Non-current portion of long-term debt (Note 7) |
||||||||
|
Non-current portion of Operating lease liabilities (Note 6) |
||||||||
|
Unearned revenue, non-current |
||||||||
|
Total non-current liabilities |
||||||||
|
COMMITMENTS AND CONTINGENCIES (Note 8) |
||||||||
|
Total liabilities |
||||||||
|
MEZZANINE EQUITY: |
||||||||
|
Preferred stock, $ |
||||||||
|
Preferred stock, Paid-in capital in excess of par
|
||||||||
|
Total mezzanine equity |
||||||||
|
STOCKHOLDERS’ EQUITY: |
||||||||
|
Preferred stock, $ |
||||||||
|
Common stock, $ |
||||||||
|
Additional paid-in capital |
||||||||
|
Accumulated deficit |
( |
) | ( |
) | ||||
|
Total stockholders’ equity |
||||||||
|
|
||||||||
|
Total liabilities, mezzanine equity and stockholders’ equity |
||||||||
The accompanying notes are an integral part of these consolidated financial statements.
FOR THE YEARS ENDED DECEMBER 31, 2022, 2023 and 2024
|
2022 |
2023 |
2024 |
||||||||||
|
Revenues (including $ |
||||||||||||
|
EXPENSES: |
||||||||||||
|
Voyage expenses (including $ |
||||||||||||
|
Operating lease expense (Note 6) |
||||||||||||
|
Vessel operating expenses (including $ |
||||||||||||
|
Dry-docking costs |
||||||||||||
|
Vessel depreciation (Note 4) |
||||||||||||
|
Management fees-related parties (Note 5) |
||||||||||||
|
General and administrative expenses (including $ |
||||||||||||
|
Gain on sale of vessels |
( |
) | ||||||||||
|
Operating income |
||||||||||||
|
|
||||||||||||
|
OTHER EXPENSES: |
||||||||||||
|
Interest and finance costs (including $ |
( |
) | ( |
) | ( |
) | ||||||
|
Interest income |
||||||||||||
|
Equity gain/(loss) in unconsolidated joint ventures |
( |
) | ||||||||||
|
Total other expenses, net |
( |
) | ( |
) | ( |
) | ||||||
|
Net income and comprehensive income |
||||||||||||
|
Less: Deemed dividend equivalents on preferred shares related to redemption value (Note 15) |
( |
) | ||||||||||
|
Less: Preferred shares dividend (Note 15) |
( |
) | ( |
) | ||||||||
|
Less: Deemed dividend on warrant inducement (Note 9)
|
( |
) | ||||||||||
|
Less: Deemed dividend on Series E Shares conversion
|
( |
) | ||||||||||
|
Net (loss)/income attributable to common shareholders |
( |
) | ( |
) | ||||||||
|
(Loss)/Earnings per common share, basic and diluted (Note 10) |
( |
) | ( |
) | ||||||||
The accompanying notes are an integral part of these consolidated financial statements.
TOP SHIPS INC.
CONSOLIDATED STATEMENTS OF MEZZANINE AND STOCKHOLDERS’ EQUITY
FOR THE YEARS ENDED DECEMBER 31, 2022, 2023 and 2024
(Expressed in thousands of U.S. Dollars – except number of shares and per share data)
| Mezzanine Equity | Preferred Stock | Common Stock |
Additional
|
Accumulated Deficit
attributable
|
||||||||||||||||||||||||||||||||||||
|
# of Shares |
Par
Value
|
Mezzanine Equity |
# of Shares |
Par Value |
# of Shares |
Par Value |
Paid-In
Capital |
to common stockholders |
Total |
|||||||||||||||||||||||||||||||
|
BALANCE, December 31, 2021 |
( |
) | ||||||||||||||||||||||||||||||||||||||
|
Net Income |
||||||||||||||||||||||||||||||||||||||||
|
Stock-based compensation |
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Redemption of fractional shares due to reverse stock split |
( |
) | ( |
) | ( |
) | ||||||||||||||||||||||||||||||||||
|
Issuance of preferred shares (Note 15) |
- | |||||||||||||||||||||||||||||||||||||||
|
Deemed dividend of Series F shares related to redemption value |
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Dividends of preferred shares (Note 15) |
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Exercise of warrants, net of fees |
||||||||||||||||||||||||||||||||||||||||
|
Redemptions of preferred shares (Note 15) |
( |
) | ( |
) | ( |
) | - | |||||||||||||||||||||||||||||||||
|
Issuance of common stock pursuant to equity offerings, net (Note 9)
|
||||||||||||||||||||||||||||||||||||||||
|
Deemed dividend on warrant inducement (Note 9)
|
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Incremental fair value of the October 2022 Warrants (Note 9)
|
||||||||||||||||||||||||||||||||||||||||
|
BALANCE, December 31, 2022 |
( |
) | ||||||||||||||||||||||||||||||||||||||
|
Net Income
|
||||||||||||||||||||||||||||||||||||||||
|
Redemption of fractional shares due to reverse stock split
|
( |
) | ||||||||||||||||||||||||||||||||||||||
|
Conversion of Series E Shares (Note 15)
|
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Deemed dividend on Series E Shares conversion (Note 15)
|
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Dividends of preferred shares (Note 15)
|
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Exercise of warrants, net of fees
|
||||||||||||||||||||||||||||||||||||||||
|
Redemptions of preferred shares (Note 15)
|
( |
) | ( |
) | ( |
) | - | |||||||||||||||||||||||||||||||||
|
Issuance of common stock pursuant to equity offerings, net (Note 9)
|
||||||||||||||||||||||||||||||||||||||||
|
BALANCE, December 31, 2023
|
( |
) | ||||||||||||||||||||||||||||||||||||||
| Net Income | ||||||||||||||||||||||||||||||||||||||||
|
Equity offering costs
|
( |
) | ( |
) | ||||||||||||||||||||||||||||||||||||
|
Redemptions of preferred shares (Note 15)
|
( |
) | ( |
) | ( |
) | - | |||||||||||||||||||||||||||||||||
|
BALANCE, December 31, 2024
|
( |
) | ||||||||||||||||||||||||||||||||||||||
The accompanying notes are an integral part of these consolidated financial statements.
TOP SHIPS INC.
CONSOLIDATED STATEMENTS OF CASH FLOWS
FOR THE YEARS ENDED DECEMBER 31, 2022, 2023 and 2024
(Expressed in thousands of U.S. Dollars)
|
2022 |
2023 |
2024 |
||||||||||
|
Cash Flows from Operating Activities: |
||||||||||||
|
Net income |
||||||||||||
|
Adjustments to reconcile net income to net cash provided by operating activities: |
||||||||||||
|
Vessel depreciation |
||||||||||||
|
Other fixed assets depreciation |
||||||||||||
|
Equity (gains)/losses in unconsolidated joint ventures |
( |
) | ( |
) | ||||||||
|
Dividends from cumulative earnings of joint venture |
||||||||||||
|
Amortization and write off of deferred financing costs and debt discounts |
||||||||||||
|
Stock-based compensation expense |
( |
) | ||||||||||
|
Amortization of Right of use assets from operating leases
|
||||||||||||
|
Gain on sale of other fixed assets
|
( |
) | ||||||||||
|
Gain on sale of vessels
|
( |
) | ||||||||||
|
(Increase)/Decrease in: |
||||||||||||
|
Trade accounts receivable |
( |
) | ( |
) | ||||||||
|
Inventories |
( |
) | ( |
) | ||||||||
|
Prepayments and other |
( |
) | ( |
) | ||||||||
|
Increase/(Decrease) in: |
||||||||||||
|
Due to related parties |
( |
) | ( |
) | ||||||||
|
Accounts payable |
( |
) | ( |
) | ||||||||
|
Other non-current liabilities |
( |
) | ( |
) | ||||||||
|
Accrued liabilities |
||||||||||||
|
Unearned revenue |
( |
) | ||||||||||
|
Operating lease liabilities
|
( |
) | ( |
) | ( |
) | ||||||
|
Net Cash provided by Operating Activities |
||||||||||||
|
Cash Flows used in Investing Activities: |
||||||||||||
|
Advances for vessels under construction and capitalized expenses |
( |
) | ||||||||||
|
Advances for asset acquisition from related parties (Note 5)
|
( |
) | ||||||||||
|
Returns of investments in unconsolidated joint ventures (Note 16)
|
||||||||||||
|
Net proceeds from vessel sales |
||||||||||||
|
Net proceeds from sales of other fixed assets, net
|
||||||||||||
|
Net Cash (used in)/ provided by Investing Activities
|
( |
) | ( |
) | ||||||||
|
Cash Flows from Financing Activities: |
||||||||||||
|
Proceeds from debt |
||||||||||||
|
Proceeds from short-term debt
|
||||||||||||
|
Proceeds from related party debt
|
||||||||||||
|
Principal payments and prepayments of related party debt
|
( |
) | ||||||||||
|
Principal payments and prepayments of debt |
( |
) | ( |
) | ( |
) | ||||||
|
Prepayments of short-term debt
|
( |
) | ||||||||||
|
Redemption of preferred shares
|
( |
) | ( |
) | ( |
) | ||||||
|
Proceeds from issuance of common stock |
||||||||||||
|
Proceeds from warrant exercises, net of fees
|
||||||||||||
|
Equity offering issuance costs |
( |
) | ( |
) | ( |
) | ||||||
|
Payment of financing costs |
( |
) | ( |
) | ( |
) | ||||||
|
Dividends of preferred shares
|
( |
) | ( |
) | ||||||||
|
Proceeds from issuance of preferred shares (Note 15)
|
||||||||||||
|
Redemption of fractional shares due to reverse stock split
|
( |
) | ||||||||||
|
Repayment of Vessel fair value participation liability
|
( |
) | ||||||||||
|
Net Cash provided by/(used in) Financing Activities |
( |
) | ( |
) | ||||||||
|
Net increase/(decrease) in cash and cash equivalents and restricted
cash
|
( |
) | ||||||||||
|
Cash and cash equivalents and restricted cash at beginning of year |
||||||||||||
|
Cash and cash equivalents and restricted cash at end of the year |
||||||||||||
|
Cash breakdown |
||||||||||||
|
Cash and cash equivalents |
||||||||||||
|
Restricted cash, current |
||||||||||||
|
Restricted cash, non-current |
||||||||||||
|
SUPPLEMENTAL CASH FLOW INFORMATION |
||||||||||||
|
Interest paid, net of capitalized interest |
||||||||||||
|
Finance fees included in Accounts payable/Accrued liabilities/Due to related parties |
||||||||||||
|
Equity issuance costs and warrant related costs included in liabilities
|
||||||||||||
|
Settlement of related party debt, interest, finance fees, Excess consideration over acquired assets,
capital expenditures and dividends with issuance of preferred shares (Note 15)
|
||||||||||||
|
Deemed dividend equivalents on preferred shares related to redemption value (Note 15)
|
||||||||||||
|
Deemed dividend on warrant inducement (Note 9)
|
||||||||||||
|
Deemed dividend on Series E Shares conversion (Note 15)
|
||||||||||||
The accompanying notes are an integral part of these consolidated financial statements.
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS
AS OF DECEMBER 31, 2023 AND 2024
AND FOR THE YEARS ENDED DECEMBER 31, 2022, 2023 and 2024
(Expressed in thousands of United States Dollars – except share, per share earnings and rate per day, unless otherwise stated)
|
1. |
Basis of Presentation and General Information: |
The consolidated financial statements include the accounts of Top Ships Inc. (formerly Top Tankers Inc. and Ocean Holdings Inc.) and its wholly owned subsidiaries (collectively the “Company”). Ocean Holdings Inc. was formed on January 10, 2000, under the laws of Marshall Islands and was renamed to Top Tankers Inc. and Top Ships Inc. in May 2004 and December 2007, respectively. The Company is an international provider of worldwide oil, petroleum products and chemicals transportation services.
As of
December 31, 2024, the Company was the sole owner of all outstanding shares of the following subsidiary companies. The following list is not exhaustive as the Company has other subsidiaries relating to vessels that have been sold and that remain
dormant for the periods presented in these consolidated financial statements as well as intermediary companies that own shipowning companies that are
|
Companies |
Date of Incorporation |
Country of Incorporation |
Activity |
|
|
|
Top Tanker Management Inc. |
|
|
|
|
Wholly owned Shipowning Companies (“SPC”) with vessels under operating lease during years ended December 31, 2022, 2023 and 2024 |
Date of Incorporation |
Country of Incorporation |
Vessel |
End of operating lease |
|
|
1 |
South California Inc. |
|
|
|
|
|
2 |
Malibu Warrior Inc. |
|
|
|
|
|
Wholly owned Shipowning Companies (“SPC”) with vessels in operation during years ended December 31, 2022, 2023 and 2024 |
Date of Incorporation |
Country of Incorporation |
Vessel |
Delivery Date |
|
|
1 |
PCH Dreaming Inc. |
|
|
|
|
|
2 |
Roman Empire Inc. |
|
|
|
|
|
3 |
Athenean Empire Inc. |
|
|
|
|
| 4 |
Julius Caesar Inc.
|
|
|
|
|
| 5 |
Legio X Inc.
|
|
|
|
|
| 6 |
Eco Oceano CA Inc.
|
|
|
|
|
As of December 31, 2022, 2023 and 2024, the
Company was the owner of
|
SPC |
Date of Incorporation |
Country of Incorporation |
Vessel |
Built Date |
|
|
1 |
California 19 Inc. |
|
|
|
|
|
2 |
California 20 Inc. |
|
|
|
|
On September 29, 2023 the Company effected a reverse stock split of its common stock. There was no change in the number of authorized common shares of the Company, or the floor price of the Company’s Series E Shares, or the number of votes of the Company’s Series D, E and F Shares. All numbers of common share and earnings per share amounts, as well as warrant shares eligible for purchase under the Company’s warrants, exercise price of said warrants and conversion prices of the Company’s Series E Shares, in these consolidated financial statements have been retroactively adjusted to reflect this reverse stock split.
|
2. |
Significant Accounting Policies: |
|
(a) |
Principles of Consolidation: The consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) and include the accounts and operating results of Top Ships Inc. and its subsidiaries referred to in Note 1. Intercompany balances and transactions have been eliminated on consolidation. Non-controlling interests are stated at the non-controlling interest’s proportion of the net assets of the subsidiaries where the Company has less than 100% interest. Subsequent to initial recognition the carrying amount of non-controlling interest is increased or decreased by the non-controlling interest’s share of subsequent changes in the equity of such subsidiaries. Total comprehensive income is attributed to a non-controlling interest even if this results in a deficit balance. Changes in the Company’s ownership interests in subsidiaries that do not result in the Company losing control over the subsidiaries are accounted for as equity transactions and the carrying amounts of the Company’s interests and the non-controlling interests are adjusted to reflect these changes in their relative interests in the subsidiaries. Any difference between the amount by which the non-controlling interests are adjusted and the fair value of the consideration paid or received is recognized directly in equity and attributed to owners of the Company. |
|
(b) |
Use of Estimates: The preparation of consolidated financial statements in conformity with U.S. GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the consolidated financial statements and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates. Significant estimates mainly include impairment of vessels, vessel useful lives and residual values and fair values of derivative instruments. Actual results may differ from these estimates. |
|
(c) |
Foreign Currency Translation: The Company’s functional currency is the U.S. Dollar because all vessels operate in international shipping markets, and therefore primarily transact business in U.S. Dollars. The Company’s books of account are maintained in U.S. Dollars. Transactions involving other currencies during the year are converted into U.S. Dollars using the exchange rates in effect at the time of the transactions. At the balance sheet dates, monetary assets and liabilities, which are denominated in other currencies are translated to U.S. Dollars based on the year-end exchange rates and any gains and losses are included in the consolidated statements of comprehensive income. |
|
(d) |
Cash and Cash Equivalents: The Company considers highly liquid investments such as time deposits and certificates of deposit with an original maturity of three months or less to be cash equivalents. |
|
(e) |
Restricted Cash: The Company considers amounts that are pledged, blocked, held as cash collateral, required to be maintained with a specific bank or be maintained by the Company as minimum cash under the terms of a loan agreement, as restricted and these amounts are presented separately on the balance sheets. In the event original maturities are shorter than twelve months, such deposits are presented as current assets while if original maturities are longer than twelve months, such deposits are presented as non-current assets. |
|
(f) |
Trade Accounts Receivable, net: The amount shown as trade accounts receivable, net at each balance sheet date, includes estimated recoveries from charterers for
hire billings, net of a provision for doubtful accounts and also accrued revenue resulting from straight-line revenue recognition of charter agreements that provide for varying charter rates as well as receivable European Union Allowances
(“EUAs”) from charterers (see below). As of December 31, 2023 and 2024 accrued revenue resulting from straight-line revenue recognition of charter agreements that provide for varying charter rates amounted to $ |
|
(g) |
Inventories: Inventories consist of lubricants, bonded stores and spares on board the vessels. Inventories are stated at the lower of cost and net realizable value. Cost, which consists of the purchase price, is determined by the first in, first out method. |
|
(h) |
Vessel Cost: Vessels are stated at cost, which in case of a newbuilding vessel, consists of the contract price, pre-delivery costs and capitalized interest incurred during its construction, and any material expenses incurred upon acquisition (improvements and delivery costs). Subsequent expenditures for conversions and major improvements are also capitalized when they appreciably extend the life, increase the earning capacity or improve the efficiency or safety of the vessels. Repairs and maintenance are charged to expense as incurred and are included in Vessel operating expenses in the consolidated statements of comprehensive income. |
|
(i) |
Impairment of Long-Lived Assets: The Company evaluates the existence of impairment indicators whenever events or changes in circumstances indicate that the
carrying values of the Company’s long lived assets are not recoverable. Such indicators of potential impairment include, vessel sales and purchases,
business plans, declines in the fair market value of vessels and overall market conditions. If there are indications for impairment present, the Company determines undiscounted projected net operating cash flows for each vessel and compares
it to the vessel’s carrying value. If the carrying value of the related vessel exceeds its undiscounted future net cash flows, the carrying value is reduced to its fair value, and the difference is recognized as an impairment loss. The
impairment evaluation the Company conducted as of December 31, 2023 and 2024 showed that there are |
|
(j) |
Vessel Depreciation: Depreciation is calculated using the straight-line method over the estimated useful life of the vessels, after deducting the estimated salvage
value. Each vessel’s salvage value is equal to the product of its lightweight tonnage and estimated scrap rate, which up until December 31, 2023 was estimated to be $ |
|
(k) |
Long Lived Assets Held for Sale: The Company classifies vessels as being held for sale when the following criteria are met: (a) management, having the authority to approve the action, commits to a plan to sell the asset, (b) the asset is available for immediate sale in its present condition subject only to terms that are usual and customary for sales of such assets, (c) an active program to locate a buyer and other actions required to complete the plan to sell the asset have been initiated, (d) the sale of the asset is probable and transfer of the asset is expected to qualify for recognition as a completed sale, within one year, (e) the asset is being actively marketed for sale at a price that is reasonable in relation to its current fair value, (f) actions required to complete the plan indicate that it is unlikely that significant changes to the plan will be made or that the plan will be withdrawn. |
|
|
Long-lived assets classified as held for sale are measured at the lower of their carrying amount or fair value less costs to sell. These vessels are not depreciated once they meet the criteria to be classified as held for sale. |
|
|
Long-lived assets previously classified as held for sale that are classified as held and used are revalued at the lower of (a) the carrying amount of the asset before it was classified as held for sale, adjusted for any depreciation expense that would have been recognized had the asset been continuously classified as held and used and (b) the fair value of the asset at the date that the Company decided not to sell the asset. |
|
(l) |
Other Fixed Assets, Net: Other fixed assets, net, consist of furniture, office equipment, art works and cars, stated at cost, which consist of the purchase/contract price less accumulated depreciation. Depreciation is calculated using the straight-line method over the estimated useful life of the assets as presented below: |
|
Description |
Useful Life (years) |
|||
|
Cars |
||||
|
Office equipment |
||||
|
Furniture and fittings |
||||
|
Computer equipment |
||||
|
Art works
|
∞
|
|||
| (m) |
Accounting for Dry-Docking Costs: All dry-docking and special survey costs are expensed in the period incurred.
|
| (n) |
Financing Costs: Fees incurred and paid to the lenders for obtaining new loans or Sale and lease backs (“SLBs”) or
refinancing existing ones are recorded as a contra to debt and such fees are amortized to interest and finance costs over the life of the related debt using the effective interest method. Any unamortized balance of costs relating to debt
repaid or refinanced that meet the criteria for Debt Extinguishment (Subtopic 470-50), is expensed in interest and finance costs in the period in which the repayment is made or refinancing occurs. Any unamortized balance of costs relating
to debt refinanced that does not meet the criteria for Debt Extinguishment, is amortized over the term of the refinanced debt.
|
| (o) |
Accounting for Revenue and Expenses: Revenues are generated from time charter arrangements. A time charter is a
contract for the use of a vessel for a specific period of time and a specified daily charter hire rate, which is generally payable monthly in advance. Revenue is shown net of address commissions, if applicable, payable directly to
charterers under the relevant charter agreements. Address commissions represent a common market practice discount (sales incentive) on services rendered by the Company and no identifiable benefit is received in exchange for the
consideration provided to the charterer. Commissions on time charter revenues are recognized on a pro rata basis over the duration of the period.
|
|
The Company based on ASC 842 determined that all time charter-out contracts are considered operating leases and therefore fall under the scope of ASC 842 because: (i) the
vessel is an identifiable asset; (ii) the Company as lessor, does not have substantive substitution rights; and (iii) the charterer, as lessee, has the right to control the use of the vessel during the term of the contract and derives the
economic benefits from such use.
|
|
Time charter revenue is recognized as earned on a straight-line basis over the term of the relevant time charter starting from the vessel’s delivery to the charterer until the
vessel is redelivered to the Company, except for any off-hire period. Revenue generated from variable lease payments is recognized in the period when changes in the facts and circumstances on which the variable lease payments are based
occur. The Company elected to not separate the lease and non-lease components included in the time charter revenue because (i) the pattern of revenue recognition for the lease and non-lease components (included in the daily hire rate) is
the same and (ii) the lease component would be classified as an operating lease. The daily hire rate represents the hire rate for a bare boat charter as well as the compensation for expenses incurred running the vessel such as crewing
expense, repairs, insurance, maintenance and lubes. Both the lease and non-lease components are earned by passage of time. Under a time charter agreement, management fees and vessel operating expenses such as crew wages, provisions and
stores, technical maintenance and insurance expenses as well as limited voyage expenses, mainly consisting of broker’s commissions, are paid by the vessel owner, whereas voyage expenses such as bunkers, port expenses, agents’ fees, and
extra war risk insurance are paid by the charterer. Vessel operating expenses, management fees and voyage expenses are expensed as incurred. Unearned revenue represents cash received prior to year-end related to revenue applicable to
periods after December 31 of each year and also amounts resulting from straight-line revenue recognition of charter agreements that provide for varying charter rates broken down into current and non-current portions according to their
expected realization.
|
|
When vessels are acquired with time charters attached and the rates on such charters are below or above market on the acquisition date, the Company allocates the total cost
between the vessel and the fair value of the attached time charter based on the relative fair values of the vessel and time charter acquired. The fair value of the attached time charter is computed as the present value of the difference
between the contractual amount to be received over the term of the time charter and management’s estimates of the market time charter rate at the time of acquisition. The fair value of below or above market time charter is recognized as a
liability or an intangible asset respectively and is amortized over the remaining period of the time charter as an increase or decrease to revenues.
|
|
Where the time charter contains a profit or loss sharing arrangement, the profit or loss is recognized based on amounts earned or incurred as of the reporting date.
|
|
The Company pays commissions to ship brokers and to the Company’s fleet manager (Note 5), a related party affiliated with the family of Mr. Evangelos J. Pistiolis, associated
with arranging the Company’s charters. These brokers’ commissions are recognized over the related charter period and are included in voyage expenses.
|
| (p) |
Earnings / (Loss) per Share: Basic earnings/(loss) per share are computed by dividing net income or loss available to common stockholders by the weighted average number of common shares outstanding during the
year. Diluted earnings per share reflect the potential dilution that could occur if securities or other contracts to issue common stock were exercised. For purposes of calculating diluted earnings per share the denominator of the
diluted earnings per share calculation includes the incremental shares assumed issued under the treasury stock method weighted for the period the non-vested shares were outstanding. The computation of diluted earnings per share also
reflects the potential dilution that could occur if warrants to issue common stock were exercised, to the extent that they are dilutive, using the treasury stock method, the potential dilution that could occur if convertible preferred
stock were converted, using the if-converted method as well as the potential dilution that could occur if the Company completed all sales pursuant to common stock purchase agreements, using the if-converted method. Finally net income
or loss available to common stockholders, when computing basic earnings/(loss) per share, is reduced to reflect any dividends or deemed dividends on preferred stock.
|
| (q) |
Financial liabilities: Financial liabilities are classified as either
financial liabilities at ‘fair value through the profit and loss’ (“FVTPL”) or ‘other financial liabilities’. Financial instruments classified as FVTPL are recognized at fair value in the balance sheet when the Company has an obligation
to perform under the contractual provisions of those instruments. Financial instruments are classified as liabilities or equity in accordance with the substance of the contractual arrangement. Changes in the fair value of financial
instruments are recognized in earnings, except in the cases where these financial instruments fall under the guidance in ASC 815-40, where they are initially classified in equity and are initially measured at fair value in permanent
equity and subsequent changes in fair value are not subsequently measured. Other financial liabilities (including borrowings and trade and other payables) are subsequently measured at amortized cost using the effective interest rate
method.
|
| (r) |
Segment Reporting: The Chief Operating Decision Maker (“CODM”), Mr. Evangelos J. Pistiolis, receives financial
information and evaluates the Company’s operations by charter revenues and not by the length, type of vessel or type of ship employment for its customers or by geographical region as the charterer is free to trade the vessel worldwide
and as a result, the disclosure of geographic information is impracticable. The CODM assesses performance for the vessel operations segment and decides how to allocate resources based on consolidated net income thus the Company has
determined that it operates under
|
| (s) |
Leases:
|
|
•
|
Sale-leaseback transactions: In accordance with ASC 842, the Company, as seller-lessee, determines whether the
transfer of an asset should be accounted for as a sale in accordance with ASC 606 (existence of a contract and satisfaction of performance obligation by transferring of the control of the asset). The existence of an option for the
seller-lessee to repurchase the asset precludes the accounting for the transfer of the asset as a sale unless both of the following criteria are met: (1) the exercise price of the option is the fair value of the asset at the time the
option is exercised; and (2) there are alternative assets, substantially the same as the transferred asset, readily available in the marketplace. If the transfer of the asset meets the criteria of sale, the Company, as seller-lessee
recognizes the transaction price for the sale when the buyer-lessor obtains control of the asset, derecognizes the carrying amount of the underlying asset and accounts for the lease in accordance with ASC 842. If the transfer does not
meet the criteria of sale, the Company does not derecognize the transferred asset, accounts for any amounts received as a financing arrangement and recognizes the difference between the amount of consideration received and the amount of
consideration to be paid as interest.
|
|
•
|
Finance lease: The Company classifies a lease as a finance lease when the lease meets any of the following
criteria at lease commencement:
|
|
|
i.
|
The lease transfers ownership of the underlying asset to the lessee by the end of the lease term.
|
|
|
ii.
|
The lease grants the lessee an option to purchase the underlying asset that the lessee is reasonably certain to exercise.
|
|
|
iii.
|
The lease term is for the major part of the remaining economic life of the underlying asset. However, if the commencement date falls
at or near the end of the economic life of the underlying asset, this criterion shall not be used for purposes of classifying the lease.
|
|
|
iv.
|
The present value of the sum of the lease payments and any residual value guaranteed by the lessee that is not
already reflected in the lease payments equals or exceeds substantially all of the fair value of the underlying asset.
|
|
|
v.
|
The underlying asset is of such a specialized nature that it is expected to have no alternative use to the lessor at the end of the
lease term.
|
|
•
|
Operating lease- The Company as a lessee: The Company recognizes right-of-use assets (“ROU”) and corresponding lease liabilities for its operating leases. ROU assets and liabilities are recognized at the commencement date of an arrangement based on the present value of lease payments over the lease term. The operating lease ROU asset also includes any lease payments made to the lessor prior to lease commencement, less any lease incentives, and initial direct costs incurred. Lease expense for operating lease payments is recognized on a straight-line basis over the lease term. |
| (t) |
Investments in unconsolidated joint ventures: The Company’s investments in unconsolidated joint ventures are
accounted for using the equity method of accounting. Under the equity method of accounting, investments are stated at initial cost and are adjusted for subsequent additional investments and the Company’s proportionate share of earnings or
losses and distributions. The Company evaluates its investments in unconsolidated joint ventures for impairment when events or circumstances indicate that the carrying value of such investments may have experienced other than a temporary
decline in value below their carrying value. If the estimated fair value is less than the carrying value and it is considered other than a temporary decline, the carrying value is written down to its estimated fair value and the resulting
impairment is recorded in the consolidated statements of comprehensive income.
|
| (u) |
Other Comprehensive Income: The Company follows the provisions of guidance regarding reporting comprehensive income
which requires separate presentation of certain transactions, such as unrealized gains and losses from effective portion of cash flow hedges, which are recorded directly as components of stockholders’ equity.
|
| (v) |
Impairment of Right of use assets from operating leases: The Company evaluates its Right of use assets from
operating leases for potential impairment when it determines a triggering event has occurred. When a triggering event has occurred, the Company performs a test of recoverability by comparing the expected undiscounted future cash flows
(including expected residual values) over the remaining lease terms to the carrying value of the Right of use asset. If the test of recoverability identifies a possible impairment, the Right of use asset’s fair value is measured in
accordance with the fair value measurement framework. An impairment charge is recognized for the amount by which the carrying value of the Right of use asset exceeds its estimated fair value and would be recorded in the consolidated
statements of comprehensive income. For the years ended December 31, 2023, and 2024 there was
|
| (w) |
Liability for European Union Allowances (“EUAs”): The maritime emissions trading scheme (“ETS”), applicable from
January 1, 2024, applies to all the shipowning companies of the Company and refers to emissions generated by intra-EU maritime voyages and emissions from voyages which start or end at EU ports (but the other destination is outside the
EU). Since the liability derives from the choice of voyages which are directed, controlled and the benefit of which is attributed to our time charterers, the latter are responsible and liable for securing the EUAs to settle the
environmental credit obligations derived from voyages they performed. However, should they fail to do so, the ultimate liability lies with the shipowning companies. As such the liability to purchase EUAs for voyages subject to ETS
performed by our vessels is presented by the Company under Accounts payable and the EUAs that are receivable by the Company from our time charterers are presented under Trade accounts receivable in the accompanying consolidated balance
sheets. Any EUAs that have been paid into the EUA trading account of Central Mare Inc by our Charterers are presented under Due from/to related parties (Note 5). Since the EU has set the first settlement of EUAs for the 2024 voyages
subject to ETS on September 30, 2025, such receivables and liabilities have been presented as current. The receivable and payable EUAs as well as the EUAs paid by our time charterers to our Fleet Manager are considered a Level 1 item in
the fair value hierarchy (since the EUAs are quoted in an active market) and all such receivable and payable balances are presented at their fair value as at the reporting date.
|
| (x) |
Recent Accounting Pronouncements: In November 2023, the Financial Accounting Standards Board (“FASB”) issued
Accounting Standard Update (“ASU”) 2023-07, which requires the disclosure of significant segment expenses that are part of an entity’s segment measure of profit or loss and regularly provided to the chief operating decision maker. In addition, it adds or makes clarifications to other segment-related disclosures, such as clarifying that the disclosure requirements in
ASC 280 are required for entities with a single reportable segment and that an entity may disclose multiple measures of segment profit and loss. ASU 2023-07 is effective for fiscal years beginning after December 15, 2023 and
interim periods beginning after December 15, 2024. Early adoption is permitted. The amendments should be adopted retrospectively. The Company adopted ASU 2023-07 as of January 1, 2024 and its adoption did not have an impact on the
Company’s financial statements or disclosures.
In November 2024, the FASB issued ASU No. 2024-03, “Income Statement—Reporting Comprehensive
Income—Expense Disaggregation Disclosures (Subtopic 220-40)”. The amendments in this Update require disclosure, in the notes to financial statements, of specified information about certain costs and expenses. The amendments in this update
are effective for annual reporting periods beginning after December 15, 2026, and interim reporting periods within annual reporting periods December 15, 2027. Early adoption is permitted. The amendments in ASU 2024-03 should be applied
either (1) prospectively to financial statements issued for reporting periods after the effective date of this update or (2) retrospectively to any or all prior periods presented in the financial statements. The Company evaluated the
impact of this ASU on its financial statements and determined that there is no effect on its consolidated results of operations.
|
|
There are no other recent accounting pronouncements the adoption of which is expected to have a material effect on the
Company’s consolidated financial statements in the current or any future periods.
|
|
3. |
Going Concern: |
At December 31, 2024, the Company had a working
capital deficit of $
|
4. |
Vessels, net: |
The amounts in the consolidated balance sheets are analyzed as follows:
|
Vessel Cost
|
Accumulated Depreciation |
Net Book Value |
||||||||||
|
Balance, December 31, 2022 |
( |
) | ||||||||||
|
— Depreciation |
- | ( |
) | ( |
) | |||||||
|
Balance, December 31, 2023 |
( |
) | ||||||||||
|
— Depreciation |
- | ( |
) | ( |
) | |||||||
|
Balance, December 31, 2024 |
( |
) | ||||||||||
As of December 31, 2024 all the titles of ownership of our vessels are held by the respecting vessel lenders to secure the relevant sale and lease back financing transactions (see Note 7).
|
5. |
Transactions with Related Parties: |
The
fees charged by and expenses relating to Central Mare for the years ended December 31, 2022, 2023 and 2024 are as follows:
|
Year Ended December 31, |
|||||||||||||
|
2022 |
|
2023 |
|
2024 |
Presented in: |
||||||||
|
Executive officers and other personnel expenses |
General and administrative expenses – Consolidated statements of comprehensive income |
||||||||||||
|
Amortization of awarded shares* |
( |
) |
Management fees – related parties – Consolidated statements of comprehensive income |
||||||||||
|
Total |
|||||||||||||
|
*
|
|
(b) Central
Shipping Inc (“CSI”) – Letter Agreement and Management Agreements: On January 1, 2019, the Company entered into a letter agreement with CSI (“CSI Letter Agreement”), a related party affiliated with the family of
Evangelos J. Pistiolis and between January 1, 2019 and September 8, 2021 the Company entered into management agreements, or Management Agreements, between CSI and the Company’s vessel-owning subsidiaries. The CSI Letter Agreement can only be
terminated subject to an
Pursuant to the CSI Letter Agreement, as well
as the Management Agreements concluded between CSI and the Company’s vessel-owning subsidiaries, the Company pays a management fee of $
CSI provides, at cost, all accounting,
reporting and administrative services. Finally, the CSI Letter Agreement provides for a performance incentive fee for the provision of management services to be determined at the discretion of the Company’s Board of Directors. The management
agreements have an initial term of
As of December 31, 2023 and 2024, the amounts
due from CSI were $
The fees charged by and expenses relating to CSI for the years ended December 31, 2022, 2023 and 2024 are as follows:
|
Year Ended December 31,
|
|||||||||||||
|
2022 |
2023 |
2024 |
Presented in: |
||||||||||
|
Management fees |
Capitalized in Vessels, net – Balance sheet |
||||||||||||
|
Management fees – related parties – Consolidated statements of comprehensive income |
|||||||||||||
|
Supervision services fees |
Capitalized in Vessels, net – Balance sheet |
||||||||||||
|
Superintendent fees |
Vessel operating expenses – Consolidated statements of comprehensive income |
||||||||||||
|
Capitalized in Vessels, net – Balance sheet |
|||||||||||||
|
Dry-docking costs - Consolidated
statements of comprehensive income
|
|||||||||||||
|
Accounting and reporting cost |
Management fees – related parties – Consolidated statements of comprehensive income |
||||||||||||
|
Commission for sale and purchase of vessels |
Gain from vessel sales – Consolidated statements of comprehensive income |
||||||||||||
|
Newbuilding vessels monitoring fee |
Capitalized in Vessels, net – Balance sheet |
||||||||||||
|
Financing fees |
Net in Current and Non-current portions of long-term debt – Balance sheet |
||||||||||||
|
Commission on charter hire revenue |
Voyage expenses - Consolidated statements of comprehensive income |
||||||||||||
|
Total |
|||||||||||||
(c) Issuance and conversion of Series E Shares: On March 29, 2019 the Company entered into a stock purchase agreement with Family Trading Inc (“Family Trading”), a related party
owned by the Lax Trust, an irrevocable trust established for the benefit of certain family members of Mr. Evangelos J. Pistiolis, pursuant to which the Company exchanged the outstanding principal, fees and interest of the Further Amended Family
Trading Credit Facility with
(d) Charter
Party with Central Tankers Chartering Inc (“CTC”): On January 6, 2021 the Company acquired a shipowning company from an entity affiliated with Mr. Evangelos J. Pistiolis that owned M/T Eco Oceano CA which was
party to a time charter, with CTC, for a firm duration of
(e)
Personal Guarantees by Mr. Evangelos J. Pistiolis and Related Amendments to the Series D Preferred Shares: As a prerequisite for the Navigare Lease (defined below, see Note 6), Mr. Evangelos J. Pistiolis personally guaranteed the
performance of the bareboat charters connected to the lease and in exchange, the Company agreed to indemnify him for any losses suffered as a result of the guarantee provided, and the Company amended the Certificate of Designations governing the
terms of the Series D Preferred Shares (see Note 9), to adjust the voting rights per share of Series D Preferred Shares such that during the term of the Navigare Lease, the combined voting power controlled by Mr. Evangelos J. Pistiolis and the Lax
Trust does not fall below a majority of the Company’s total voting power, irrespective of any new common or preferred stock issuances, and thereby complying with a relevant covenant of the bareboat charters entered in connection with the Navigare
Lease. This personal guarantee comes into effect in the case
(f) Issuance of Series F Shares: On January 17, 2022, the Company entered into a stock purchase agreement with Africanus Inc., an affiliate of Evangelos J. Pistiolis for the sale of up to
(g) Short-term loan from Central Mare (“Central Mare Bridge Loan”): On January 5, 2022 the Company entered into an unsecured credit facility for up to $
(h) Executive bonus: On
December 10, 2023 and on October 9,
2024 the Company’s compensation committee comprising of independent directors suggested and the board of directors granted to Mr. Evangelos J. Pistiolis a bonus of $
(i) Advances for Asset Acquisition to Related Party: On June 14, 2024 the Company entered into a non-binding letter of intent (“No-Shop LOI”) with Mr. Evangelos J. Pistiolis whereby the latter was precluded from marketing or selling the mega yacht M/Y Para Bellvm (
(j) Personal Guarantee for HSBC loan: On January 15, 2024 the Company entered into a bridge loan with HSBC Private Bank (Suisse) SA (“HSBC”) (Note 7). As a prerequisite for granting the loan to the Company, HSBC requested a personal guarantee from Mr.
Evangelos J. Pistiolis, which he provided in exchange for an arrangement fee of
|
6. |
Leases |
A. Lease arrangements, under which the Company acts as the lessee
Bareboat Chartered-in Vessels:
The Company has treated the Navigare lease as an operating lease. An
operating lease ROU asset amounting to $
The Company’s future minimum operating lease payments required to be made after December 31, 2024, relating to the bareboat chartered-in vessels M/T Eco Beverly Hills and M/T Eco Bel Air are as follows:
|
Year ending December 31, |
Bareboat charter lease payments |
|||
|
2025 |
||||
|
Total |
||||
|
Less imputed interest |
( |
) | ||
|
Total Lease Liability |
||||
|
Presented as follows: |
||||
|
Short-term lease liability |
||||
The average remaining lease term on our bareboat chartered-in contracts
is
B. Lease arrangements, under which the Company acts as the lessor
Charter agreements:
During the year ended December 31, 2024, the Company operated
Future minimum time-charter receipts of the Company’s vessels in operation as of December
31, 2024, based on commitments relating to non-cancellable time charter contracts as of December 31, 2024, are as follows :
|
Year ending December 31, |
Time Charter receipts |
|||
|
2025 |
||||
|
2026 |
||||
|
2027 |
||||
| 2028 |
||||
|
2029 and thereafter
|
||||
|
Total |
||||
|
7. |
Debt: |
The amounts in the consolidated balance sheets are analyzed as follows (facility names defined below):
|
Financier / Vessel(s) |
December 31, |
|||||||
|
2023 |
2024 |
|||||||
|
Total long-term debt: |
||||||||
|
Cargill Facility
( |
||||||||
|
1st CMBFL Facility (
|
||||||||
|
1st AVIC Facility
(
|
||||||||
|
2nd AVIC Facility (
|
||||||||
|
Huarong Facility (
|
||||||||
|
2nd CMBFL Facility (
|
||||||||
|
Total long-term debt |
||||||||
|
Less: Deferred finance fees |
( |
) |
( |
) |
||||
|
Less: Debt discount relating to Vessel
fair value participation liability
|
( |
) |
||||||
|
Total long-term debt net of deferred finance fees and debt discounts |
||||||||
|
Presented: |
||||||||
|
Current portion of long-term debt |
||||||||
|
Long-term debt |
||||||||
ABN Facility
On March 18,
2021, the Company entered into a credit facility with ABN Amro for $
The facility
contained various covenants, including (i) an asset cover ratio of
The facility was secured as follows:
|
|
•
|
First priority mortgage over M/T Eco West Coast; |
|
|
•
|
Assignment of insurance and earnings of the mortgaged vessel; |
|
|
•
|
Specific assignment of any time charters with duration of more than |
|
|
•
|
Corporate guarantee of the Company; |
|
|
•
|
Pledge of the shares of the shipowning subsidiary; |
|
|
•
|
Pledge over the earnings account of the vessel. |
The facility
bore interest at LIBOR plus a margin of
Alpha Bank Facility
On May 6,
2021, the Company entered into a credit facility with Alpha Bank for $
The facility
contained various covenants, including (i) an asset cover ratio of
The facility was secured as follows:
|
|
•
|
First priority mortgage over M/T Eco Malibu; |
|
|
•
|
Assignment of insurance and earnings of the mortgaged vessel; |
|
|
•
|
Specific assignment of any time charters with duration of more than |
|
|
•
|
Corporate guarantee of the Company; |
|
|
•
|
Pledge of the shares of the shipowning subsidiary; |
|
|
•
|
Pledge over the earnings account of the vessel. |
The facility
bore interest at LIBOR plus a margin of
FINANCINGS COMMITTED UNDER SALE AND LEASEBACK AGREEMENTS
The majority
of the below sale and leaseback agreements (“SLB”s) contain, customary covenants and event of default clauses, including cross-default provisions and restrictive covenants and performance requirements including (i) a ratio of total net debt to the
aggregate market value of the Company’s fleet, current or future, of no more than
Additionally, all the SLBs contain restrictions on the relative shipowning company incurring further indebtedness or guarantees and paying dividends when in default or if such dividend payment would result in an event of default or termination event under the SLB agreements. The same dividend restrictions apply to the Company as well. All the SLBs have change of control provisions whereby there may not be a change of control of the Company, save with the prior written consent of the financier.
Finally both CMBFL SLBs have an asset cover ratio covenant of
All the below SLBs are secured mainly by the following:
|
|
• |
Ownership of the vessel financed; |
|
|
• |
Cross-default covenants, in the case where |
|
|
• |
Assignment of insurances and earnings of the vessel financed; |
|
|
• |
Specific assignment of any time charters of the vessel financed with duration of more than |
|
|
• |
Corporate guarantee of Top Ships Inc.; |
|
|
• |
Pledge of the shares of the relative shipowning subsidiary; |
|
|
• |
Pledge over the earnings account of the vessel financed. |
On June 29,
2018 the Company entered into an SLB and a
The facility
also contained a fair value appreciation sharing provision, whereby the Company had to share with Cargill
The SLB with Cargill was accounted for as a financing transaction, as control remained with the Company and as such the M/T Eco Marina Del Rey was recorded as an asset on the Company’s balance sheet. In addition, the Company had an obligation to repurchase the vessel.
1st CMBFL Facility
On November
23, 2021 the Company entered into an SLB with CMBFL, for its newbuilding vessels M/T Julius Caesar and M/T Legio X Equestris (the “Old CMBFL Facility”). Consummation of the SLB took place on January 17 and March 2 2022, respectively. Following the
sale, the Company has bareboat chartered back the vessels for a period of
As part of
this transaction, the Company had continuous options to buy back the vessels at purchase prices stipulated in the bareboat agreements depending on when the option would be exercised and at the end of the
On January
16 and January 23, 2024, the Company exercised its purchase options under the Old CMBFL Facility and took full ownership of M/Ts Julius Caesar and Legio X Equestris for $
The
consideration from the 1st CMBFL Facility amounted to $
The 1st
CMBFL Facility was accounted for as a financing transaction, as control will remain with the Company and the
Scheduled Principal Repayments: The Company’s annual principal payments required to be made after December 31, 2024 on its debt obligations, are as follows:
|
Years |
||||
|
December 31, 2025 |
||||
|
December 31, 2026 |
||||
|
December 31, 2027 |
||||
|
December 31, 2028 |
||||
|
December 31, 2029 and thereafter |
||||
|
Total |
||||
As
of December 31, 2023 and 2024, the Company was in compliance with all debt covenants with respect to its credit facilities. The fair value of debt outstanding on December 31, 2024, after excluding unamortized financing fees, amounted to $
Financing Costs: The net additions in deferred financing costs amounted to $
|
8.
|
Commitments and Contingencies:
|
Various claims, suits, and complaints, including those involving government regulations and product liability, arise in the ordinary course of the shipping business. As part of the normal course of operations, the Company’s customers may disagree on amounts due to the Company under the provision of the contracts which are normally settled through negotiations with the customer. Disputed amounts are normally reflected in revenues at such time as the Company reaches agreement with the customer on the amounts due.
Other than the cases mentioned above, the Company is not a party to any material litigation where claims or counterclaims have been filed against the Company other than routine legal proceedings incidental to its business.
On December 10, 2020, the Company entered into a corporate guarantee agreement with Alpha Bank of Greece (which was amended on February 2, 2022) in respect of the obligations of its
Environmental Liabilities:
The Company accrues for the cost of environmental liabilities when management becomes aware that a liability is probable and is able to reasonably estimate the probable exposure. Currently, management is not aware of any such claims or contingent liabilities, which should be disclosed, or for which a provision should be established in the consolidated financial statements.
|
9. |
Common and Preferred Stock, Additional Paid-In Capital and Dividends: |
Reverse stock split: On September 29, 2023 the Company effected a reverse stock split of its common stock. There was no change in the number of authorized common shares of the Company, or the floor price of the Company’s Series E Shares, or the number of votes of the Company’s Series D, E and F Shares. All numbers of common share and earnings per share amounts, as well as warrant shares eligible for purchase under the Company’s warrants, exercise price of said warrants and conversion prices of the Company’s Series E Shares, in these consolidated financial statements have been retroactively adjusted to reflect this reverse stock split.
Series D preferred
shares: On May 8, 2017, the Company issued
Equity distribution agreement: On April 15, 2022, the Company, entered into an equity distribution agreement, or as they are commonly known, at-the-market offering (“ATM”), with Maxim Group LLC
(“Maxim”). Under the ATM the Company could sell up to $
|
10. |
(Loss)/ Earnings Per Common Share: |
All shares issued are included in the Company’s common stock and have equal rights to vote and participate in dividends and in undistributed earnings.
The components of the calculation of basic and diluted (loss)/earnings per share for the years ended December 2022, 2023 and 2024 are as follows:
|
Year Ended December 31, |
||||||||||||
|
2022 |
2023 |
2024 |
||||||||||
|
Net Income |
||||||||||||
|
Less: Deemed dividend equivalents on preferred shares related to redemption value |
( |
) | ||||||||||
|
Less: Dividends of preferred shares |
( |
) | ( |
) | ||||||||
| Less: Deemed dividend on warrant inducement |
( |
) | ||||||||||
| Less: Deemed dividend on Series E Shares conversion | ( |
) | ||||||||||
|
(Loss)/Net Income attributable to common shareholders |
( |
) | ( |
) | ||||||||
|
(Loss)/Earnings per share: |
||||||||||||
|
Weighted average common shares outstanding, basic and dilutive |
||||||||||||
|
(Loss)/Earnings per share, basic and diluted |
( |
) | ( |
) | ||||||||
For the years ended December 31, 2022, 2023 and 2024,
|
11. |
Voyage and Vessel Operating Expenses: |
The amounts in the consolidated statements of comprehensive income are as follows:
|
Voyage Expenses |
Year Ended December 31, |
|||||||||||
|
2022 |
2023 |
2024 |
||||||||||
|
Bunkers |
||||||||||||
|
Commissions (including $ |
||||||||||||
|
Total |
||||||||||||
|
Vessel Operating Expenses |
Year Ended December 31, |
|||||||||||
|
2022 |
2023 |
2024 |
||||||||||
|
Crew wages and related costs |
||||||||||||
|
Insurance |
||||||||||||
|
Repairs and maintenance (including $ |
||||||||||||
|
Spares and consumable stores |
||||||||||||
|
Registration and taxes (Note 13) |
||||||||||||
|
Total |
||||||||||||
|
12. |
Interest and Finance Costs: |
The amounts in the consolidated statements of comprehensive income are analyzed as follows:
|
Interest and Finance Costs |
Year Ended December 31, |
|||||||||||
|
2022 |
2023 |
2024 |
||||||||||
|
Interest on debt (including $ |
||||||||||||
|
Bank charges |
||||||||||||
|
Amortization and write-off of financing fees |
||||||||||||
|
Amortization of debt
discount relating to Vessel fair value participation liability (Note 7)
|
||||||||||||
|
Total |
||||||||||||
|
Less interest capitalized |
( |
) | ||||||||||
|
Total |
||||||||||||
|
13. |
Income Taxes: |
Marshall Islands and Greece does not impose a tax on international shipping income. Under the laws of Marshall Islands and Greece, the countries of the companies’ incorporation and vessels’ registration, the companies are subject to registration and tonnage taxes, which have been included in Vessel operating expenses in the consolidated statements of comprehensive income.
Under the United States Internal Revenue Code of 1986, as amended (the “Code”), the U.S. source gross transportation income of a ship-owning or chartering corporation, such as the Company, is subject to a 4% U.S. Federal income tax without allowance for deduction, unless that corporation qualifies for exemption from tax under Section 883 of the Code and the Treasury Regulations promulgated thereunder. U.S. source gross transportation income consists of 50% of the gross shipping income that is attributable to transportation that begins or ends, but that does not both begin and end, in the United States.
Under Section 883 of the Code and the regulations thereunder, the Company will be exempt from U.S. federal income tax on our U.S.-source shipping income if:
(1) the Company is organized in a foreign country, or its country of organization, grants an “equivalent exemption” to corporations organized in the United States; and
(2) either
A. more than 50% of the value of the Company’s stock is owned, directly or indirectly, by individuals who are “residents” of the Company’s country of organization or of another foreign country that grants an “equivalent exemption” to corporations organized in the United States (each such individual a “qualified shareholder” and such individuals collectively, “qualified shareholders”), which the Company refers to as the “50% Ownership Test,” or
B. the Company’s stock is “primarily and regularly traded on an established securities market” in the Company’s country of organization, in another country that grants an “equivalent exemption” to U.S. corporations, or in the United States, which the Company refers to as the “Publicly-Traded Test.”
The Marshall Islands, the jurisdiction where the Company and the Company’s ship-owning subsidiaries are incorporated, grants an “equivalent exemption” to U.S. corporations. Therefore, the Company will be exempt from U.S. federal income tax with respect to the Company’s U.S.-source shipping income if either the 50% Ownership Test or the Publicly-Traded Test is met.
For purposes of the Publicly Traded Test Treasury Regulations provide, in pertinent part, that stock of a foreign corporation will be considered to be “primarily traded” on an established securities market if the number of shares of each class of stock that are traded during any taxable year on all established securities markets in that country exceeds the number of shares in each such class that are traded during that year on established securities markets in any other single country. The Company’s common shares, which is the Company’s sole class of issued and outstanding stock that is traded, is and the Company anticipates that its common shares will continue to be “primarily traded” on the NYSE American.
The Treasury Regulations also require for purposes of the Publicly Traded Test that the Company’s stock be “regularly traded” on an established securities market. Under the Treasury Regulations, the Company’s stock will be considered to be “regularly traded” if one or more classes of the Company’s stock representing more than 50% of the Company’s outstanding shares, by total combined voting power of all classes of stock entitled to vote and by total combined value of all classes of stock, are listed on one or more established securities markets, which the Company refers to as the “listing threshold.”
The Company took the position for U.S. federal income tax reporting purposes that it was not subject to U.S. federal income taxation for the 2022, 2023 taxable years since the company believes it qualifies for the exemption from tax under Section 883 and the Company intends to take the same position for the 2024 taxable year.
|
14. |
Financial Instruments: |
The principal financial assets of the Company consist of cash on hand and at banks, restricted cash, trade accounts receivables (including EUAs) and long-term deposits. The principal financial
liabilities of the Company consist of long-term loans (Note 7), accounts payable (including EUAs) due to suppliers, amounts due to related parties and accrued liabilities.
|
a) |
Interest rate risk: The Company as of December 31, 2024 is subject to market risks relating to changes in interest rates, since all of its debt except for the 1st CMBFL Facility is subject to floating interest rates. |
|
b) |
Credit risk: Financial instruments, which potentially subject the Company to significant concentrations of credit risk, consist principally of cash. The Company places its temporary cash investments, consisting mostly of deposits, with high credit qualified financial institutions. The Company performs periodic evaluations of the relative credit standing of those financial institutions with which it places its temporary cash investments. |
|
c) |
Fair value: |
The following methods and assumptions were used to estimate the fair value of each class of financial instrument:
Cash and cash equivalents and restricted cash are considered Level 1 items as they represent liquid assets with short term maturities. The Company considers its creditworthiness when determining the fair value of its liquid assets.
The Company follows the accounting guidance for Fair Value Measurements. This guidance enables the reader of the financial statements to assess the inputs used to develop those measurements by establishing a hierarchy for ranking the quality and reliability of the information used to determine fair values. The guidance requires assets and liabilities carried at fair value to be classified and disclosed in one of the following three categories:
Level 1: Quoted market prices in active markets for identical assets or liabilities;
Level 2: Observable market based inputs or unobservable inputs that are corroborated by market data;
Level 3: Unobservable inputs that are not corroborated by market data.
|
15. |
Mezzanine Equity |
Each holder
of Series E Shares, at any time, had the right, subject to certain conditions, to convert all or any portion of the Series E Shares then held by such holder into the Company’s common shares at the conversion rate then in effect. Each Series E Share
was convertible into the number of the Company’s common shares equal to the quotient of
The Series E
Shares were not subject to redemption in cash at the option of the holders thereof under any circumstance. Finally, the holders of outstanding Series E Shares were entitled to receive, semi-annual dividends payable in cash on the last day of June
and December of each year (each such date being referred to herein as a “Semi Annual Dividend Payment Date”), commencing on the first Semi Annual Dividend Payment Date, being June 30, 2019 in an amount per share (rounded to the nearest cent) equal
to
The Company determined that the Series E shares were more akin to equity than debt and that the above identified conversion feature, subject to adjustments, was clearly and closely related to the host instrument, and
accordingly bifurcation and classification of the conversion feature as a derivative liability was not required. Given that the Series D and Series E preferred stock’s holder (Lax Trust) controlled a majority of the Company votes, the preferred
equity was in essence redeemable at the option of the holder and hence was classified in Mezzanine equity as per ASC 480-10-S99 “Distinguishing liabilities from Equity – SEC Materials”.
On December
6, 2023 the Company received a conversion notice for the conversion of all the outstanding Series E Shares (
The
Company, based on ASC 470-20-40-5, determined that the Series E Shares conversion feature is in essence a redemption, since such conversion was settled by a delivery of a variable number of shares of common stock with a fixed monetary amount and by
applying ASC 260-10-S99-2 has recognized the difference between the carrying amount of the Series E Shares at the date of conversion and the fair value of the common stock delivered on the same date, amounting to $
SERIES F PREFERRED SHARES
On January 17, 2022, the Company entered
into a stock purchase agreement with Africanus Inc., an affiliate of Evangelos J. Pistiolis for the sale of up to
|
16. |
Investments in Unconsolidated Joint Ventures |
2020 Joint Venture
On April 24,
2020 the Company acquired from a company affiliated with Mr. Evangelos J. Pistiolis, or the MR Seller, a
Out of the
purchase price of $
On March 12,
2020, California 19 Inc. together with California 20 Inc. entered into a loan agreement with Alpha Bank for a senior debt facility of $
On
September 27, 2024 California 19 Inc. and California 20 Inc. refinanced the JV Alpha Facility with the same bank (Alpha Bank) and increased the loan to $
Each of the
The Company’s exposure is limited to its
share of the net assets of California 19 Inc. and California 20 Inc., proportionate to its
California 19 Inc. and California 20 Inc. made the following disbursements to the Company in 2022, 2023 and 2024:
|
December 31, 2022 |
December 31, 2023 |
December 31, 2024 |
||||||||||||||||||||||
|
California 19 Inc. |
California 20 Inc. |
California 19 Inc. |
California 20 Inc. |
California 19
Inc.
|
California
20 Inc.
|
|||||||||||||||||||
|
Total disbursements |
||||||||||||||||||||||||
Recognition of Equity gain/(loss) in unconsolidated joint ventures of the 2020 Joint Venture for the years ended December 31, 2022, 2023 and 2024 are summarized below:
|
December 31, 2022 |
December 31, 2023 |
December 31, 2024 | ||||||||||||||||||||||
|
California 19 Inc. |
California 20 Inc. |
California 19 Inc. |
California 20 Inc. |
California 19
Inc.
|
California 20
Inc.
|
|||||||||||||||||||
|
Net profit attributable to the Company |
||||||||||||||||||||||||
|
Amortization of Basis Differences |
( |
) | ( |
) | ( |
) | ( |
) | ( |
) | ( |
) | ||||||||||||
|
Equity gains in unconsolidated joint ventures |
( |
) | ( |
) | ||||||||||||||||||||
|
17. |
Revenues |
Revenues are comprised of the following:
|
2022 |
2023 |
2024 |
||||||||||
|
Time charter revenues |
||||||||||||
|
Time charter revenues from related party (Note 5) |
||||||||||||
|
Total |
||||||||||||
The Company
typically enters into time charters for periods ranging between to
|
18. |
Subsequent Events |
| • |
not be redeemable;
|
| • |
entitle holders to quarterly dividend payments in an amount per share equal to the aggregate per share amount of all cash dividends, and the aggregate per share amount (payable
in kind) of all non-cash dividends or other distributions other than a dividend payable in our common shares or a subdivision of our outstanding common shares (by reclassification or otherwise), declared on our common shares since the
immediately preceding quarterly dividend payment date; and
|
| • |
entitle holders to one vote on all matters submitted to a vote of our shareholders.
|
| • |
Flip In. If an Acquiring Person
obtains beneficial ownership of 15% or more of our common shares, then each Right will entitle the holder thereof to purchase, for the Exercise Price, a number of our common shares (or, in certain circumstances, cash, property or other
of our securities) having a then-current market value of twice the Exercise Price. However, the Rights are not exercisable following the occurrence of the foregoing event until such time as the Rights are no longer redeemable by us, as
further described below.
|
| • |
Flip Over. If, after an Acquiring
Person obtains 15% or more of our common shares, (i) we merge into another entity; (ii) an acquiring entity merges into us; or (iii) we sell or transfer 50% or more of its assets, cash flow or earning power, then each Right (except for
Rights that have previously been voided as set forth above) will entitle the holder thereof to purchase, for the Exercise Price, a number of our common shares of the person engaging in the transaction having a then-current market value
of twice the Exercise Price.
|
| • |
Notional Shares. Shares held by
affiliates and associates of an Acquiring Person, including certain entities in which the Acquiring Person beneficially owns a majority of the equity securities, and Notional Common Shares (as defined in the Rights Agreement) held by
counterparties to a Derivatives Contract (as defined in the Rights Agreement) with an Acquiring Person, will be deemed to be beneficially owned by the Acquiring Person.
|
| • |
prior to the date of the transaction that resulted in the shareholder becoming an interested shareholder, the Board approved either the business combination or the transaction
that resulted in the shareholder becoming an interested shareholder;
|
| • |
upon consummation of the transaction that resulted in the shareholder becoming an interested shareholder, the interested shareholder owned at least 85% of the voting stock of
the corporation outstanding at the time the transaction commenced;
|
| • |
at or subsequent to the date of the transaction that resulted in the shareholder becoming an interested shareholder, the business combination is approved by the Board and
authorized at an annual or special meeting of shareholders by the affirmative vote of at least 66 2/3% of the outstanding voting stock that is not owned by the interested shareholder; and
|
| • |
the shareholder became an interested shareholder prior to the consummation of the initial public offering.
|
|
Marshall Islands
|
Delaware
|
|
|
Shareholder Meetings
|
||
|
Held at a time and place as designated in the bylaws.
|
May be held at such time or place as designated in the certificate of incorporation or the bylaws, or if not so designated, as determined by the board of
directors.
|
|
|
Special meetings of the shareholders may be called by the board of directors or by such person or persons as may be authorized by the articles of
incorporation or by the bylaws.
|
Special meetings of the shareholders may be called by the board of directors or by such person or persons as may be authorized by the certificate of
incorporation or by the bylaws.
|
|
|
May be held within or outside of the Marshall Islands.
|
May be held within or outside of Delaware.
|
|
|
Notice:
|
Notice:
|
|
|
Whenever shareholders are required to take any action at a meeting, written notice of the meeting shall be given which shall state the place, date and hour
of the meeting and, unless it is an annual meeting, indicate that it is being issued by or at the direction of the person calling the meeting. Notice of a special meeting shall also state the purpose for which the meeting is called.
|
W Whenever shareholders are required to take any action at a meeting, a written notice of the meeting shall be given which shall state the place, if any,
date and hour of the meeting, and the means of remote communication, if any.
|
|
|
A copy of the notice of any meeting shall be given personally, sent by mail or by electronic mail not less than 15 nor more than 60 days before the
meeting.
|
Written notice shall be given not less than 10 nor more than 60 days before the meeting.
|
|
|
Shareholders’ Voting Rights
|
||
|
Unless otherwise provided in the articles of incorporation, any action required to be taken at a meeting of shareholders may be taken
without a meeting, without prior notice and without a vote, if a consent in writing, setting forth the action so taken, is signed by all the shareholders entitled to vote with respect to the subject matter thereof, or if the articles of
incorporation so provide, by the holders of outstanding shares having not less than the minimum number of votes that would be necessary to authorize or take such action at a meeting at which all shares entitled to vote thereon were present
and voted.
|
Any action required to be taken at a meeting of shareholders may be taken without a meeting if a consent for such action is in writing and is signed by
shareholders having not fewer than the minimum number of votes that would be necessary to authorize or take such action at a meeting at which all shares entitled to vote thereon were present and voted
.
|
|
|
Marshall Islands
|
Delaware
|
|
|
Any person authorized to vote may authorize another person or persons to act for him by proxy.
|
Any person authorized to vote may authorize another person or persons to act for him by proxy.
|
|
|
Unless otherwise provided in the articles of incorporation or bylaws, a majority of shares entitled to vote constitutes a quorum. In no event shall a
quorum consist of fewer than one-third of the shares entitled to vote at a meeting.
|
For stock corporations, the certificate of incorporation or bylaws may specify the number of shares required to constitute a quorum but in no event shall a
quorum consist of less than one-third of shares entitled to vote at a meeting. In the absence of such specifications, a majority of shares entitled to vote shall constitute a quorum.
|
|
|
When a quorum is once present to organize a meeting, it is not broken by the subsequent withdrawal of any shareholders.
|
When a quorum is once present to organize a meeting, it is not broken by the subsequent withdrawal of any shareholders.
|
|
|
The articles of incorporation may provide for cumulative voting in the election of directors.
|
The certificate of incorporation may provide for cumulative voting in the election of directors.
|
|
|
Merger or Consolidation
|
||
|
Any two or more domestic corporations may merge into a single corporation if approved by the board and if authorized by a majority vote of
the holders of outstanding shares at a shareholder meeting.
|
Any two or more corporations existing under the laws of the state may merge into a single corporation pursuant to a board resolution and
upon the majority vote by shareholders of each constituent corporation at an annual or special meeting.
|
|
| Any sale, lease, exchange or other disposition of all or substantially all the assets of a corporation, if not made in the corporation's usual or regular course of business, once approved by the board, shall be authorized by the affirmative vote of two-thirds of the shares of those entitled to vote at a shareholder meeting. | Every corporation may at any meeting of the board sell, lease or exchange all or substantially all of its property and assets as its board deems expedient and for the best interests of the corporation when so authorized by a resolution adopted by the holders of a majority of the outstanding stock of the corporation entitled to vote. | |
| Any domestic corporation owning at least 90% of the outstanding shares of each class of another domestic corporation may merge such other corporation into itself without the authorization of the shareholders of any corporation. | Any corporation owning at least 90% of the outstanding shares of each class of another corporation may merge the other corporation into itself and assume all of its obligations without the vote or consent of shareholders; however, in case the parent corporation is not the surviving corporation, the proposed merger shall be approved by a majority of the outstanding stock of the parent corporation entitled to vote at a duly called shareholder meeting. | |
| Any mortgage, pledge of or creation of a security interest in all or any part of the corporate property may be authorized without the vote or consent of the shareholders, unless otherwise provided for in the articles of incorporation. | Any mortgage or pledge of a corporation's property and assets may be authorized without the vote or consent of shareholders, except to the extent that the certificate of incorporation otherwise provides | |
|
Directors
|
||
|
The board of directors must consist of at least one member.
|
The board of directors must consist of at least one member.
|
|
|
The number of board members may be changed by an amendment to the bylaws, by the shareholders, or by action of the board under the specific provisions of a
bylaw.
|
The number of board members shall be fixed by, or in a manner provided by, the bylaws, unless the certificate of incorporation
fixes the number of directors, in which case a change in the number shall be made only by an amendment to the certificate of incorporation.
|
|
|
If the board is authorized to change the number of directors, it can only do so by a majority of the entire board and so long as
no decrease in the number shall shorten the term of any incumbent director.
|
If the number of directors is fixed by the certificate of incorporation, a change in the number shall be made only by an
amendment of the certificate.
|
|
|
Removal:
|
Removal:
|
|
|
Any or all of the directors may be removed for cause by vote of the shareholders.
|
Any or all of the directors may be removed, with or without cause, by the holders of a majority of the shares entitled to vote unless the certificate of
incorporation otherwise provides.
|
|
|
If the articles of incorporation or the bylaws so provide, any or all of
the directors may be removed without cause by vote of the shareholders..
|
In the case of a classified board, shareholders may effect
removal of any or all directors only for cause.
|
|
|
Dissenter’s Rights of Appraisal
|
||
|
Marshall Islands
|
Delaware
|
|
|
Shareholders have a right to dissent from any plan of merger, consolidation or sale of all or substantially all assets not made in the usual course of
business, and receive payment of the fair value of their shares. However, the right of a dissenting shareholder under the BCA to receive payment of the appraised fair value of his shares shall not be available for the shares of any class or
series of stock, which shares or depository receipts in respect thereof, at the record date fixed to determine the shareholders entitled to receive notice of and to vote at the meeting of the shareholders to act upon the agreement of merger
or consolidation, were either (i) listed on a securities exchange or admitted for trading on an interdealer quotation system or (ii) held of record by more than 2,000 holders. The right of a dissenting shareholder to receive payment of the
fair value of his or her shares shall not be available for any shares of stock of the constituent corporation surviving a merger if the merger did not require for its approval the vote of the shareholders of the surviving corporation.
|
Appraisal rights shall be available for the shares of any class or series of stock of a corporation in a merger or consolidation, subject to limited
exceptions, such as a merger or consolidation of corporations listed on a national securities exchange in which listed stock is offered for consideration is (i) listed on a national securities exchange or (ii) held of record by more than
2,000 holders.
|
|
|
A holder of any adversely affected shares who does not vote on or consent in writing to an amendment to the articles of incorporation has the right to
dissent and to receive payment for such shares if the amendment:
|
||
|
• alters or abolishes any preferential right of any outstanding shares having preference; or
|
||
|
• creates, alters or abolishes any provision or right in respect to the redemption of any outstanding shares; or
|
||
|
|
||
|
• alters or abolishes any preemptive right of such holder to acquire shares or other securities; or
|
||
|
|
||
|
• excludes or limits the right of such holder to vote on any matter, except as such right may be limited by the voting rights given to new shares then being authorized of any existing or new class.
|
||
|
Shareholders’ Derivative Actions
|
||
|
An action may be brought in the right of a corporation to procure a judgment in its favor, by a holder of shares or of voting trust certificates or of a
beneficial interest in such shares or certificates. It shall be made to appear that the plaintiff is such a holder at the time of bringing the action and that he was such a holder at the time of the transaction of which he complains, or
that his shares or his interest therein devolved upon him by operation of law.
|
In any derivative suit instituted by a shareholder of a corporation, it shall be averred in the complaint that the plaintiff was a
shareholder of the corporation at the time of the transaction of which he complains or that such shareholder's stock thereafter devolved upon such shareholder by operation of law.
|
|
|
A complaint shall set forth with particularity the efforts of the plaintiff to secure the initiation of such action by the board or the
reasons for not making such effort.
Such action shall not be discontinued, compromised or settled, without the approval of the High Court of the Republic of the Marshall
Islands
|
Other requirements regarding derivative suits have been created by judicial decision, including that a shareholder may not bring a derivative suit unless
he or she first demands that the corporation sue on its own behalf and that demand is refused (unless it is shown that such demand would have been futile).
|
|
|
Reasonable expenses including attorneys’ fees may be awarded if the action is successful.
|
||
|
A corporation may require a plaintiff bringing a derivative suit to give security for reasonable expenses if the plaintiff owns less than 5% of any class
of outstanding shares or holds voting trust certificates or a beneficial interest in shares representing less than 5% of any class of such shares and the shares, voting trust certificates or beneficial interest of such plaintiff has a fair
value of $50,000 or less.
|
||
![]() |
![]() |
|
1. Shipbroker
N/A
|
2. Place and date
11 January 2024
|
|
|
3. Owners/Place of business (Cl. 1)
SEA 179 LEASING CO. LIMITED, a company incorporated under
the laws of Hong Kong with company number 2878380 whose
registered office is at 46/F, Champion Tower, 3 Garden Road, Central, Hong Kong
|
4. Bareboat Charterers/Place of business (Cl. 1)
PCH DREAMING INC. a corporation incorporated under
the laws of the Republic of the Marshall Islands, having
its registered address at Trust Company Complex,
Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands
MH96960
|
|
|
5. Vessel’s name, call sign and flag (Cl. 1 and 3)
Eco Marina Del Rey
Call Sign: V7A 2018
Flag: Marshall Islands or any other flag state of the Vessel as may be agreed in writing by the Owners and the Charterers.
|
||
|
6. Type of Vessel
OIL/CHEMICAL TANKER
|
7. GT/NT
29,994 / 13,850
|
|
|
8. When/Where built
2019
Hyundai Mipo Dockyard Co., Ltd, Korea
|
9. Total DWT (abt.) in metric tons on summer freeboard
50,267
|
|
|
10. Classification Society (Cl. 3)
DNV or any other Approved Classification Society
|
11 . Date of last special survey by the Vessel’s classification society
N/A
|
|
|
12 Further particulars of Vessel (also indicate minimum number of months’ validity of class certificates agreed acc. to Cl. 3)
IMO No.: 9798349
Length: 176.20 metres
Breadth: 32.20 metres
Depth: 19.10 metres
|
||
|
13 . Port or Place of delivery (Cl. 3)
Back to back with MOA delivery
|
14. Time for delivery (Cl. 4)
See Clause 34 (Delivery
and Charter of Vessel)
|
15. Cancelling date (Cl. 5)
See definition of
"Cancelling Date" and
Clause 33
(Cancellation)
|
|
16. Port or Place of redelivery (Cl. 15)
See Clauses 41.6 (Termination, Redelivery and Total Loss)
|
17. No. of months' validity of trading and class certificates upon redelivery (Cl. 15)
Six (6) months
|
|
|
18. Running days’ notice if other than stated in Cl. 4
N/A
|
19. Frequency of dry-docking (Cl. 10(g))
In accordance with Approved Classification Society or requirements of Flag State
|
|
|
20. Trading limits (Cl. 6)
International Navigating Limits and excluding any war listed area declared by the Joint War Committee, see also Clause 46.1(t), 46.1(u) and 46.1(v) (Undertakings)
|
||
|
21. Charter period (Cl. 2)
See Clause 32 (Charter Period)
|
22. Charter hire (Cl. 11)
See Clause 36 (Charterhire and Advance Charterhire)
|
|
|
23. New class and other safety requirements (state percentage of Vessel's insurance value acc. to Box 29)(Cl. 10(a)(ii))
N/A
|
||
|
24. Rate of interest payable acc. to Cl. 11 (f) and, if applicable, acc. to PART IV
See Clause 37 (Changes to Interest Rate, Default Interest)
|
25. Currency and method of payment (Cl. 11)
Dollars/Bank transfer
|
|
|
26. Place of payment; also state beneficiary and bank account (Cl. 11)
See Clause 36 (Charterhire and Advance Charterhire); such account as the Owners may notify the Charterers from time to time
|
27. Bank guarantee/bond (sum and place) (Cl. 24) (optional)
See Clause 24
|
|
|
28. Mortgage(s), if any (state whether 12(a) or (b) applies; if 12(b) applies state date of Financial Instrument and name of Mortgagee(s)/Place of business) (Cl. 12)
N/A
|
29. Insurance (hull and machinery and war risks) (state value acc. to Cl. 13(f) or, if applicable, acc. to Cl. 14(k)) (also state if Cl. 14 applies)
See Clause 39 (Insurance) - Clause 14 does not apply
|
|
|
30. Additional insurance cover, if any, for Owners’ account limited to (Cl. 13(b) or, if applicable, Cl. 14(g))
See Clause 39 (Insurance)
|
31. Additional insurance cover, if any, for Charterers’ account limited to (Cl. 13(b) or, if applicable, Cl. 14(g))
See Clause 39 (Insurance)
|
|
32. Latent defects (only to be filled in if period other than stated in Cl. 3)
N/A
|
33. Brokerage commission and to whom payable (Cl. 27) N/A
|
|
34. Grace period (state number of clear banking days) (Cl. 28)
N/A
|
35. Dispute Resolution (state 30(a), 30(b) or 30(c); if 30(c) agreed Place of Arbitration must be stated (Cl. 30)
(c) Clause 30 not applicable. See Clause 65
(Governing Law and Enforcement)
|
|
36. War cancellation (indicate countries agreed) (Cl. 26(f))
N/A
|
|
|
37. Newbuilding Vessel (indicate with “yes” or “no” whether PART III applies) (optional)
No
|
38. Name and place of Builders (only to be filled in if PART III applies)
N/A
|
|
39. Vessel’s Yard Building No. (only to be filled in if PART III applies)
N/A
|
40. Date of Building Contract (only to be filled in if PART III applies)
N/A
|
|
41. Liquidated damages and costs shall accrue to (state party acc. to Cl. 1)
a) N/A
b) N/A
c) N/A
|
|
|
42. Hire/Purchase agreement (indicate with “yes” or “no” whether PART IV applies) (optional)
No, Part IV does not apply
|
43. Bareboat Charter Registry (indicate with “yes” or “no” whether PART V applies) (optional)
No
|
|
44. Flag and Country of the Bareboat Charter Registry (only to be filled in if PART V applies)
N/A
|
45. Country of the Underlying Registry (only to be filled in if PART V applies)
N/A
|
|
46. Number of additional clauses covering special provisions, if agreed
Clause 32 (Charter Period) to Clause 66 (Definitions)
|
|
|
Signature (Owners)
|
/s/ CUI Wanying
CUI Wanying
Attorney-in-Fact
|
Signature (Charterers)
|
/s/ Alexandros Tsirikos
Alexandros Tsirikos
Attorney-in-Fact
|
|
1 1. Definitions
|
|
2 In this Charter, the following terms shall have the
|
|
3 meanings hereby assigned to them:
|
|
4 “The Owners” shall mean the party identified in Box 3;
|
|
5 “The Charterers” shall mean the party identified in Box 4;
|
|
6 “The Vessel” shall mean the vessel named in Box 5 and
|
|
7 with particulars as stated in Boxes 6 to 12.
|
|
8 “Financial Instruments” has
the meaning ascribed to it
|
|
in Clause 66 (Definitions).
|
|
9
|
|
|
|
11 2 Charter Period
|
|
12 In consideration of the hire detailed in Box 22,
|
|
13 the Owners have agreed to let and the Charterers have
|
|
14 agreed to hire the Vessel for the period stated in Box 21
|
|
15
|
|
Period)
|
|
16 3. Delivery
|
|
17 (not applicable when Part III applies, as indicated in Box 37)
|
|
18 (a) The Owners shall before and at the time of delivery
|
|
|
|
|
|
|
|
22
|
|
shall be delivered by the Owners and taken
|
|
23 over by the Charterers at the port or place indicated in
|
|
24 Box 13. in such ready safe berth as the Charterers may
|
|
25
|
|
26
|
|
|
|
|
|
|
|
|
|
|
|
|
|
33 (c) The delivery of the Vessel by the Owners and the
|
|
34 taking over of the Vessel by the Charterers shall
|
|
35 constitute a full performance by the Owners of all the
|
|
36 Owners’ obligations under this Clause 3, and thereafter
|
|
37 the Charterers shall not be entitled to make or assert
|
|
38 any claim against the Owners on account of any
|
|
39 conditions, representations or warranties expressed or
|
|
40 implied with respect to the Vessel.
|
|
|
|
|
|
|
|
|
|
|
|
|
|
47 4. Time for Delivery (See Clause 34 (Delivery and
|
|
Charter of Vessel))
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
60 5. Cancelling (See Clause 33 (Cancellation))
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
86 6. Trading Restrictions (see also Clauses 46.1(t), 46.1(u)
|
| and 46.1(v)) (Undertakings) |
|
87 The Vessel shall be employed in lawful trades for the
|
|
88 carriage of suitable lawful merchandise within the trading
|
|
89 limits indicated in Box 20.
|
|
90 The Charterers undertake not to employ the Vessel or
|
|
91 suffer the Vessel to be employed otherwise than in
|
|
92 conformity with the terms of the contracts of insurance
|
|
93 (including any warranties expressed or implied therein)
|
|
94 without first obtaining the consent of the insurers to such
|
|
95 employment and complying with such requirements as
|
|
96 to extra premium or otherwise as the insurers may
|
|
97 prescribe.
|
|
98 The Charterers also undertake not to employ the Vessel
|
|
99 or suffer her employment in any trade or business which
|
|
100 is forbidden by the law of any country to which the Vessel
|
|
101 may sail or is otherwise illicit or in carrying illicit or
|
|
102 prohibited goods or in any manner whatsoever which
|
|
103 may render her liable to condemnation, destruction,
|
|
104 seizure or confiscation.
|
|
105 Notwithstanding any other provisions contained in this
|
|
106 Charter it is agreed that nuclear fuels or radioactive
|
|
107 products or waste are specifically excluded from the
|
|
108 cargo permitted to be loaded or carried under this
|
|
109 Charter. This exclusion does not apply to radio-isotopes
|
|
110 used or intended to be used for any industrial,
|
|
111 commercial, agricultural, medical or scientific purposes
|
|
112 provided the Owners’ prior approval has been obtained
|
|
113 to loading thereof.
|
|
114 7. Surveys on Delivery and Redelivery
|
|
115 Provision on Delivery see Clause 47.2 (Inspection of
|
| Vessel) |
|
|
|
116 The Owners
|
|
|
|
117 surveyors for the purpose of determining and agreeing
|
|
118 in writing the condition of the Vessel at the time of
|
|
119
|
|
(Termination, Redelivery and Total Loss)hereunder (if
|
|
applicable) at the costs of the Charterers.
|
|
|
|
|
|
|
|
|
|
|
|
124 8. Inspection (See Clause 47 (Inspection of Vessel))
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
152 9. Inventories, Oil and Stores (See Clause 34.7 (Delivery
|
|
and Charter of Vessel))
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
168 10. Maintenance and Operation
|
|
169 (a)(i)Maintenance and Repairs - During the Charter
|
|
170 Period the Vessel shall be in the full possession
|
|
171 and at the absolute disposal for all purposes of the
|
|
172 Charterers and under their complete control in
|
|
173 every respect. The Charterers shall maintain the
|
|
174 Vessel, her machinery, boilers, appurtenances and
|
|
175 spare parts in a good state of repair, in efficient
|
|
176 operating condition and in accordance with good
|
|
177 commercial maintenance practice and,
|
|
178
|
|
179 own expense they shall at all times keep the
|
|
180 Vessel’s Classification
|
| Classification |
|
181 Society indicated in Box 10 and maintain all other
|
|
182 necessary certificates in force at all times.
|
|
183 (ii) New Class and Other Safety Requirements - In the
|
|
184 event of any improvement, structural changes or
|
|
185 new equipment becoming necessary for the
|
|
186 continued operation of the Vessel by reason of new
|
|
187 class requirements or by compulsory legislation, the the
|
|
Charterers shall ensure that the same are complied
|
|
with and the time and costs of compliance shall be for
|
|
the Charterers' account.
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
201 (iii) Financial Security - The Charterers shall maintain
|
|
202 financial security or responsibility in respect of third
|
|
203 party liabilities as required by any government,
|
|
204 including federal, state or municipal or other division
|
|
205 or authority thereof, to enable the Vessel, without
|
|
206 penalty or charge, lawfully to enter, remain at, or
|
|
207 leave any port, place, territorial or contiguous
|
|
208 waters of any country, state or municipality in
|
|
209 performance of this Charter without any delay. This
|
|
210 obligation shall apply whether or not such
|
|
211 requirements have been lawfully imposed by such
|
|
212 government or division or authority thereof.
|
|
213 The Charterers shall make and maintain all arrange-
|
|
214 ments by bond or otherwise as may be necessary to
|
|
215 satisfy such requirements at the Charterers’ sole
|
|
216 expense and the Charterers shall indemnify the Owners
|
|
217 against all consequences whatsoever (including loss of
|
|
218 time) for any failure or inability to do so.
|
|
219 (b) Operation of the Vessel - The Charterers shall at
|
|
220 their own expense and by their own procurement man,
|
|
221 victual, navigate, operate, supply, fuel and, whenever
|
|
222 required, repair the Vessel during the Charter Period
|
|
223 and they shall pay all charges and expenses of every
|
|
224 kind and nature whatsoever incidental to their use and
|
|
225 operation of the Vessel under this Charter, including
|
|
226 annual
|
|
general
|
|
227 municipality and/or state taxes. The Master, officers
|
|
228 and crew of the Vessel shall be the servants of the Charterers
|
|
229 for all purposes whatsoever, even if for any reason
|
|
230 appointed by the Owners.
|
|
231 Charterers shall comply with the regulations regarding
|
|
|
|
232 officers and crew in force in the country of the Vessel’s
|
|
233 flag or any other applicable law.
234 (c) The Charterers shall keep the Owners
235
236 planned dry-docking and major repairs of the Vessel,
237 as reasonably required.
238 (d) Flag and Name of Vessel – During the Charter
239 Period, the Charterers shall have the liberty to paint the
240 Vessel in their own colours, install and display their
241 funnel insignia and fly their own house flag (with all fees,
costs and expenses arising in relation thereto for the
Charterers' account). The
242 Charterers shall also have the liberty, with the Owners’
243 consent,
244 change the flag and/or the name of the Vessel during
245 the Charter Period (with all fees, costs and expenses
arising in relation thereto for the Charterers'
account). Painting and re-painting, instalment
246 and re-instalment, registration and re-registration, if
247 required by the Owners, shall be at the Charterers’
248 expense and time.
249 (e) Changes to the Vessel –
Clause 10(a)(ii),
250 the Charterers shall make no structural changes in the
251 Vessel or changes in the machinery, boilers, appurten-
252 ances or spare parts thereof without in each instance
253 first securing the Owners’ approval thereof. If the Owners
254 so agree, the Charterers shall, if the Owners so require,
255 restore the Vessel to its former condition
257 (f) Use of the Vessel’s Outfit, Equipment and
258 Appliances - The Charterers shall have the use of all
259 outfit, equipment, and appliances on board the Vessel
260 at the time of delivery, provided the same or their
261 substantial equivalent shall be returned to the Owners
262 on redelivery in the same good order and condition as
263 when received, ordinary wear and tear excepted. The
264 Charterers shall from time to time during the Charter
265 Period replace, renew or substitute such items of
equipment as shall be so
266 damaged or worn as to be unfit for use. The Charterers
267 are to procure that all repairs to or replacement of any
268 damaged, worn or lost parts or equipment be effected
269 in such manner (both as regards workmanship and
270 quality of materials) as not to diminish the value of the
271 Vessel. Title of any equipment so replaced, renewed
or substituted shall vest in and remain with the
Owners. The Charterers have the right to fit additional
272 equipment at their expense and risk (provided that no
permanent structural damage is caused to the Vessel
by reason of such installation) and
273 shall, at their expenses, remove such equipment and
make good any damage caused by the fitting or
removal of such additional equipment before the
Vessel is redelivered to the Owners.
274
275 equipment on hire on the Vessel at time of delivery shall
276 be kept and maintained by the Charterers and the
277 Charterers shall assume the obligations and liabilities
278 of the Owners under any lease contracts in connection
279 therewith and shall reimburse the Owners for all
|
|
280 expenses incurred in connection therewith, also for any
281 new equipment required in order to comply with radio
282 regulations.
283 (g) Periodical Dry-Docking - The Charterers shall dry-
284 dock the Vessel and clean and paint her underwater
285 parts whenever the same may be necessary, but not
286 less than once during the period stated in Box 19.
287
288
289
290 11. Hire (See Clause 36 (Charterhire and Advance
Charterhire))
328 12. Mortgage (See Clause 63.3 (Assignment and
Transfer))
|
|
|
|
357 13. Insurance and Repairs (See also Clause 39
(Insurance))
358 (a) Subject
to Clause 39 (Insurance), d
Charter Period the Vessel shall be kept
359 insured in accordance with Clause 39 (Insurance) by
the Charterers at their expense against hull
360 and machinery, marine and (including blocking and
trapping) war and Protection and Indemnity risks and
freight, demurrage and defence risks
361 (and any risks against which it is compulsory to insure
362 for the operation of the Vessel, including but not limited
to maintaining
363 financial security in accordance with sub-clause
364 10(a)(iii)) in such form as the Owners shall in writing
365 approve. During the Charter Period the Charterers
shall procure (at Charteres' expense) that there are in
place innocent Owners' interest insurance, lessor's
additional perils (pollution) insurance and if
applicable, Mortgagees' interest insurance and
Mortgagees' additional perils (pollution) insurance for
an amount equal to at least one hundred and twenty
percent. (120%) of the then Owners' cost and shall
procure (at Charterers' expense),
366
367 Charterers to protect the interests of both the Owners
368 and the Charterers and the Owners' Financiers
369 The Charterers shall be at liberty to protect under such
370 insurances the interests of any managers they may
371 appoint provided such
manager has entered into a
manager's undertaking in form and substance
acceptable to the Owners and the Owners' Financiers
(if any). Insurance policies shall cover the Owners, the
mortgagee(s) (if any)
372 the Charterers according to their respective interests.
373 Subject to the provisions of the agreed loss payable
clauses,
374
375 the Charterers shall effect all insured repairs and shall
376 undertake settlement and reimbursement from the
377 insurers of all costs in connection with such repairs as
378 well as insured charges, expenses and liabilities to the
|
|
379 extent of coverage under the insurances herein provided
380 for.
381 The Charterers also to remain responsible for and to
382 effect repairs and settlement of costs and expenses
383 incurred thereby in respect of all other repairs not
384 covered by the insurances and/or not exceeding any
385 possible franchise(s) or deductibles provided for in the
386 insurances.
387 All time used for repairs under the provisions of sub-
388 clause 13(a)
389
390 for the Charterers’ account.
391 (b)
395
396 furnish the
additional
397 insurance effected, including copies of any cover notes
398 or policies and the written consent of the insurers of
399 any such required insurance in any case where the
400 consent of such insurers is necessary. The Charterers
hereby undertake that any additional insurances that
they arrange now or in the future will always be
compliant with the terms of the underlying hull and
machinery policies.
401 (c) The Charterers shall upon the request of the
402 Owners, provide information and promptly execute such
403 documents as may be required to enable the Owners to
404 comply with the insurance provisions of the Financial
405 Instrument (if any).
406 (d) Subject to the provisions of the Financial Instru-
407 ments and Clause 41.13 (Termination, Redelivery and
Total Loss)
Loss,
408
410 insurance payments for such loss shall be paid to the
411 Owners (or, if applicable, the Owners' Financiers
accordance with the
payable clauses).
and the Owners' Financiers,
414
415 consequence of which the Vessel is likely to become a
416
421 (f) For the purpose of insurance coverage against hull
422 and machinery and war risks under the provisions of
423 sub-clause 13(a), the value of the Vessel is the sum
424 indicated in Clause 39 (Insurance).
425 14. Insurance, Repairs and Classification
|
|
|
|
|
|
|
514 15. Redelivery (See Clause 41.6 (Termination,
Redelivery and Total Loss))
546 16. Non-Lien
547 Save for Permitted Security Interest (if any), The
Charterers will not suffer, nor permit to be continued,
548 any lien or encumbrance incurred by them or their
|
|
|
|
|
|
|
|
|
|
|
32.1
|
|
32.2
|
Notwithstanding the fact that the Charter Period shall commence on the Commencement Date, this Charter shall be:
|
|
(a)
|
in full force and effect; and
|
|
(b)
|
valid, binding and enforceable against the parties hereto,
|
|
33.1
|
If:
|
|
(a)
|
the Vessel is not delivered by the Charterers as sellers to the Owners as buyers under the MOA by the Cancelling Date (or such later date as the parties to the MOA may agree); or
|
|
(b)
|
the MOA expires, is cancelled, terminated, rescinded or suspended or otherwise ceases to remain in full force and effect for any reason (in whole or in part),
|
|
34.1
|
|
34.2
|
|
(a)
|
the delivery to and acceptance by the Charterers of the Vessel under the Existing Sub-BBC;
|
|
(b)
|
the delivery to and acceptance by the Owners as buyers of the Vessel under the MOA;
|
|
(c)
|
no Potential Termination Event or Termination Event having occurred which is continuing from the date of this Charter to the last day of the Charter Period (inclusive);
|
|
(d)
|
the representations and warranties contained in Clause 45 - (Representations and Warranties) being true and correct on the date hereof and
each day thereafter until and including the last date of the Charter Period;
|
|
(e)
|
the Delivery occurring on or before the Cancelling Date; and
|
|
(i)
|
|
34.3
|
The conditions precedent specified in Clause 34.2(f) are inserted for the sole benefit of the Owners and may be waived or deferred in whole or in part and with
or without conditions by the Owners.
|
|
34.4
|
(i) On delivery to and acceptance by the Charterers (in their capacity as charterers) of the Vessel from the Existing Charterer (in their capacity as owners)
under the Existing Sub-BBC and (ii) on delivery to and acceptance by the Owners (in their capacity as buyers) of the Vessel from the Charterers (in their capacity as sellers) under the MOA, the Vessel shall be deemed to have been
delivered to, and accepted without reservation by, the Charterers under this Charter and the Charterers shall become and be entitled to the possession and use of the Vessel on and subject to the terms and conditions of this Charter on
the same day as the delivery date of the Vessel under the MOA.
|
|
34.5
|
On Delivery, as evidence of the commencement of the Charter Period, the Charterers shall sign and deliver to the Owners, the Acceptance Certificate. The
Charterers shall be deemed to have accepted the Vessel under this Charter, and the commencement of the Charter Period having started, on Delivery even if, for whatever reason, the Acceptance Certificate is not signed and/or the
Charterers do not take actual possession of the Vessel at that time.
|
|
34.6
|
The Charterers shall not be entitled for any reason whatsoever to refuse to accept delivery of the Vessel under this Charter once the Vessel has been delivered
to and accepted by the Owners (in their capacity as buyers) from the Charterers (in their capacity as sellers) under the MOA, and the Owners shall not be liable for any losses, costs or expenses whatsoever or howsoever arising
including without limitation, any loss of profit or any loss or otherwise:
|
|
(a)
|
resulting directly or indirectly from any defect or alleged defect in the Vessel (including but not limited to any deficiency in seaworthiness, merchantability, classification,
condition, design, quality, operation, performance, capacity or fitness for use or the eligibility of the Vessel for any particular trade or operation) or any failure of the Vessel; or
|
|
(b)
|
arising from any delay in the commencement of the Charter Period or any failure of the Charter Period to commence.
|
|
34.7
|
The Owners shall not be obliged to deliver the Vessel to the Charterers with any bunkers and unused lubricating oils and hydraulic oils and greases in storage
tanks and unopened drums of the Vessel except for such items which are already on the Vessel on Delivery. The Owners shall not be responsible for the fitness, quality or quantity of any such bunkers and unused lubricating oils and
hydraulic oils and greases and the Charterers shall make no claim against Owners in respect of the same.
|
|
34.8
|
The Charterers shall procure receipt by the Owners of the conditions subsequent set out in Part C of Schedule 2 in a form and substance satisfactory to the
Owners within the time periods permitted therein.
|
|
36.2
|
|
36.3
|
The Charterers shall be deemed to have paid the Advance Charterhire to the Owners on the Commencement Date by the Owners (as buyers under the MOA) setting off
an amount equal to the Advance Charterhire against a corresponding amount of the Purchase Price payable by the Owners to the Charterers (as sellers) under the MOA.
|
|
36.4
|
The Advance Charterhire shall not bear interest and shall be non-refundable.
|
|
36.5
|
|
(a)
|
a capital element of the Charterhire (the "Fixed Charterhire") to be calculated in the following manner:
|
|
(i)
|
A = 1/28 x B
|
|
(ii)
|
A is the amount of the Fixed Charterhire due on each such Payment Date.
|
|
(iii)
|
B is the difference between the Opening Capital Balance and the Final Purchase Option Price.
|
|
(b)
|
a variable element of Charterhire (the "Variable Charterhire") which shall be calculated by applying the applicable Interest Rate to the
Owners' Costs on the immediately preceding Payment Date (or, in the case of the First Payment Date only, on the Commencement Date) for the relevant Hire Period ending on the relevant Payment Date by reference to the actual number of
days elapsed.
|
|
36.5A
|
For the purposes of determining the Variable Charterhire:
|
|
(a)
|
if no Term SOFR is available for any relevant Hire Period the applicable Reference Rate shall be the Interpolated Term SOFR for a period equal in length to for that Hire Period;
|
|
(c)
|
If no Term SOFR is available for any relevant Hire Period and it is not possible to calculate the Interpolated Term SOFR, the applicable Reference Rate shall be the Historic Term
SOFR;
|
|
(d)
|
if paragraph (b) above applies but no Historic Term SOFR is available for any relevant Hire Period, the applicable Reference Rate shall be the Interpolated Historic Term SOFR for a
period equal in length to that Hire Period; and
|
|
(e)
|
if paragraph (c) above applies but it is not possible to calculate the Interpolated Historic Term SOFR, there shall be no Reference Rate for that Hire Period and Clause 37.3 shall
apply for that Hire Period.
|
|
36.6
|
Charterhire shall be payable in arrears on the following dates (each a "Payment Date"):
|
|
(a)
|
on the date falling three (3) months after the Commencement Date (the "First Payment Date"), the first instalment of Charterhire shall be
payable; and
|
|
(b)
|
on each date falling three (3) months thereafter during the Charter Period (other than the last day of the Charter Period), each subsequent instalment of Charterhire (other than the
last instalment of Charterhire); and
|
|
(c)
|
on the last day of the Charter Period, the final instalment of Charterhire,
|
|
36.8
|
Time of payment of the Charterhire and any other payments by the Charterers under this Charter shall be of the essence of this Charter.
|
|
36.9
|
All payments of the Charterhire and any other moneys payable hereunder shall be made in Dollars.
|
|
36.10
|
All payments of the Charterhire and any other moneys payable hereunder shall be payable by the Charterers to the Owners' designated bank account as the Owners may notify the
Charterers in writing from time to time.
|
|
36.11
|
Payment of the Charterhire and any other amounts under this Charter shall be at the Charterers' risk until receipt by the Owners.
|
|
(a)
|
(except in the case of the Advance Charterhire) any set off, counterclaim, recoupment, defence, claim or other right which the Charterers may at any time have against the Owners or
any other person for any reason whatsoever including, without limitation, any act, omission or breach on the part of the Owners under this Charter or any other agreement at any time existing between the Owners and the Charterers;
|
|
(b)
|
any change, extension, indulgence or other act or omission in respect of any indebtedness or obligation of the Charterers, or any sale, exchange, release or surrender of, or other
dealing in, any security for any such indebtedness or obligation;
|
|
(c)
|
any title defect or encumbrance or any dispossession of the Vessel by title paramount or otherwise;
|
|
(d)
|
any defect in the seaworthiness, condition, value, design, merchantability, operation or fitness for use of the Vessel or the ineligibility of the Vessel for any particular trade,
or for registration or documentation under the laws of any relevant jurisdiction;
|
|
(e)
|
the Total Loss or any damage to or forfeiture or court marshall's or other sale of the Vessel if the Termination Sum or any part thereof remains due;
|
|
(f)
|
any libel, attachment, levy, detention, sequestration or taking into custody of the Vessel or any restriction or prevention of or interference with or interruption or cessation in,
the use or possession thereof by the Charterers unless for such period where such arrest, detention or seizure is solely attributable to the fault of the Owners;
|
|
(g)
|
any insolvency, bankruptcy, reorganization, arrangement, readjustment, dissolution, liquidation or similar proceedings by or against the Charterers and any other Relevant Person;
|
|
(h)
|
any invalidity, unenforceability, lack of due authorization or other defects, or any failure or delay in performing or complying with any of the terms and provisions of this Charter
or any of the Leasing Documents by any party to this Charter or any other person;
|
|
(i)
|
any enforcement or attempted enforcement by the Owners of their rights under this Charter or any of the Leasing Documents executed or to be executed pursuant to this Charter;
|
|
(j)
|
any loss of use of the Vessel due to deficiency or default or strike of officers or crew, fire, breakdown, damage, accident, defective cargo or any other cause which would or might
but for this provision have the effect of terminating or in any way affecting any obligation of the Charterers under this Charter; or
|
|
(k)
|
any prevention, delay, deviation or disruption in the use of the Vessel resulting from the wide outbreak of any viruses or any other highly infectious or contagious diseases
(including the 2019 novel coronavirus), including but not limited to those caused by:
|
|
(i)
|
closure of ports;
|
|
(ii)
|
prohibitions or restrictions against the Vessel calling at or passing through certain ports;
|
|
(iii)
|
restriction in the movement of personnel and/or shortage of labour affecting the operation of the Vessel or the operation of the ports (including stevedoring operations);
|
|
(iv)
|
quarantine regulations affecting the Vessel, its cargo, the crew members or relevant port personnel;
|
|
(v)
|
fumigation or cleaning of the Vessel; or
|
|
(vi)
|
any claims raised by any Approved Sub-charterer or manager of the Vessel that a force majeure event or termination event (or any other analogous event howsoever called) has occurred
under the relevant charter agreement or management agreement (as the case may be) of the Vessel as a result of the outbreak of such viruses.
|
|
36.13
|
|
(a)
|
the operation of this Charter in respect of the hire and all other payments to be made pursuant to this Charter and the remittance thereof to the Owners; and
|
|
(b)
|
the import, export, purchase, operation, delivery and re-delivery of the Vessel,
|
|
37.3
|
If:
|
|
(a)
|
this Clause 37.3 applies pursuant to Clause 36.5A and Clause 37.1; or
|
|
(b)
|
a substitute basis is not so requested and/or agreed pursuant to Clause 37.2 above; or
|
|
(c)
|
|
(i)
|
the Margin, and
|
|
(ii)
|
the cost of funds certified and notified by the Owners, with relevant supporting evidence available to the Owners at the relevant time (expressed as an annual rate of interest)
relating to the then prevailing Owners' Costs or any part thereof during the relevant Hire Period (as reasonably determined by the Owners),
|
|
37.4
|
|
(a)
|
providing for the use of a Replacement Reference Rate in relation to Dollars in place of (or in addition to) that Published Rate; and
|
|
(b)
|
|
(i)
|
aligning any provision of any Leasing Document to the use of that Replacement Reference Rate;
|
|
(ii)
|
enabling that Replacement Reference Rate to be used for the calculation of the Interest Rate under this Charter (including, without limitation, any consequential changes required to
enable that Replacement Reference Rate to be used for the purposes of this Charter);
|
|
(iii)
|
implementing market conventions applicable to that Replacement Reference Rate;
|
|
(iv)
|
providing for appropriate fallback (and market disruption) provisions for that Replacement Reference Rate; or
|
|
37.6
|
All interest (including default interest) and any other payments under this Charter which are of an annual or periodic nature shall accrue from day to day and
shall be calculated on the basis of the actual number of days elapsed and a three hundred and sixty (360) days' year.
|
|
38.2
|
The Charterers shall promptly notify any party (including, without limitation, the Weco Charterer or any other Approved Sub-charterer of the Vessel) (as the
Owners may request) in writing that the Vessel is the property of the Owners and the Charterers shall provide the Owners with a copy of such written notification and satisfactory evidence to the opinion of the Owners that such party
has received such written notification.
|
|
38.3
|
Subject to Clause 38.4, if the Vessel is arrested, seized, impounded, forfeited, detained or taken out of their possession or control (whether or not pursuant
to any distress, execution or other legal process), the Charterers shall procure the immediate release of the Vessel (whether by providing bail or procuring the provision of security or otherwise do such lawful things as the
circumstances may require) and shall immediately notify the Owners of such event and shall indemnify the Owners against all losses, costs or charges incurred by the Owners by reason thereof in re-taking possession or otherwise in
re-acquiring the Vessel. Without prejudice to the generality of the foregoing and Clause 52 - , the Charterers agree to indemnify the Owners against all consequences or liabilities arising from the master, officers or agents signing
bills of lading or other documents.
|
|
38.4
|
If the Vessel is arrested or otherwise detained solely because of the Owners' direct actions or omissions and for reasons which are not in any part of a
consequence of contributory negligence and/or wilful misconduct of any Approved Sub-charterer, a Relevant Person or any other member of the Group (or its affiliates), the Owners shall at their own expense take all reasonable steps to
procure that the Vessel is released within a reasonable time.
|
|
38.5
|
The Charterers shall pay and discharge or cause the Weco Charterer or any other sub-charterer of the Vessel to pay and discharge all obligations and liabilities
whatsoever which have given or may give rise to liens on or claims enforceable against the Vessel. The Charterers shall take all steps to prevent (and shall procure that any sub-charterer of the Vessel shall take all steps to prevent)
an arrest (threatened or otherwise) of the Vessel.
|
|
(a)
|
in Dollars;
|
|
(b)
|
in the case of fire and usual hull and machinery, marine risks and war risks (including blocking and trapping), on an agreed value basis of at least the higher of (i) one hundred
per cent (100%) of then applicable Market Value of the Vessel and (ii) one hundred and twenty per cent (120%) of the then prevailing Owners' Costs;
|
|
(c)
|
in the case of oil pollution liability risks for the Vessel, for an aggregate amount equal to the higher of (i) $1,000,000,000 and (ii) the highest level of cover from time to time
available under protection and indemnity club entry and in the international marine insurance market;
|
|
(d)
|
in the case of protection and indemnity risks, in respect of the full tonnage of the Vessel and with a protection and indemnity club which is a member of the International Group of
Protection and Indemnity Clubs;
|
|
(e)
|
with first class international insurers and/or underwriters acceptable to the Owners and having a Standard & Poor's rating of BBB+ or above, a Moody's rating of A or above or an
AM Best rating of A- or above or otherwise acceptable to the Owners or, in the case of war risks through a protection and indemnity club which meets the requirements of paragraph (d) above; and
|
|
(f)
|
on terms and in form acceptable to the Owners and the Owners' Financiers (if any).
|
|
39.2
|
|
(a)
|
subject always to paragraph (b), name the Charterers, the Approved Manager and the Owners(and if applicable the Owners' Financiers if so required by the Owners) as the only named assureds unless the interest of every other named assured or co-assured is limited:
|
|
(i)
|
in respect of any Obligatory Insurances for hull and machinery and war risks;
|
|
(A)
|
to any provable out-of-pocket expenses that they have incurred and which form part of any recoverable claim on underwriters; and
|
|
(B)
|
to any third party liability claims where cover for such claims is provided by the policy (and then only in respect of discharge of any claims made against them); and
|
|
(ii)
|
in respect of any Obligatory Insurances for protection and indemnity risks, to any recoveries they are entitled to make by way of reimbursement following discharge of any third
party liability claims made specifically against them,
|
|
(i)
|
in respect of fire and other usual marine risks and war risks, name (or be amended to name) the same as additional named assured for their rights and interests, warranted no
operational interest and with full waiver of rights of subrogation against such financiers, but without such financiers thereby being liable to pay (but having the right to pay) premiums, calls or other assessments in respect of such
insurance;
|
|
(ii)
|
in relation to protection and indemnity risks, name (or be amended to name) the same as additional insured or co-assured for their rights and interests to the extent permissible
under the relevant protection and indemnity club rules; and
|
|
(iii)
|
name the same and the Owners as respectively the first ranking loss payee and the second ranking loss payee (and in the absence of any financiers, the Owners as first ranking loss
payee) in accordance with the terms of the relevant loss payable clauses approved by the Owners' Financiers and the Owners with such directions for payment in accordance with the terms of such relevant loss payable clause, as the
Owners and the Owners' Financiers (if any) may specify;
|
|
(c)
|
provide that all payments by or on behalf of the insurers under the Obligatory Insurances to the Owners and/or the Owners' Financiers (as applicable) shall be made without set-off,
counterclaim, deductions or condition whatsoever;
|
|
(d)
|
provide that such Obligatory Insurances shall be primary without right of contribution from other insurances which may be carried by the Owners or the Owners' Financiers (if any);
|
|
(e)
|
provide that the Owners and/or the Owners' Financiers (if any) may make proof of loss if the Charterers fail to do so; and
|
|
(f)
|
provide that if any Obligatory Insurance is cancelled, or if any substantial change is made in the coverage which adversely affects the interest of the Owners and/or the Owners'
Financiers (if any), or if any Obligatory Insurance is allowed to lapse for non-payment of premium, such cancellation, change or lapse shall not be effective with respect to the Owners and/or the Owners' Financiers (if any) for thirty
(30) days after receipt by the Owners and/or the Owners' Financiers (if any) of prior written notice from the insurers of such cancellation, change or lapse.
|
|
39.3
|
The Charterers shall:
|
|
(a)
|
at least fifteen (15) days prior to Delivery (or such shorter period agreed by the parties), notify in writing the Owners of the terms and conditions of all Insurances (copied to
the Owners' Financiers (if any) and the brokers or insurers with whom the Insurances are or will be placed);
|
|
(b)
|
at least fifteen (15) days before the expiry of any obligatory insurance or otherwise before the change of appointment of any brokers (or other insurers) and any protection and
indemnity or war risks association through which Obligatory Insurances are taken from time to time pursuant to this Clause 39 - (Insurance), notify the Owners (copied to the Owners' Financiers
(if any)) of the brokers (or other insurers) and any protection and indemnity or war risks association through or with whom the Charterers propose to renew or obtain that Obligatory Insurance and of the proposed terms of such renewed
or new insurance cover and obtain the Owners' approval to such matters;
|
|
(c)
|
|
(d)
|
procure that the approved brokers and/or the war risks and protection and indemnity associations with which such a renewal is effected shall promptly after the renewal or the
effective date of the new insurance and protection and indemnity cover notify the Owners (copied to the Owners' Financiers (if any)) in writing of the terms and conditions of the renewal; and
|
|
(e)
|
as soon as practicable after the expiry of any Obligatory Insurance and within thirty (30) days after such expiry, deliver to the Owners a letter of undertaking as required by this
Charter in respect of such Insurances for the Vessel as renewed pursuant to Clause 39.3(c) (Insurance) together with copies of the relevant policies or cover notes or entry certificates duly
endorsed with the interest of the Owners and/or the Owners' Financiers (if any).
|
|
39.4
|
The Charterers shall ensure that all insurance companies and/or underwriters, and/or insurance brokers (if any) provide the Owners with copies (or upon the
Owners' request, originals) of policies, cover notes and certificates of entry relating to the Obligatory Insurances which they are to effect or renew and letter or letters of undertaking in a form required by the Owners and/or the
Owners' Financiers (if any) and including undertakings by the insurance companies and/or underwriters that:
|
|
(a)
|
they will have endorsed on each policy, immediately upon issuance, a loss payable clause and a notice of assignment complying with the provisions of this Charter and the Financial
Instruments;
|
|
(b)
|
they will hold the benefit of such policies and such insurances, to the order of the Owners and/or the Owners' Financiers (if any) and/or such other party in accordance with the
said loss payable clause;
|
|
(c)
|
they will advise the Owners and the Owners' Financiers (if any) promptly of any material change to the terms of the Obligatory Insurances of which they are aware;
|
|
(d)
|
(i) they will indicate in the letters of undertaking that they will immediately notify the Owners and the Owners' Financiers (if any) when any cancellation, charge or lapse of the
relevant obligatory insurance occur and (ii) following a written application from the Owners and/or the Owners' Financiers (if any) not later than one (1) month before the expiry of the Obligatory Insurances they will notify the
Owners and the Owners' Financiers (if any) not less than fourteen (14) days before the expiry of the obligatory insurances, in the event of their not having received notice of renewal instructions from the Charterers and, in the event
of their receiving instructions to renew, they will promptly notify the Owners and the Owners' Financiers (if any) of the terms of the instructions; and
|
|
(e)
|
if any of the Obligatory Insurances form part of any fleet cover, the Charterers shall procure that the insurance broker(s), or leading insurer, as the case may be, undertakes to
the Owners and the Owners' Financiers (if any) that such insurance broker or insurer will not set off against any sum recoverable in respect of a claim relating to the Vessel under such Obligatory Insurances any premiums due in
respect of any other vessel under any fleet cover of which the Vessel forms a part or any premium due for other insurances, they waive any lien on the policies, or any sums received under them, which they might have in respect of such
premiums, and they will not cancel such Obligatory Insurances by reason of non-payment of such premiums or other amounts, and will arrange for a separate policy to be issued in respect of the Vessel forthwith upon being so requested
by the Owners and/or the Owners' Financiers (if any) and where practicable.
|
|
39.5
|
The Charterers shall ensure that any protection and indemnity and/or war risks associations in which the Vessel is entered provides the Owners and the Owners'
Financiers (if any) with:
|
|
(a)
|
a copy of the certificate of entry for the Vessel as soon as such certificate of entry is issued;
|
|
(b)
|
a letter or letters of undertaking in such form as may be required by the Owners and the Owners' Financiers (if any) or in such association's standard form; and
|
|
(c)
|
a certified copy of each certificate of financial responsibility for pollution by oil or other Environmentally Sensitive Material issued by the relevant certifying authority in
relation to the Vessel.
|
|
39.6
|
The Charterers shall ensure that all policies relating to Obligatory Insurances are deposited with the approved brokers (if any) through which the insurances
are effected or renewed.
|
|
39.7
|
The Charterers shall procure that all premiums or other sums payable in respect of the Obligatory Insurances are punctually paid and produce all relevant
receipts when so required by the Owners.
|
|
39.8
|
The Charterers shall ensure that any guarantees required by a protection and indemnity or war risks association are promptly issued and remain in full force and
effect.
|
|
39.9
|
The Charterers shall neither do nor omit to do (nor permit to be done or not to be done) any act or thing which would or might render any Obligatory Insurance
invalid, void, voidable or unenforceable or render any sum payable under an Obligatory Insurance repayable in whole or in part; and, in particular:
|
|
(a)
|
the Charterers shall procure that all necessary action is taken and all requirements are complied with which may from time to time be applicable to the Obligatory Insurances, and
(without limiting the obligations contained in this Clause 39 - (Insurance)) ensure that the Obligatory Insurances are not made subject to any exclusions or qualifications to which the Owners
have not given their prior approval (unless such exclusions or qualifications are made in accordance with the rules of a protection and indemnity association which is a member of the International Group of Protection And Indemnity
Clubs);
|
|
(b)
|
the Charterers shall not make or permit any changes relating to the classification or the classification society of the Vessel or, subject to procuring the provision of a
replacement manager's undertaking in substantially the same form as the Manager's Undertaking, any changes to the manager or operator of the Vessel unless such changes have, if required, first been approved by the underwriters of the
Obligatory Insurances, the Owners and the Owners' Financiers (if any);
|
|
(c)
|
the Charterers shall procure that all quarterly or other voyage declarations which may be required by the protection and indemnity risks association in which the Vessel is entered
to maintain cover for trading to the United States of America and Exclusive Economic Zone (as defined in the United States Oil Pollution Act 1990 or any other applicable legislation) are made and the Charterers shall promptly provide
the Owners with copies of such declarations and a copy of its valid certificate of financial responsibility; and
|
|
(d)
|
the Charterers shall not employ the Vessel, nor allow it to be employed, otherwise than in conformity with the terms and conditions of the Obligatory Insurances, without first
obtaining the consent of the insurers and complying with any requirements (as to extra premium or otherwise) which the insurers specify.
|
|
39.10
|
The Charterers shall not make or agree to any alteration to the terms of any Obligatory Insurance nor waive any right relating to any Obligatory Insurance without the prior written
consent of the Owners and the Owners' Financiers (if any).
|
|
39.11
|
The Charterers shall not settle, compromise or abandon any claim under any obligatory insurance for Total Loss or for a Major Casualty, and shall do all things necessary and provide
all documents, evidence and information to enable the Owners to collect or recover any moneys which at any time become payable in respect of the Obligatory Insurances.
|
|
39.12
|
The Charterers shall provide the Owners upon written request (except that upon the occurrence of a Total Loss or a Major Casualty the Charterers shall provide the following
immediately without the Owners' making any request), copies of:
|
|
(a)
|
all communications between the Charterers and:
|
|
(i)
|
the approved brokers;
|
|
(ii)
|
the approved protection and indemnity and/or war risks associations; and/or
|
|
(iii)
|
the approved insurers and/or underwriters, which relate directly or indirectly to:
|
|
(A)
|
the Charterers' obligations relating to the Obligatory Insurances including, without limitation, all requisite declarations and payments of additional premiums or calls; and
|
|
(B)
|
any credit arrangements made between the Charterers and any of the persons referred to in paragraphs (i) or (ii) above relating wholly or partly to the effecting or maintenance of
the Obligatory Insurances; and
|
|
(b)
|
any communication with any party involved in case of a claim under any of the Vessel's insurances.
|
|
39.13
|
|
(a)
|
any information which the Owners or the Owners' Financiers (or any such designated person) request for the purpose of:
|
|
(i)
|
obtaining or preparing any report from an independent marine insurance broker as to the adequacy of the Obligatory Insurances effected or proposed to be effected; and/or
|
|
(ii)
|
effecting, maintaining or renewing any such insurances as are referred to in Clause 13(a) (Insurance and Repairs) or Clause 39 - (Insurance) dealing with or considering any matters relating to any such insurances; and
|
|
(b)
|
copies of any communication between all parties involved in case of a claim under any of the Vessel's insurances exceeding the Major Casualty amount.
|
|
39.15
|
|
(a)
|
|
(a)
|
when an agreed form of such detailed report satisfactory to the Owners is obtained as a condition precedent requirement under Schedule 2 of this Charter;
|
|
(b)
|
when the Owners procure the issuance of such detailed report no more than once every calendar year, unless a Termination Event has occurred in which case such reports may be
procured at the Charterer's cost at any such time; and
|
|
(c)
|
further from time to time upon the Owners' demand where, in the Owners' opinion, at any time during the Charter Period there has been a material change in the terms of the
Insurances and/or a change in the circumstances which would materially adversely affect the adequacy of the Obligatory Insurances.
|
|
39.18
|
The Charterers shall:
|
|
(a)
|
keep the Vessel insured at their expense against such other risks (other than loss of hire which shall be insured against upon an occurrence and during the continuance of a
Termination Event) which the Owners or the Owners' Financiers consider reasonable for a prudent shipowner or operator to insure against for trading, management, operational and/or safety purposes at the relevant time (as notified by
the Owners and having regard to the then existing available insurance cover and standard practice in the operation of vessels of the same type as the Vessel) and which risks are, at that time, generally insured against by owners or
operators of vessels similar to the Vessel or of the same type as the Vessel (excluding loss of hire); and
|
|
(b)
|
upon demand fully indemnify the Owners in respect of all premiums and other expenses incurred by the Owners in respect of any other insurances (other than loss of hire insurances
which the Owners may take out upon an occurrence and during the continuance of a Termination Event) which the Owners deem necessary (having regard to the existing insurance cover and market practice for the trading, management,
operation and safety of vessels of the same type) and takes out in respect of the Vessel.
|
|
40.1
|
It is expressly agreed and acknowledged that the Owners are not the manufacturer or original supplier of the Vessel but that the Owners (in their capacity as
buyers) have purchased the Vessel from the Charterers (in their capacity as sellers) pursuant to the MOA at the request of the Charterers, for the purpose of then chartering the Vessel to the Charterers hereunder and that no
condition, term, warranty or representation of any kind is or has been given to the Charterers by or on behalf of the Owners in respect of the Vessel (or any part thereof).
|
|
40.2
|
All conditions, terms or warranties express or implied by the law relating to the specifications, quality, description, merchantability or fitness for any
purpose of the Vessel (or any part thereof) or otherwise are hereby expressly excluded.
|
|
40.3
|
The Charterers agree and acknowledge that the Owners shall not be liable for any claim, loss, damage, expense or other liability of any kind or nature caused
directly or indirectly by the Vessel or by any inadequacy thereof or the use or performance thereof or any repairs thereto or servicing thereof and the Charterers shall not by reason thereof be released from any liability to pay any
Charterhire or other payment due under this Charter.
|
|
40.4
|
The Charterers further agree and acknowledge that the Owners are not operating the Vessel and the liability to surrender any Emission Allowances in respect of
the Vessel under any applicable Emission Scheme shall lie with the Charterers and/or any other organisation or person whom the Charterers have contractually agreed to take over all duties and responsibilities (including any
sub-charterer of the Vessel or the Approved Manager) imposed by the ISM Code, and the Charterers hereby agree that they shall promptly upon the Owners’ request, provide and submit a signed mandate letter in the form acceptable to the
Owners (acting reasonably) and the relevant authority and any other information and documents as required by the relevant authority.
|
|
40.5
|
Without prejudice to Clause 40.4, in relation to EU ETS:
|
|
(a)
|
the Charterers acknowledge that if the Vessel stops at ports in the European Union, they will incur liabilities under EU ETS and Fuel EU Maritime;
|
|
(b)
|
the Charterers acknowledge and agree that if they intend to sail the Vessel into ports in the European Union, the Charterers shall register the Vessel as part of a Shipping Company
as required under the EU ETS and shall comply in all respects with the EU ETS and Fuel EU Maritime;
|
|
(c)
|
|
(d)
|
the Charterers shall submit the ETS and Fuel EU Maritime Letter to the relevant administering authority upon registration of the Vessel pursuant to the EU ETS and shall provide the
Owners with evidence of such registration within fourteen (14) days.
|
|
41.1
|
|
(a)
|
without prejudice to Clause 41.10(b), the obligation to pay the Termination Sum is a continuing obligation and shall survive the termination of the leasing of the Vessel under this
Charter and shall continue in full force and effect until irrevocably and unconditionally paid in full;
|
|
(b)
|
payment of the Termination Sum is deemed to be proportionate as to amount, having regard to the legitimate interest of the Owners, in protecting against the Owners’ risk of the
Charterers failing to perform its obligations under this Charter; and
|
|
(c)
|
subject to clause 49.5, the Termination Sum shall, depending on the nature of the Termination Event(s) on the basis of which the Owners serve a Termination Notice, be either an
obligation to pay damages following acceptance by the Owners of a breach of condition by the Charterers or an obligation to pay an agreed sum in specified circumstances which do not involve a breach of contract by the Charterers.
|
|
41.2
|
If the Charterers fail to make any payment of the Termination Sum on the Termination Date, Clause 37.5 shall apply and the Owners shall be entitled to exercise
their rights under Clauses 41.10 and 41.11.
|
|
41.4
|
|
(b)
|
|
(c)
|
to the satisfaction of the Approved Classification Society; and
|
|
(d)
|
|
(e)
|
|
(f)
|
be re-delivered to the Owners together with all spare parts and spare equipment as were on board at the time of Delivery, and any such spare parts and spare equipment on board at
the time of re-delivery shall be taken over by the Owners free of charge;
|
|
(g)
|
be free of any cargo and Security Interest (save for the Security Interests granted pursuant to the Financial Instruments, if any);
|
|
(h)
|
be free of any crew and officers unless otherwise instructed by the Owners;
|
|
(i)
|
be free of any charter or other employment (unless the Owners wish to retain the continuance of any prevailing charter or as otherwise agreed by the Owners in their absolute
discretion); and
|
|
(j)
|
have such amount of bunkers on board the Vessel as would be sufficient to enable the Vessel to sail to the nearest bunker port in compliance with all bunkering fuel content
regulations then applicable in such place of redelivery, including without limitation, the global sulphur limit imposed by the International Maritime Organization (IMO).
|
|
(a)
|
the prevailing market rate for the bareboat chartering of vessels of a similar type as the Vessel (as determined by an Approved Valuer appointed by the Owners); and
|
|
(b)
|
the prevailing market rate for the chartering of vessels of a similar type as the Vessel on the Index.
|
|
41.9
|
The Owners shall, at the time of the redelivery of the Vessel, take over all bunkers, lubricating oil, unbroached provisions, paints, ropes, other consumable
stores and spare parts in the Vessel (but, if (with the consent of the Owners) any time charter of the Vessel remains in place at the time of redelivery, excluding any bunkers or such other items owned by a third party time charterer,
and in such case, the Charterers shall on demand reimburse the Owners for any amount the Owners have to pay to that time charterer for such bunkers or items) at no cost to the Owners.
|
|
41.10
|
|
(a)
|
the Charterers' right to possess and operate the Vessel shall immediately cease and (without in any way affecting the Charterers' obligation to pay the Charterer the Termination Sum
and comply with their other obligations under this Charter) the Charterers shall hold the Vessel as gratuitous bailee only to the Owners, the Charterers shall procure that the master and crew follow the orders and directions of the
Owners and the Charterers shall, upon the Owners' request (at Owners' sole discretion), be obliged to immediately (and at the Charterers' own cost) redeliver the Vessel to the Owners at such ready and nearest safe port or location as
the Owners may require and for the avoidance of doubt, any such redelivery shall not extinguish the Owners' right to recover the Termination Sum from the Charterers under this Charter;
|
|
(i)
|
the Nominated Purchaser is acceptable to the Owners (such acceptability not to be unreasonably withheld or delayed); and
|
|
(ii)
|
the price to be paid by the Nominated Purchaser (after deducting any commissions, taxes and other costs of sale) is equal to or more than the applicable Termination Sum (unless
otherwise agreed by the Owners in their absolute discretion);
|
|
41.14
|
If the Total Loss Proceeds unconditionally received by the Owners (or the Owners' Financiers in accordance with the terms of the relevant loss payable clause) are less than the
Termination Sum, the Charterers shall pay such shortfall to the Owner on the Total Loss Payment Date.
|
|
41.15
|
|
(a)
|
the Owners (in their capacity as buyers) purchasing the Vessel from the Charterers (in their capacity as sellers) in accordance with the terms of the MOA; and
|
|
(b)
|
the Owners subsequently chartering the Vessel to the Charterers in accordance with the terms of this Charter,
|
|
42.2
|
Without prejudice to any other rights of the Owners hereunder, the Charterers shall promptly pay to the Owners on written demand on a full indemnity basis all
costs, charges and expenses incurred by the Owners in collecting any Charterhire or the Advance Charterhire or the Option Premium or other payments not paid on the due date under this Charter and in remedying any other failure of the
Charterers to observe the terms and conditions of this Charter.
|
|
42.3
|
All documented costs and expenses (including, but not limited to, third party legal costs) incurred by the Owners or Owners' legal counsel in the preparation,
negotiation, finalisation and execution of all documentation in relation to this Charter or any other Leasing Document (including without limitation any registration or filing expenses, all documented costs incurred by the Owners and
all third party legal costs, expenses and other disbursement incurred by the Owners' legal counsels in connection with the same) shall be for the account of the Charterers (regardless of whether the transaction contemplated by the
Leasing Documents actually completes).
|
|
42.4
|
All documented costs and expenses incurred by the Owners in relation to the acquisition, registration of title of the Vessel in the Owners' name in the Flag
State together with any and all fees (including but not limited to any vessel registration and tonnage fees and the Owners' initial and ongoing annual registration and maintenance costs if required to be registered as a foreign
maritime entity or the appointment of resident agents under the laws of the Flag State) payable by the Owners to register, maintain and/or renew such registration shall be for the account of the Charterers (regardless of whether the
Vessel is delivered under the MOA and this Charter). Without prejudice to the foregoing, if the Flag State requires the Owners to establish a physical presence or office in the jurisdiction of such Flag State, all fees, costs and
expenses payable by the Owners to establish and maintain such physical presence or office shall be for the account of the Charterers. The Charterers shall promptly provide the Owners with evidence of payment of the annual
register/tonnage tax amounts payable to the Flag State or any other aforesaid costs, expenses and/or taxes when the same fall due.
|
|
42.5
|
All costs and expenses incurred by the Owners (including but not limited to legal fees) in relation to the transfer of title of the Vessel from the Owners to
the Charterers and the re-delivery of the Vessel by the Charterers to the Owners pursuant to Clause 41 - (Termination, Redelivery and Total Loss) shall be for the account of the Charterers.
|
|
42.6
|
If:
|
|
(a)
|
the Charterers request an amendment, waiver or consent (including an amendment or waiver which is required pursuant to 37.4 to address the fact that a Published Rate Replacement
Event has occurred); or
|
|
(b)
|
the Charterers make a request to re-register the Vessel in another Flag State,
|
|
42.7
|
The Charterers shall, on demand, pay to the Owners the amount of all documented costs and expenses (including third party legal fees) incurred by the Owners in
connection with the enforcement of, or the preservation of any rights under, any Leasing Document, including, without limitation, any action brought by the Owners to arrest or recover possession of the Vessel, and with any proceedings
instituted by or against the Owners as a consequence of it entering into a Leasing Document or enforcing those rights.
|
|
42.8
|
Notwithstanding anything to the contrary herein, the indemnities provided by the Charterers shall be provided in favour of the Owners and shall continue in full
force and effect notwithstanding any breach of the terms of this Charter or termination of this Charter pursuant to the terms hereof.
|
|
43.1
|
No neglect, delay, act, omission or indulgence on the part of either party in enforcing the terms and conditions of this Charter or any other Leasing Document
(to which they are party to) shall prejudice the strict rights of that party or be construed as a waiver thereof nor shall any single or partial exercise of any right of either party preclude any other or further exercise thereof.
|
|
43.2
|
No right or remedy conferred upon either party by this Charter or any other Leasing Document shall be exclusive of any other right or remedy provided for herein
or by law and all such rights and remedies shall be cumulative.
|
|
CLAUSE 44 -
|
NOTICES
|
|
44.1
|
Any notice, certificate, demand or other communication to be served, given made or sent under or in relation to this Charter shall be in English and in writing
and (without prejudice to any other valid method or giving making or sending the same) shall be deemed sufficiently given or made or sent if sent by registered post or by email to the following respective address or email address:
|
|
(a)
|
to the Owners: SEA 179 LEASING CO., LIMITED
|
|
(b)
|
to the Charterers: PCH DREAMING INC.
|
|
45.1
|
|
(a)
|
|
(b)
|
|
(c)
|
|
(i)
|
to execute each of the Leasing Documents to which it is a party; and
|
|
(ii)
|
to comply with and perform its obligations under each of the Leasing Documents to which it is a party;
|
|
(d)
|
all the consents, approvals, authorisations, licenses or permits referred to in Clause 45.1(c) (Representations and Warranties) remain in
force and nothing has occurred which makes any of them liable to revocation;
|
|
(e)
|
each of the Leasing Documents and the Approved Sub-charter to which a Relevant Person or the Approved Sub-charterer is a party (as the case may be) constitutes such Relevant
Person's or the Approved Sub-charterer's legal, valid and binding obligations enforceable against such party in accordance with its respective terms and any relevant insolvency laws affecting creditors' rights generally;
|
|
(f)
|
the entry into and performance by each Relevant Person (and in the case of sub-paragraph (ii) below, the Approved Sub-charterer) of, and the transactions contemplated by, each
Leasing Document to which it (and in the case of sub-paragraph (ii) below, the Approved Sub-charterer) is a party do not and will not conflict with:
|
|
(i)
|
any law or regulation applicable to it (including Anti-Money Laundering Laws, Business Ethics Laws, Sanctions or laws relating to anti-trust or collusion and laws relating to human
rights violation);
|
|
(ii)
|
the constitutional documents of such Relevant Person; and
|
|
(iii)
|
any agreement or instrument binding upon it or any of its assets or constitute a default or termination event (however described) under any such agreement or instrument;
|
|
(g)
|
there are no outstanding notices or demands from any governmental, quasi-governmental or public authority or instrumentality or any other person claiming authority in respect of the
Vessel requiring any work or other action to be taken or the expenditure of any money to be taken in respect of the Vessel or any part thereof;
|
|
(h)
|
the Vessel is free of encumbrances and liens except for the Permitted Security Interests; no third party has any Security Interest, other than the Permitted Security Interests, or
any other interest, right or claim over, in or in relation to the Vessel, this Charter or any moneys payable hereunder and/or any of the other Leasing Documents;
|
|
(i)
|
all payments which a Relevant Person is liable to make under any Leasing Document to which such Relevant Person is a party may be made by such party without deduction or withholding
for or on account of any tax payable under the laws of its Relevant Jurisdiction;
|
|
(j)
|
no legal or administrative action involving a Relevant Person has been commenced or taken (including but not limited to actions involving any Environmental Claim;
|
|
(k)
|
each Relevant Person has paid all taxes applicable to, or imposed on or in relation to it, its business or if applicable, the Vessel, except for those being contested in good faith
with adequate reserves;
|
|
(l)
|
it is not necessary under the laws of the Relevant Jurisdictions that this Charter or any other Leasing Document be registered, filed, recorded, notarized or enrolled with any court
or other authority in that jurisdiction or that any stamp, registration, notarial or similar taxes or fees be paid on or in relation to the Leasing Documents to which it is a party or the transactions contemplated by those Leasing
Documents; the choice of governing law as stated in each Leasing Document to which a Relevant Person is a party and the agreement by such party to refer disputes to the relevant courts or tribunals as stated in such Leasing Document
are valid and binding against such Relevant Person;
|
|
(m)
|
no Relevant Person nor any of their assets are entitled to immunity on the grounds of sovereignty or otherwise from any legal action or proceeding (which shall include, without
limitation, suit, attachment prior to judgment, execution or other enforcement);
|
|
(n)
|
the obligations of each Relevant Person under each Leasing Document to which it is a party, are the direct, general and unconditional obligations of such Relevant Person and rank at
least pari passu with all other present and future unsecured and unsubordinated creditors of such Relevant Person save for any obligation which is mandatorily preferred by law and not by
virtue of any contract;
|
|
(o)
|
each Leasing Document creates (or, once entered into, will create) the Security Interest which it is expressed to create with the ranking and priority it is expressed to have;
|
|
(p)
|
the Charterers and any other Relevant Person (i) are not US Tax Obligors and (ii) have not established a place of business in the United Kingdom or the United States of America;
|
|
(i)
|
is a Prohibited Person;
|
|
(ii)
|
is owned or controlled by or acting directly or indirectly on behalf of or for the benefit of, a Prohibited Person;
|
|
(iii)
|
owns or controls a Prohibited Person; or
|
|
(iv)
|
|
(r)
|
no Relevant Person or any of their respective directors, officers, and employees or, to the best of its knowledge, the Approved Sub-charterer is in breach of applicable Sanctions
laws, and none of them (i) has been or is currently being investigated on compliance with Sanctions, (ii) has received notice or is aware of any claim, action, suit or proceeding against any of them with respect to Sanctions and (iii)
has taken any action to evade the application of Sanctions;
|
|
(s)
|
|
(i)
|
prevent and detect incidences of bribery and corruption, money laundering and terrorism financing; and
|
|
(ii)
|
promote and achieve compliance with Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and or Business Ethics Laws including, but not limited to, ensuring thorough and
accurate books and records, and utilization of best efforts to ensure that Affiliates acting on behalf of a Relevant Person shall act in compliance with Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and Business Ethics
Laws,
|
|
(t)
|
that in relation to any Approved Sub-Charter:
|
|
(i)
|
each copy of that Approved Sub-Charter provided to the Owners is a true and complete copy of such document and there have been no amendments, supplements or variations to the same;
|
|
(ii)
|
each of the Weco Charterer and any other Approved Sub-Charterer is fully aware of the transactions contemplated under the MOA and this Charter; and
|
|
(iii)
|
the Weco Charterer and any other Approved Sub-Charterer has consented to the assignment by the Charterers to the Owners of all their rights, interests and benefits in relation to
the Weco Charter or, as the case may be, the relevant Approved Sub-Charter pursuant to the General Assignment;
|
|
(u)
|
the Vessel is not employed, operated or managed in any manner which (i) is contrary to any Sanctions and in particular, the Vessel is not used by or to benefit any party which is a
target of Sanctions or trade to any area or country where trading the Vessel to such area or country would constitute a breach of any Sanctions or published boycotts imposed by any of the United Nations, the European Union, the United
States of America, the United Kingdom or the People's Republic of China (provided that operation or use of the Vessel by the Weco Charterer pursuant to the Weco Charter shall not in any case be deemed to be in breach or contrary to
any published boycotts or sanctions imposed by the People's Republic of China) or (ii) would trigger the operation of any sanctions limitation or exclusion clause in any insurance documentation;
|
|
(v)
|
none of the Relevant Persons nor any of their assets, in each case, has any right to immunity from set off, legal proceedings, attachment prior to judgment or other attachment or
execution of judgement on the grounds of sovereign immunity or otherwise;
|
|
(w)
|
none of the Relevant Persons is insolvent, bankrupt or in liquidation, bankruptcy or administration or subject to any other formal or informal insolvency or bankruptcy procedure
(including, without limitation, those referred to under Clause 49.1(g) and for the avoidance of doubt including the presentation of a petition for commencing such procedures), and no receiver, administrative receiver, administrator,
liquidator, trustee or analogous officer has been appointed in respect of the any Relevant Person or all or material part of their assets;
|
|
(x)
|
no Termination Event or Potential Termination Event is continuing or might reasonably be expected to result from the entry into and performance of this Charter or any other Leasing
Document;
|
|
(y)
|
|
(ii)
|
breach of any Sanctions by any Relevant Person; and
|
|
(iii)
|
upon and after the commencement of the Charter Period, any casualty or occurrence (including damage caused to the Vessel for any reason whatsoever which results, or may be expected
to result, in repairs on the Vessel) which amounts to Major Casualty and which are not being dealt with in accordance with the Leasing Documents (including without limitation in accordance with Clause 38 - (Possession of Vessel) and the General Assignment);
|
|
(aa)
|
|
(bb)
|
|
(cc)
|
|
46.1
|
|
(a)
|
|
(i)
|
as soon as possible, but in no event later than one hundred and fifty (150) days after the end of each financial year of the Charterers, the annual financial statement accounts of
the Charterers for that financial year as referred to in the Guarantor's audited consolidated annual financial statement accounts for that financial year to be delivered under Clause 46.1(b)(iii);
|
|
(ii)
|
as soon as possible, but in no event later than ninety (90) days after the end of each half-year, the unaudited semi-annual accounts of the Charterers for that half-year (as
referred to in the Guarantor's audited consolidated financial statement accounts);
|
|
(iii)
|
|
(iv)
|
as soon as possible, but in no event later than ninety (90) days after the end of each half-year, the semi-annual consolidated unaudited accounts of the Guarantor for that half-year
certified as to their correctness by at least one director of the Guarantor;
|
|
(c)
|
they shall provide to the Owners, at the same time as they are despatched, copies of all notices and minutes relating to any of their extraordinary shareholders' meeting which are
despatched to the Charterers' or the Guarantor's respective shareholders or creditors or any class of them, unless same are publicly available;
|
|
(d)
|
they will provide the Owners promptly upon becoming aware of them, the details of:
|
|
(i)
|
|
(ii)
|
any litigation, arbitration or administrative proceedings or investigations relating to any other matters not referred to in paragraph (i) above (including proceedings or
investigations relating to any alleged or actual breach of the ISM Code or of the ISPS Code) in relation to a Relevant Person; and
|
|
(iii)
|
any Termination Event or Potential Termination Event that has occurred (and the steps, if any, being taken to remedy it);
|
|
(e)
|
they will, promptly upon a request by the Owners, supply to the Owners a certificate signed by an officer on its behalf certifying that no Termination Event or Potential Termination
Event has occurred (or if a Termination Event or Potential Termination Event has occurred, specifying the nature of the Potential Termination Event or Termination Event (and the steps, if any, being taken to remedy it));
|
|
(g)
|
|
(i)
|
do all that such Relevant Person reasonably can to ensure that any Leasing Document to which such Relevant Person is a party validly creates the obligations and the Security
Interests which such Relevant Person purports to create; and
|
|
(ii)
|
without limiting the generality of paragraph (i), promptly register, file, record or enroll any Leasing Document to which such Relevant Person is a party with any court or authority
in all Relevant Jurisdictions, pay any stamp duty, registration or similar tax in all Relevant Jurisdictions in respect of any Leasing Document to which such Relevant Person is a party, give any notice or take any other step which, is
or has become necessary or desirable for any such Leasing Document to be valid, enforceable or admissible in evidence or to ensure or protect the priority of any Security Interest which such Relevant Person creates;
|
|
(j)
|
|
(i)
|
any default by either the Approved Sub-charterer or the Charterers of the terms of the Approved Sub-charter;
|
|
(ii)
|
an event of default or termination event howsoever called under the terms of any Approved Sub-charter entitling either the Charterers or the Approved Sub-charterer to terminate the
Approved Sub-charter;
|
|
(iii)
|
breach of any Sanctions; or
|
|
(iv)
|
any Potential Termination Event or a Termination Event,
|
|
(k)
|
they shall, and shall procure that each other Relevant Person will, on the sixth month anniversary of the Commencement Date and at six-monthly intervals thereafter and otherwise
upon the Owners' and/or the Owners' Financiers (if any) request (acting reasonably) from time to time and as soon as practicable after receiving such request, provide the Owners with any additional financial or other information
relating:
|
|
(i)
|
to the Vessel (including, but not limited to the management, employment, condition, class records, location and pooling arrangement of the Vessel) and, to their best knowledge
having made due enquiry, to the Weco Charterer;
|
|
(ii)
|
the terms and conditions of any sub-charter together with any other information relating to such sub-charter; and
|
|
(iii)
|
to any other matter (which include without limitation, to their best knowledge having made due enquiry, any other matters relating to the Weco Charterer) which may be reasonably
requested by the Owners (or the Owners' Financiers (if any)) at any time or which under the terms of the relevant Leasing Document may be sought from the person in possession of such information.
|
|
(m)
|
|
(i)
|
conduct their activities in a manner consistent with US and UN sanctions, as applicable;
|
|
(ii)
|
have sufficient resources in place to ensure execution of and compliance with their own sanctions policies by their personnel, e.g., direct hires, contractors, and staff;
|
|
(iii)
|
ensure subsidiaries and affiliates comply with the relevant policies, as applicable;
|
|
(iv)
|
have relevant controls in place to monitor automatic identification system (AIS) transponders;
|
|
(v)
|
have controls in place to screen and assess onboarding or offloading cargo in areas they determine to present a high risk;
|
|
(vi)
|
have controls to assess authenticity of bills of lading, as necessary; and
|
|
(vii)
|
have controls in place consistent with the Sanctions Advisory;
|
|
(i)
|
the Vessel shall not be constructed, operated, employed, managed, used by or for the benefit of a Prohibited Person;
|
|
(ii)
|
the Vessel shall not be employed in trading with any Prohibited Person or in any manner contrary to Sanctions;
|
|
(iii)
|
notwithstanding any other provision of this paragraph (p), the Vessel shall not be permitted to call at any port in any Prohibited Country or any area or country where trading in
such area or country would constitute or would be reasonably expected to constitute a breach of Sanctions;
|
|
(iv)
|
the Vessel shall not be traded in any manner which would trigger the operation of any sanctions limitation or exclusion clause (or similar) in the Insurances or in any manner which
would result or would reasonably be expected to result in any Relevant Person or the Owners becoming a Prohibited Person; and
|
|
(v)
|
that each charterparty in respect of the Vessel shall contain, for the benefit of the Owners, language which gives effect to the provisions of Clause 46.1(p) as regards Sanctions
and of this Clause and which permits refusal of employment or voyage orders if compliance would result in a breach of Sanctions and which prohibits trading to any Prohibited Country;
|
|
(vi)
|
it and any sub-charterer of the Vessel or the Approved Manager will cooperate and exchange all relevant data and information in a timely manner to facilitate compliance with any
applicable Emission Scheme and enable each party to calculate the amount of Emission Allowances in respect of the Vessel that must be surrendered to the authorities of the applicable Emission Scheme for the Charter Period and that
each relevant party will supply the relevant authority of such Emission Scheme with relevant mandating documents to surrender such allowances to ensure that the Charterers will be in compliance with all Environmental Laws;
|
|
(q)
|
they shall ensure that the Market Value of the Vessel will be tested at any of the following instances:
|
|
(i)
|
on or around the end of each calendar year starting from and including 31 December 2024 (each such date the "Market Value Test Date") and the
Charterers shall procure valuation reports issued by the Approved Valuers evidencing such Market Value applicable to a Market Value Test Date to be delivered to the Owners no later than 30 days after the Market Value Test Date;
|
|
(ii)
|
if, in the opinion of the Owners, any volatile market fluctuations occur that may affect the value of the Vessel or vessels of the similar type of the Vessel, at any time at the
request of the Owners;
|
|
(iii)
|
at any time at the request of the Owners if the Owners have determined that the Market Value of the Vessel is likely to fall below an amount equal to 125% of the then applicable
Owners' Cost; and
|
|
(iv)
|
upon the occurrence of a Potential Termination Event or Termination Event, at any time at the request of the Owners,
|
|
(i)
|
as soon as they become aware, any Environmental Claim made against the Charterers or any sub-charter of the Vessel in connection with the Vessel or any Environmental Incident;
|
|
(ii)
|
arrest or detention of the Vessel;
|
|
(iii)
|
any exercise or purported exercise of any lien on that Vessel or its Earnings or any requisition of that Vessel for hire;
|
|
(iv)
|
any damage caused to or alteration of the Vessel for any reason whatsoever which results, or may be expected to result, in repairs on the Vessel which exceed $5,000,000; or
|
|
(v)
|
any casualty or occurrence as a result of which the Vessel has become or is, by the passing of time or otherwise, likely to become, a Major Casualty;
|
|
(s)
|
they shall not permit the sub-chartering of the Vessel other than pursuant to any Approved Sub-Charter provided that if:
|
|
(i)
|
any such Approved Sub-charter is terminated and/or rescinded;
|
|
(ii)
|
the Charterers comply with their obligations under Clause 46.1(aa)(iii); and
|
|
(iii)
|
with the consent of the Owners.,
|
|
1.
|
in case such sub-charter is a bareboat charter (irrespective of duration) or a time charter of a period exceeding or capable of exceeding twelve (12) months (taking into account any
optional extension periods), assign all their rights and interests under such sub-charter and procure the sub-charterer of such sub-charter to give a written acknowledgment of such assignment and provide such documents as the Owners
may reasonably require regarding the due execution of such sub-charter; and
|
|
2.
|
in case such sub-charter is a bareboat charter (irrespective of duration), procure the sub-charterer of such sub-charter to execute a general assignment to assign their rights under
the Insurances and Requisition Compensation in respect of the Vessel, in favour of the Owners, each in a form acceptable to the Owners;
|
|
(u)
|
|
(i)
|
conduct its business in compliance with all Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and/or Business Ethics Laws;
|
|
(ii)
|
maintain systems, controls, policies and procedures designed to promote and achieve ongoing compliance with Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and/or Business
Ethics Laws;
|
|
(iii)
|
in respect of the Charterers, not use, or permit or authorize any person to directly or indirectly use, the Opening Capital Balance for any purpose that would breach any Anti-Money
Laundering Laws, Anti-Terrorism Financing Laws and/or Business Ethics Laws;
|
|
(iv)
|
not lend, invest, contribute or otherwise make available the Opening Capital Balance to or for any other person in a manner which would result in a violation of Anti-Money
Laundering Laws, Anti-Terrorism Financing Laws and/or Business Ethics Laws.
|
|
(w)
|
|
(i)
|
the shares of the Guarantor cease to trade on the NASDAQ or Over the Counter (OTC); or
|
|
(ii)
|
pursuant to Clause 46.1(q), it is determined that the Market Value of the Vessel falls below the amount equivalent to one hundred and twenty five per cent (125%) of the then
applicable Owners' Costs (the "LTV Breach" and the said difference between the Market Value of the Vessel and one hundred and twenty five per cent (125)% of the then applicable Owners' Costs
shall be referred to as the "shortfall"),
|
|
(A)
|
|
(B)
|
provide, or ensure that a third party has provided, additional Security Interests which, has a Market Value (in the case of a Security Interests over a vessel) or otherwise in the
opinion of the Owners (in the case of Security Interests over any other asset) has a net realisable value at least equal to the shortfall and is acceptable to the Owners, and which is documented in such terms as the Owners may
require.
|
|
(z)
|
save with the prior written consent of the Owners, they shall not, and shall procure that no other Relevant Person shall, agree or enter into any transaction, arrangement, document
or do or omit to do anything which will have the effect of varying, amending, supplementing or waiving any term of the Weco Charter or any other Approved Sub-Charter;
|
|
(i)
|
all Earnings and any other amounts received by them in connection with the Vessel are paid into the Operating Account;
|
|
(ii)
|
|
(A)
|
in relation to Weco Charter, either:
|
|
(1)
|
the date on which the Weco Charter is terminated prior to the end of the relevant charter period; or
|
|
(2)
|
the date being one (1) month prior to the third anniversary (or, if such charter period extends beyond its third anniversary, the fourth anniversary) of the charter period
commencement date of the Weco Charter (the "Notification Date"), in case the Weco Charterer does not exercise the optional extension of the Weco Charter and the Charterers do not enter into a
Substitute Charter or provide evidence (to the satisfaction of the Owners) relating to the entry into, and validity of, such Substitute Charter by the Notification Date; or
|
|
(B)
|
in relation to a Substitute Charter, either:
|
|
(1)
|
the date on which such Substitute Charter is terminated prior to the end of the relevant charter period; or
|
|
(2)
|
the date being one (1) month prior to the expiry date of the fixed period under such Substitute Charter (in each case, a "New Notification Date"),
in case the Charterers do not enter into a replacement Substitute Charter or provide evidence (to the satisfaction of the Owners) relating to the entry into, and validity of, such replacement Substitute Charter by the relevant New
Notification Date,
|
|
(bb)
|
|
(i)
|
they shall not:
|
|
(A)
|
purchase, cancel or redeem any of its share capital;
|
|
(B)
|
increase or reduce its authorised share capital;
|
|
(C)
|
issues any further shares; and
|
|
(dd)
|
they shall ensure that the Vessels to be maintained with all spare parts on board and on order and with all stores on board together with all records, logs, plans, operating manuals
and drawings in relation to the Vessel or the Vessel's operations and/or maintenance; and
|
|
(ee)
|
they shall, upon the request of the Owners and at the cost of the Charterers, on or before 31st July in each calendar year, supply or procure the supply to the Owners all
information necessary in order for the Owners to comply with their or any Owners' Financiers' obligations under the Poseidon Principles in respect of the preceding year, including, without limitation, all ship fuel oil consumption
data required to be collected and reported in accordance with Regulation 22A of Annex VI and any Statement of Compliance relating to the Vessel for the preceding calendar year and, for the avoidance of doubt, such information shall be
"Confidential Information" for the purposes of Clause 56 - (Confidentiality) but the Charterers acknowledge that, in accordance with the Poseidon Principles, such information will form part of
the information published regarding the Owners' and/or Owners' Financiers' portfolio climate alignment.
|
|
47.1
|
|
(a)
|
to ascertain the condition of the Vessel and satisfy themselves that the Vessel is being properly repaired and maintained;
|
|
(b)
|
in dry-dock if the Charterers have not dry-docked the Vessel in accordance with Clause 10(g) (Periodical Dry-Docking); and
|
|
(c)
|
for any other reason they consider necessary,
|
|
47.3
|
The Charterers shall also permit the Owners to inspect the Vessel's log books whenever requested and shall whenever required by the Owners furnish them with
full information regarding any casualties or other accidents or damage to the Vessel.
|
|
47.4
|
Except as otherwise provided under Clause 47.2, the documented costs and fees for any inspection and survey permitted under this Clause shall be paid by the
Charterers.
|
|
47.5
|
All time used in respect of inspection, survey or repairs pursuant to this Clause shall be for the Charterers' account and form part of the Charter Period.
|
|
49.1
|
|
(c)
|
|
(d)
|
any Relevant Person commits any other breach of, or omits to observe or perform, any of their other obligations or undertakings in this Charter or any Leasing Document (other than a
breach referred to in paragraphs (a), (b) and (c) above) unless such breach or omission is in the opinion of the Owners, remediable and the Relevant Person remedies (or cause to remedy) such breach or omission to the satisfaction of
the Owners within ten (10) Business Days of the occurrence of such breach or omission;
|
|
(e)
|
any representation or warranty made by any Relevant Person in or pursuant to any Leasing Document to which it is a party proves to be untrue or misleading when it is made;
|
|
(f)
|
|
(i)
|
|
(ii)
|
any Financial Indebtedness of such entity becomes due and payable, or capable of being declared due and payable, prior to its stated maturity date as a consequence of any event of
default and not as a consequence of the exercise of any voluntary right of prepayment;
|
|
(iii)
|
a lease, hire purchase agreement or charter creating any Financial Indebtedness of such entity is terminated by the lessor or owner as a consequence of any termination event or
event of default (howsoever defined); or
|
|
(ii)
|
|
(iii)
|
any administrative or other receiver is appointed over all or a substantial part of the assets of such entity unless as part of a solvent reorganisation which has been approved by
the Owners;
|
|
(v)
|
a petition is presented in any Relevant Jurisdiction for the winding up or administration, or the appointment of a provisional liquidator, of such entity;
|
|
(vi)
|
such entity petitions a court, or presents any proposal for, any form of judicial or non-judicial suspension or deferral of payments, reorganisation of their debt (or certain of
their debt) or arrangement with all or a substantial proportion (by number or value) of their creditors or of any class of them or with a minority proportion (by number or value) of their creditors or of any class of them which would
reasonably likely to have a Material Adverse Effect or any such suspension or deferral of payments, reorganisation or arrangement is effected by court order, contract or otherwise;
|
|
(vii)
|
any meeting of the members or directors of such entity is summoned for the purpose of considering a resolution or proposal to authorise or take any action of a type described in
paragraph (iii), (iv), (v) or (vi);
|
|
(viii)
|
in any jurisdiction, any event occurs or any procedure is commenced which, in the opinion of the Owners, is similar to any of the foregoing referred to in (ii) to and including
(vii) above; or
|
|
(ix)
|
|
(h)
|
a Relevant Person suspends or ceases or threatens to suspend or cease carrying on its business;
|
|
(j)
|
any event or circumstance occurs which (in the opinion of the Owners) has or is reasonably likely to have a Material Adverse Effect;
|
|
(k)
|
this Charter or any Leasing Document or any Security Interest created by a Leasing Document:
|
|
(i)
|
is cancelled, terminated, rescinded or suspended or otherwise ceases to remain in full force and effect for any reason or no longer constitutes valid, binding and enforceable
obligations of any party to that document for any reason whatsoever; or
|
|
(ii)
|
is amended or varied without the prior written consent of the Owners;
|
|
(m)
|
|
(n)
|
any Termination Event (as defined in each Other Charter) occurs under such Other Charter;
|
|
(i)
|
an event of default or termination event howsoever called under the terms of the Approved Sub-charter entitling either the Approved Sub-charterer or the Charterers to terminate the
Approved Sub-charter and the Charterers breach or omit to observe or perform their obligations under Clause 46.1(aa)(iii);
|
|
(ii)
|
if any Relevant Person or the Approved Sub-charterer:
|
|
(A)
|
is or becomes a Prohibited Person;
|
|
(B)
|
is owned or controlled by or acting directly or indirectly on behalf of or for the benefit of, a Prohibited Person;
|
|
(C)
|
owns or controls a Prohibited Person;
|
|
(D)
|
has a Prohibited Person serving as a director, officer or employee;
|
|
(p)
|
Delivery does not occur on or prior to the Cancelling Date;
|
|
(q)
|
there is a merger, amalgamation, demerger or corporate reconstruction of any of the Charterers, the Other Charterers and the Guarantor without the Owners' prior written consent;
|
|
(r)
|
|
(i)
|
|
(ii)
|
the Guarantor ceases being an entity reporting with the U.S. Securities and Exchange Commission;
|
|
(s)
|
there is a change in control of ownership or control of the Charterers or there is a change of voting control in the case of the Guarantor as set out in Clause 45 - (Representations and Warranties) unless prior written consent from the Owners has been obtained prior to such change;
|
|
(t)
|
there is any occurrence of any litigation, arbitration or administrative proceedings or investigations involving a Relevant Person which has been commenced or taken and has been
adversely determined and which would have or is reasonably likely to have a Material Adverse Effect; or
|
|
(u)
|
any lease, hire purchase agreement, charter or any other financing arrangement in respect of any Associated Vessel (other than the Vessel and the Other Vessels) is terminated,
cancelled or repudiated by the relevant lessor or owner or financier as a consequence of any termination event or event of default (howsoever defined therein).
|
|
49.4
|
Without limiting the generality of the foregoing or any other rights of the Owners or the Charterers, upon the occurrence of a Termination Event, the Charterers
agree and acknowledge that the Owners shall have the sole and exclusive right and power to (i) settle, compromise, compound, adjust or defend any action, suit or proceeding relating to or pertaining to the Vessel and this Charter,
(ii) make proof of loss, appear in and prosecute any action arising from any policy or policies of insurance maintained pursuant to this Charter, and settle, adjust or compromise any claims for loss, damage or destruction under, or
take any other action in respect of, any such policy or policies and/or change or appoint a new manager for the Vessel and the appointment of any originally appointed manager may be terminated immediately without any recourse to the
Owners.
|
|
49.5
|
Each Termination Event shall either be a breach of condition by the Charterers where it involves a breach of this Charter or any of the other Leasing Document
by the Charterers or shall otherwise be an agreed terminating event, the occurrence of which gives rise to a right of the Owners to terminate the leasing of the Vessel under this Charter and to exercise its rights under this clause,
provided that, in case of a breach of contract claim, the claim amount of the Owners should not exceed the applicable Termination Sum as at the relevant time.
|
|
(a)
|
|
(a)
|
upon the Charterers providing not less than sixty (60) days' prior written notice (the "Purchase Option Notice") to purchase the Vessel;
|
|
(b)
|
on any Payment Date which falls on or after the first (1st) anniversary of the Commencement Date or on the last day of the Charter Period (as the case may be) (unless otherwise
agreed by the Owners) (the "Purchase Option Date"); and
|
|
(c)
|
in the absence of the occurrence of a Potential Termination Event or a Termination Event which is continuing on or prior to either the date of the Purchase Option Notice or the
Purchase Option Date.
|
|
51.3
|
The Purchase Option Notice shall be signed by a duly authorised officer or attorney of the Charterers and, once delivered to the Owners, will be irrevocable and
the Charterers shall be bound to pay to the Owners the Purchase Option Price on the Purchase Option Date.
|
|
51.4
|
|
51.5
|
If the Charterers do not exercise the Purchase Option on or before the expiration of the Charter Period:
|
|
(a)
|
the Charterers shall pay the Option Premium to the Owners on the last day of the Charter Period;
|
|
(b)
|
the Charterers shall on the last day of the Charter Period re-deliver the Vessel to the Owners in accordance with Clause 41.6 and shall ensure that they have fulfilled their
obligations under this Charter and made payment of the Option Premium, all Charterhire and all other moneys pursuant to the terms of this Charter; and
|
|
(c)
|
the Owners shall be entitled (at Owners' sole discretion) to sell or operate the Vessel as they may require and may create whatsoever interests thereon, including without limitation
sale and purchase agreements, charterparties or any other form of employment contracts.
|
|
51.6
|
For the avoidance of doubt, the Charterers agree that should the Option Premium not be paid or not be paid in full on its due date for payment under the terms
of this Charter, any net proceeds deriving from the sale or operation of the Vessel by the Owners shall not be applied towards reduction of the unpaid Option Premium, Charterhire or any other moneys due pursuant to the terms of this
Charter.
|
|
(c)
|
the Vessel shall be free from any registered mortgages incurred by the Owners;
|
|
(d)
|
the Purchase Option Price or the Termination Sum or the Mandatory Sale Price shall be paid by (or on behalf of) the Charterers to the Owners on the Purchase Option Date or the Termination Date or the Mandatory Sale Date (as the case may be) together with unpaid amounts of Charterhire and other moneys owing by or accrued or due from the
Charterers under this Charter on or prior to the Purchase Option Date or the Termination Date or the Mandatory Sale Date (as the case may be) which remain unpaid; and
|
|
(e)
|
concurrently with the Owners receiving irrevocable payment of the Purchase Option Price or, as the case may be, the applicable Termination Sum or the applicable Mandatory Sale Price
and all other moneys payable under this Charter in full pursuant to the terms of this Charter, the Owners shall (save in the event of Total Loss) (at the Charterer's cost) transfer the legal and beneficial ownership of the Vessel on
an "as is where is" basis to the Charterers or their nominees and shall (at the Charterers' cost) execute a bill of sale and a protocol of delivery and acceptance evidencing the same and any other document strictly necessary to
transfer the title of the Vessel to the Charterers or their nominees (and to the extent required for such purposes, the Vessel shall be deemed first to have been redelivered to the Owners), provided that the Owners shall not be
obliged to transfer the legal and beneficial interest in the Vessel to the Charterers in any event unless the Owners are satisfied that no Termination Event has occurred and is continuing and all obligations, duties, liabilities and
indemnities of the Charterers under the Leasing Documents have been fully performed and (if applicable) paid.
|
|
53.1
|
The Charterers shall indemnify the Owners on their demand against all documented claims, expenses, liabilities, losses, fees (including but not limited to any
vessel registration and tonnage fees or any tax incurred by the Owners as a result of the operation and/or trading of the Vessel) suffered or incurred by or imposed on the Owners arising from this Charter and any Leasing Document,
including but not limited to (i) in connection with delivery, possession, performance, control, registration, repair, survey, insurance, maintenance, manufacture, purchase, ownership and operation of the Vessel by the Owners, (ii)
costs related to the prevention or release of liens or detention of or requisition, use, operation or redelivery, sale or disposal of the Vessel or any part of it and (iii) enforcing the Owners' rights under this Charter or any
Leasing Document, in each case of paragraphs (i) to (iii), whether prior to, during or after termination of the leasing of this Charter and whether or not the Vessel is in the possession or the control of the Charterers or otherwise.
Without prejudice to its generality, this Clause covers any claims, expenses, liabilities and losses which arise, or are asserted, under or in connection with any law relating to safety at sea, the ISM Code, the ISPS Code, the MARPOL
Protocol, any Environmental Law, any Sanctions or any Anti- Money Laundering Laws, Anti-Terrorism Financing Laws or Business Ethics Laws.
|
|
53.2
|
The Charterers agree to indemnify the Owners against all consequences or liabilities arising from the Master, officers or agents signing Bills of Lading or
other documents.
|
|
53.4
|
All rights which the Charterers have at any time (whether in respect of this Charter or any other transaction) against the Other Charterers or any Relevant
Person shall be fully subordinated to the rights of the Owners under the Leasing Documents and until the end of this Charter and unless the Owners otherwise direct, the Charterers shall not exercise any rights which it may have
(whether in respect of this Charter or any other transaction) by reason of performance by it of its obligations under the Leasing Documents or by reason of any amount becoming payable, or liability arising, under this Clause:
|
|
(a)
|
to be indemnified by the Other Charterers or such Relevant Person;
|
|
(b)
|
to claim any contribution from any third party providing security for, or any other guarantor of, the Other Charterers' or such Relevant Person's obligations under the Leasing
Documents;
|
|
(c)
|
to take any benefit (in whole or in part and whether by way of subrogation or otherwise) of any rights of the Other Charterers or such Relevant Person under the Leasing Documents or
of any other guarantee or security taken pursuant to, or in connection with, the Leasing Documents by any of the aforesaid parties;
|
|
(d)
|
to bring legal or other proceedings for an order requiring the Other Charterers or such Relevant Person to make any payment, or perform any obligation, in respect of any Leasing
Document;
|
|
(e)
|
to exercise any right of set-off against the Other Charterers or such Relevant Person; and/or
|
|
(f)
|
to claim or prove as a creditor of the Other Charterers or such Relevant Person,
|
|
(g)
|
and if the Charterers receive any benefit, payment or distribution in relation to such rights it shall hold that benefit, payment or distribution to the extent necessary to enable
all amounts which may be or become payable to the Owners or the Other Owners by the Other Charterers or such Relevant Person under or in connection with the Leasing Documents to be repaid in full on trust for the Owners or the Other
Owners and shall promptly pay or transfer the same to the Owners or the Other Owners as may be directed by the Owners.
|
|
53.5
|
The Charterers hereby irrevocably agree to indemnify and hold harmless the Owners against any claim, expense, liability or loss reasonably incurred by the
Owners in liquidating or employing deposits from the Owners' Financiers or third parties to fund the acquisition of the Vessel pursuant to the MOA.
|
|
53.6
|
Notwithstanding anything to the contrary herein (but subject and without prejudice to Clause 33 - (Cancellation) ) and
without prejudice to any right to damages or other claim which the Charterers may have at any time against the Owners under this Charter, the indemnities provided by the Charterers in favour of the Owners shall continue in full force
and effect notwithstanding any breach of the terms of this Charter or termination of this Charter pursuant to the terms hereof or termination of this Charter by the Owners.
|
|
(a)
|
|
(b)
|
|
(d)
|
|
(e)
|
|
(f)
|
|
54.1
|
|
(a)
|
without any form of set-off, cross-claim, condition or counterclaim;
|
|
(b)
|
made free and clear of all present and future taxes, levies, duties or deductions of any nature whatsoever, whether levied now or in the future, unless required by law; and
|
|
(c)
|
net of any bank charges or bank fees.
|
|
54.2
|
Without prejudice to Clause 54.1 (No Set-off or Tax Deduction), if the Owners are required by law to make a tax
deduction from any payment:
|
|
(a)
|
the Owners shall notify the Charterers as soon as they become aware of the requirement; and
|
|
(b)
|
the amount due in respect of the payment shall be increased by the amount necessary to ensure that the Owners receive and retain (free from any liability relating to the tax
deduction) a net amount which, after the tax deduction, is equal to the full amount which they would otherwise have received.
|
|
54.3
|
|
54.4
|
Clause 54.3 shall not apply:
|
|
(a)
|
with respect to any tax assessed on the Owners under the law of the jurisdiction in which the Owners are incorporated or, if different, the jurisdiction (or jurisdictions) in which
the Owners are treated as resident for tax purposes if that tax is imposed on or calculated by reference to the net income received or receivable (but not any sum deemed to be received or receivable) by the Owners; or
|
|
(b)
|
to the extent a loss, liability or cost is compensated for by an increased payment under Clauses 55.2 or 55.3.
|
|
54.6
|
If the Charterers compensate the Owners by an increased payment pursuant to Clause 55.2 or 55.3 and the Owners determine that they have obtained and utilized a
tax credit attributable to this increased payment, the Owners shall reimburse the Charterers that increased payment (or part thereof if the tax credit is attributable to only part of such increased payment).
|
|
55.1
|
|
(a)
|
the introduction or alteration after the date of this Charter of a law or an alteration after the date of this Charter in the manner in which a law is interpreted or applied
(excluding any effect which relates to the application to payments under this Charter of a tax on the Owners' overall net income); or
|
|
(b)
|
complying with any regulation (including any which relates to capital adequacy or liquidity controls or which affects the manner in which the Owners allocates capital resources to
their obligations under this Charter) which is introduced, or altered, or the interpretation or application of which is altered, after the date of this Charter,
|
|
(a)
|
an additional or increased cost incurred as a result of, or in connection with, the Owners or the Owners' parent company or the Owners' Financiers (if any) having entered into, or
being a party to, this Charter, of funding or financing the acquisition of the Vessel pursuant to the MOA or performing their obligations under this Charter;
|
|
(b)
|
a reduction in the amount of any payment to the Owners under this Charter or in the effective return which such a payment represents to the Owners (if any) on their capital; or
|
|
(c)
|
an additional or increased cost of funds relating to the acquisition of the Vessel pursuant to the MOA,
|
|
(a)
|
making or lodging any claim or proof against the Charterers, whether in their liquidation, any arrangement involving them or otherwise; or
|
|
(b)
|
obtaining an order or judgment from any court or other tribunal; or
|
|
(c)
|
enforcing any such order or judgment;
|
|
56.1
|
|
(a)
|
|
(c)
|
|
(i)
|
a shareholder or an Affiliate of either Party or a party referred to in either paragraph (d) or (e) (including the employees, officers and directors thereof);
|
|
(ii)
|
professional advisers retained by a disclosing party; or
|
|
(iii)
|
persons advising on, providing or considering the provision of financing to the disclosing party or an Affiliate,
|
|
(g)
|
with the prior written consent of all Parties; or
|
|
(h)
|
to any person which is a classification society or other entity which the Owners or the Owners' Financiers have engaged to make the calculations necessary to enable the Owners
and/or the Owners' Financiers to comply with their reporting obligations under the Poseidon Principles.
|
|
59.1
|
Any settlement or discharge under any Leasing Document between the Owners and any Relevant Person shall be conditional upon no security or payment to the Owners
by any Relevant Person or any other person being set aside, adjusted or ordered to be repaid, whether under any insolvency law or otherwise.
|
|
59.2
|
If the Owners consider that an amount paid or discharged by, or on behalf of, a Relevant Person or by any other person in purported payment or discharge of an
obligation of that Relevant Person to the Owners under the Leasing Documents is capable of being avoided or otherwise set aside on the liquidation or administration of that Relevant Person or otherwise, then that amount shall not be
considered to have been unconditionally and irrevocably paid or discharged for the purposes of the Leasing Documents.
|
|
62.1
|
Defined terms
|
|
(b)
|
|
(c)
|
any agreement pursuant to the implementation of any treaty, law or regulation referred to in paragraphs (a) or (b) above with the IRS, the US government or any governmental or
taxation authority in any other jurisdiction.
|
|
62.2
|
FATCA Information
|
|
(a)
|
Subject to paragraph (c) below, each Relevant Party shall, on the date of this Charter, and thereafter within ten Business Days of a reasonable request by another Relevant Party:
|
|
(i)
|
confirm to that other party whether it is a FATCA Exempt Party or is not a FATCA Exempt Party; and
|
|
(ii)
|
supply to the requesting party (with a copy to all other Relevant Parties) such other form or forms (including IRS Form W-8 or Form W-9 or any successor or substitute form, as
applicable) and any other documentation and other information relating to its status under FATCA (including its applicable "pass thru percentage" or other information required under FATCA or other official guidance including
intergovernmental agreements) as the requesting party reasonably requests for the purpose of the requesting party's compliance with FATCA.
|
|
(b)
|
If a Relevant Party confirms to any other Relevant Party that it is a FATCA Exempt Party or provides an IRS Form W-8 or W-9 showing that it is a FATCA Exempt Party and it
subsequently becomes aware that it is not, or has ceased to be a FATCA Exempt Party, or that the said form provided has ceased to be correct or valid, that party shall so notify all other Relevant Parties or provide the relevant
revised form, as applicable, reasonably promptly.
|
|
(c)
|
Nothing in this Clause shall oblige any Relevant Party to do anything which would or, in its reasonable opinion, might constitute a breach of any law or regulation, any policy of
that party, any fiduciary duty or any duty of confidentiality, or to disclose any confidential information (including, without limitation, its tax returns and calculations); provided, however, that nothing in this paragraph shall
excuse any Relevant Party from providing a true, complete and correct IRS Form W-8 or W-9 (or any successor or substitute form where applicable). Any information provided on such IRS Form W-8 or W-9 (or any successor or substitute
forms) shall not be treated as confidential information of such party for purposes of this paragraph.
|
|
(d)
|
If a Relevant Party fails to confirm its status or to supply forms, documentation or other information requested in accordance with the provisions of this Charter or the provided
information is insufficient under FATCA, then:
|
|
(i)
|
if that party failed to confirm whether it is (and/or remains) a FATCA Exempt Party then such party shall be treated for the purposes of this Charter and the Leasing Documents as if
it is a FATCA Non-Exempt Party; and
|
|
(ii)
|
if that party failed to confirm its applicable passthru percentage then such party shall be treated for the purposes of this Charter and the Leasing Documents (and payments made
thereunder) as if its applicable passthru percentage is 100%,
|
|
(a)
|
If the representation made by the Charterers under Clause 45.1(p) (Representations and Warranties) proves to be untrue or misleading such
that the Charterers are required to make a FATCA Deduction, the Charterers shall make the FATCA Deduction and any payment required in connection with that FATCA Deduction within the time allowed and in the minimum amount required by
FATCA.
|
|
(b)
|
If the Charterers are required to make a FATCA Deduction then the Charterers shall increase the payment due from them to the Owners to an amount which (after making any FATCA
Deduction) leaves an amount equal to the payment which would have been due if no FATCA Deduction had been required.
|
|
(c)
|
The Charterers shall promptly upon becoming aware that they must make a FATCA Deduction (or that there is any change in the rate or basis of a FATCA Deduction) notify the Owners
accordingly. Within thirty (30) days of the Charterers making either a FATCA Deduction or any payment required in connection with that FATCA Deduction, the Charterers shall deliver to the Owners evidence satisfactory to the Owners
that the FATCA Deduction has been made or (as applicable) any appropriate payment paid to the relevant governmental or taxation authority.
|
|
(d)
|
If the Owners are required to make a deduction or withholding from a payment under any Financial Instruments in respect of FATCA, and is required under such Financial Instrument to
pay additional amounts in respect of such deduction or withholding, the amount of the payment due from the Charterers under this Charter shall be increased to an amount which, after such deduction or withholding and payment of
additional amounts, leaves the Owners with an amount equal to the amount which it would have had remaining if it had not been required to pay additional amounts under such Financial Instruments.
|
|
62.4
|
FATCA Deduction by Owners
|
|
62.5
|
FATCA Mitigation
|
|
63.1
|
The Charterers shall not assign this Charter except with the Owners' prior consent in writing.
|
|
(i)
|
at such time following the occurrence of a Termination Event which is continuing; or
|
|
(ii)
|
to an affiliate of the Owners. Provided always that, notwithstanding such assignment, transfer or sale, this Charter will continue (or will be novated to the applicable new owner)
on identical terms (save for logical, consequential or mutually agreed amendments).
|
|
63.3
|
The Charterers shall remain liable to the aforesaid assignee, transferee or new owner of the Vessel (as the case may be) for its performance of all obligations
under this Charter (where applicable, as novated) after any such assignment or transfer or any change of the registered ownership of the Vessel from the Owners to such new owner. The Charterers shall procure that any Relevant Person
which is a party to a Leasing Document:
|
|
(a)
|
becomes liable to such assignee, transferee or new owner of the Vessel for its performance of all obligations pursuant to such Leasing Document; and
|
|
(b)
|
enters into all necessary documents or takes any necessary actions or provide all necessary assistance required for such Leasing Document and any Security Interest created
thereunder remaining in full force and effect (or to be novated and/or executed) as from the completion of the relevant assignment, transfer or sale.
|
|
63.4
|
Without limiting the generality of Clause 63.2:
|
|
(b)
|
the Owners may do any of the following as security for the funding arrangements referred to in paragraph (a) above, in each case, without the prior consent of the Charterers:
|
|
(i)
|
|
(ii)
|
|
(iii)
|
|
(iv)
|
|
(d)
|
during the Charter Period a change in the registered or beneficial ownership of the Vessel or the Owners (by sale of shares in the Owners or other transactions having the same
effect) may be effected without the Charterers' consent, provided always that, in the event of change in the registered or beneficial ownership of the Vessel, notwithstanding such change, this Charter would continue on identical terms
(save for logical, consequential or mutually agreed amendments). The Guarantor and the Charterers shall (where applicable) remain jointly and severally liable to the aforesaid new owner of the Vessel for its performance of all
obligations pursuant to this Charter after change of the registered and/or beneficial ownership of the Vessel or the Owners from the Owners to such new owner and agree and undertake to enter into any such usual documents as the Owners
shall reasonably require to complete or perfect the transfer of the Vessel (with the benefit and burden of this Charter) pursuant to this Clause.
|
|
(e)
|
All expenses arising out of assignment or transfer of this Charter as per Clause 63 - (Assignment and Transfer) shall be for the Owner's
account subject to no Termination Event or Potential Termination Event having occurred or being continuing at the relevant time.
|
|
(a)
|
firstly, in or towards any amounts outstanding under the Leasing Documents other than the Termination Sum (including but not limited to any costs and expenses incurred in the
enforcement of the Security Documents, to the extent these are not covered under the Termination Sum);
|
|
(b)
|
secondly, in or towards satisfaction of the Charterers' obligation to pay the Termination Sum (or such portion of it that then remains unpaid) in any order of application in the
amounts comprising the Termination Sum as the Owners may determine; and
|
|
(c)
|
thirdly, any amounts remaining after the application of 64(a) and 64(b) above, shall be paid to the Charterers, but subject always to the terms of the General Assignment.
|
|
(a)
|
|
(c)
|
The reference shall be to three arbitrators. A party wishing to refer a Dispute to arbitration shall appoint its arbitrator (who shall be either a full member of the LMAA, or a
practising barrister of King's Counsel who is also a member of the Commercial Bar Association, or a retired High Court Judge practising as an arbitrator, in each case who carries on business in London) and send notice of such
appointment in writing to the other party requiring the other party to appoint its own arbitrator within fourteen (14) calendar days of that notice and stating that it will appoint its arbitrator as sole arbitrator unless the other
party appoints its own arbitrator and gives notice that it has done so within the fourteen (14) days specified. If the other party does not appoint its own arbitrator and give notice that it has done so within the fourteen (14) days
specified, the party referring a Dispute to arbitration may, without the requirement of any further prior notice to the other party, appoint its arbitrator as sole arbitrator and shall advise the other party accordingly. The award of
a sole arbitrator shall be binding on both parties as if he or she had been appointed by agreement. Nothing herein shall prevent the parties agreeing in writing to vary these provisions to provide for the appointment of a sole
arbitrator. If the two arbitrators so appointed are unable to agree on the appointment of the third arbitrator, they or either of them may by written notice request the President of the LMAA to appoint the third arbitrator within
fourteen (14) days of such request.
|
|
(d)
|
Where the reference is to three arbitrators the procedure for making appointments shall be in accordance with the procedure for full arbitration stated above.
|
|
(f)
|
In cases where neither the claim nor any counterclaim exceeds the sum of US$100,000 (or such other sum as the Parties may agree) the arbitration shall be conducted in accordance
with the LMAA Small Claims Procedure current at the time when the arbitration proceedings are commenced.
|
|
(a)
|
This Agreement, in conjunction with the other Leasing Documents, constitutes the entire agreement between the parties and supersedes all previous agreements, understandings and
arrangements between them, whether in writing or oral, in respect of its subject matter.
|
|
(b)
|
Each Party acknowledges that it has not entered into this agreement or any other Leasing Document in reliance on, and shall have no remedies in respect of, any representation or
warranty that is not expressly set out in this Agreement or in any other Leasing Document.
|
|
67.1
|
In this Charter, unless as expressly defined otherwise, the following capitalized terms shall have the meanings ascribed to them below:
|
|
(a)
|
in respect of a day on which a payment is required to be made or other dealing is due to take place under a Leasing Document in Dollars, also a day on which commercial banks are
open in New York City; and
|
|
(b)
|
in relation to the fixing of an interest rate in relation to the Owners' Costs, also a day which is a US Government Securities Business Day.
|
|
(a)
|
except to the extent that they fall within paragraph (b),
|
|
(i)
|
all freight, hire and passage moneys;
|
|
(ii)
|
any compensation payable in the event of requisition of the Vessel for hire;
|
|
(iii)
|
any remuneration for salvage and towage services;
|
|
(iv)
|
any demurrage and detention moneys;
|
|
(v)
|
damages for breach (or payments for variation or termination) of any charterparty or other contract for the employment of the Vessel; and
|
|
(vi)
|
all moneys which are at any time payable under any Insurances in respect of loss of hire (if any); and
|
|
(b)
|
if and whenever the Vessel is employed on terms whereby any moneys falling within paragraphs (a)(i) to (vi) are pooled or shared with any other person, that proportion of the net
receipts of the relevant pooling or sharing arrangement which is attributable to the Vessel.
|
|
(a)
|
any claim by any governmental, judicial or regulatory authority or any other person which arises out of an Environmental Incident or an alleged Environmental Incident or which
relates to any Environmental Law; or
|
|
(b)
|
any claim by any other person which relates to an Environmental Incident,
|
|
(a)
|
any release, emission, spill or discharge of Environmentally Sensitive Material whether within the Vessel or from the Vessel into any other vessel or into or upon the air, water,
land or soils (including the seabed) or surface water; or
|
|
(b)
|
any incident in which Environmentally Sensitive Material is released, emitted, spilled or discharged into or upon the air, water, land or soils (including the seabed) or surface
water from a vessel other than the Vessel and which involves a collision between the Vessel and such other vessel or some other incident of navigation or operation, in either case, in connection with which the Vessel is actually or
potentially liable to be arrested, attached, detained or injuncted and/or the Vessel and/or any Relevant Person and/or any operator or manager of the Vessel is at fault or allegedly at fault or otherwise liable to any legal or
administrative action; or
|
|
(c)
|
any other incident in which Environmentally Sensitive Material is released, emitted, spilled or discharged into or upon the air, water, land or soils (including the seabed) or
surface water otherwise than from the Vessel and in connection with which the Vessel is actually or potentially liable to be arrested and/or where any Relevant Person and/or any operator or manager of the Vessel is at fault or
allegedly at fault or otherwise liable to any legal or administrative action.
|
|
(a)
|
for principal, interest or any other sum payable in respect of any moneys borrowed or raised by the debtor;
|
|
(b)
|
under any loan stock, bond, note or other security issued by the debtor;
|
|
(c)
|
under any acceptance credit, guarantee or letter of credit facility made available to the debtor;
|
|
(d)
|
under a financial lease, a deferred purchase consideration arrangement (other than deferred payments for assets or services obtained on normal commercial terms in the ordinary
course of business) or any other agreement having the commercial effect of a borrowing or raising of money by the debtor;
|
|
(e)
|
under any foreign exchange transaction, any interest or currency swap or any other kind of derivative transaction entered into by the debtor or, if the agreement under which any
such transaction is entered into requires netting of mutual liabilities, the liability of the debtor for the net amount; or
|
|
(f)
|
under a guarantee, indemnity or similar obligation entered into by the debtor in respect of a liability of another person which would fall within paragraphs (a) to (e) if the
references to the debtor referred to the other person.
|
|
(a)
|
all policies and contracts of insurance, including entries of the Vessel in any protection and indemnity or war risks association, which are effected in respect of the Vessel or
otherwise in relation to it whether before, on or after the date of this Charter; and
|
|
(b)
|
all rights and other assets relating to, or derived from, any of the foregoing, including any rights to a return of a premium and any rights in respect of any claim whether or not
the relevant policy, contract of insurance or entry has expired on or before the date of this Charter.
|
|
(a)
|
either:
|
|
(i)
|
the most recent applicable Term SOFR (as of a day which is not more than three (3) US Government Securities Business Days before the Quotation Day) for the longest period (for which
Term SOFR is available) which is less than the Hire Period; or
|
|
(ii)
|
if no such Term SOFR is available for a period which is less than the Hire Period, SOFR for a day which is no more than five (5) US Government Securities Business Days (and no less
than two (2) US Government Securities Business Days) before the Quotation Day; and
|
|
(b)
|
the most recent applicable Term SOFR (as of a day which is not more than three (3) US Government Securities Business Days before the Quotation Day) the shortest period (for which
Term SOFR is available) which exceeds the Hire Period.
|
|
(a)
|
either:
|
|
(i)
|
the applicable Term SOFR (as of the Quotation Day in respect of that Hire Period) for the longest period (for which Term SOFR is available) which is less than that Hire Period; or
|
|
(ii)
|
if no such Term SOFR is available for a period which is less than that Hire Period, SOFR for the day which is two (2) US Government Securities Business Days before the Quotation
Day; and
|
|
(b)
|
|
(a)
|
the technical and commercial management agreement made or to be made between the Approved Manager and the Charterers; or
|
|
(b)
|
such other management agreement subsequently entered into in respect of the Vessel as may be approved by the Owners (such approval not to be unreasonably withheld).
|
|
(b)
|
any Variable Charterhire accrued as at the date of payment of the Mandatory Sale Price;
|
|
(c)
|
(in case of Clause 36.13, Clause 37.3 or Clause 54.5) if the Mandatory Sale Date occurs on or before the third (3rd) anniversary of the Commencement Date, one per cent. (1.00%) of the Owners' Costs as at the relevant date;
|
|
(d)
|
any Breakfunding Costs;
|
|
(e)
|
|
(a)
|
subject to sub-paragraph (b) below, the arithmetic mean of the valuations shown by two (2) valuation reports prepared:
|
|
(i)
|
in Dollars;
|
|
(ii)
|
on a date no later than thirty (30) days after the relevant Market Value Test Date;
|
|
(iii)
|
with or without physical inspection of that Vessel; and
|
|
(iv)
|
on the basis of a sale for prompt delivery for cash on normal arm's length commercial terms as between a willing seller and a willing buyer, free of any existing charter or other
contract of employment,
|
|
(a)
|
the business, operations, property, condition (financial or otherwise) or prospects of any Relevant Person or the Guarantor and its Subsidiaries as a whole;
|
|
(b)
|
the ability of any Relevant Person to perform its obligations under any Leasing Document to which it is a party; or
|
|
(c)
|
the validity or enforceability of, or the effectiveness or ranking of any Security Interests granted pursuant to any of the Leasing Documents or the rights or remedies of the Owners
under any of the Leasing Documents.
|
|
(a)
|
in relation to Other Vessel A, Julius Caesar Inc., a corporation incorporated under the laws of the Republic of Marshall Islands whose registered address is at Trust Company
Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands, MH96960 ("Other Charterer A"); and
|
|
(b)
|
in relation to Other Vessel B, Legio X Inc., a corporation incorporated under the laws of the Republic of Marshall Islands whose registered address is at Trust Company Complex,
Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands, MH96960 ("Other Charterer B").
|
|
(a)
|
in relation to Other Vessel A, Sea 268 Leasing Co. Limited, a company incorporated under the law of Hong Kong with company number 3053427 ("Other
Owner A"); and
|
|
(b)
|
in relation to Other Vessel B, Sea 269 Leasing Co. Limited, a company incorporated under the law of Hong Kong with company number 3053475 ("Other
Owner B"),
|
|
(a)
|
the very large crude carrier named Julius Caesar with IMO number 9912244 ("Other Vessel A"); and
|
|
(b)
|
the very large crude carrier named Legio X Equestris with IMO number 9912256 ("Other Vessel B"),
|
|
(a)
|
any Security Interest created by a Security Document or a Financial Instrument;
|
|
(b)
|
prior to the Commencement Date, any Security Interest created by a "Security Document" (howsoever defined under the Existing Sub-BBC);
|
|
(c)
|
any lien for unpaid master's and crew's wages in accordance with the ordinary course of operation of the Vessel or in accordance with usual reputable maritime practice;
|
|
(d)
|
any lien for salvage;
|
|
(e)
|
any lien for master's disbursements incurred in the ordinary course of trading;
|
|
(f)
|
any other lien arising by operation of law or otherwise in the ordinary course of the operation, repair or maintenance of the Vessel provided such liens do not secure amounts more
than thirty (30) days overdue;
|
|
(g)
|
any Security Interest created in favour of a plaintiff or defendant in any action of the court or tribunal before whom such action is brought as security for costs and expenses
where the Owners are prosecuting or defending such action in good faith by appropriate steps; and
|
|
(h)
|
Security Interests arising by operation of law in respect of taxes which are not overdue or for payment of taxes which are overdue for payment but which are being contested by the
Owners or the Charterers in good faith by appropriate steps and in respect of which adequate reserves have been made,
|
|
(a)
|
the methodology, formula or other means of determining that Published Rate has, in the opinion of the Parties, materially changed;
|
|
(b)
|
|
(i)
|
|
(ii)
|
the administrator of that Published Rate publicly announces that it has ceased or will cease to provide that Published Rate permanently or indefinitely and, at that time, there is
no successor administrator to continue to provide that Published Rate;
|
|
(iii)
|
the supervisor of the administrator of that Published Rate publicly announces that such Published Rate has been or will be permanently or indefinitely discontinued; or
|
|
(iv)
|
the administrator of that Published Rate or its supervisor announces that that Published Rate may no longer be used; or
|
|
(c)
|
the administrator of that Published Rate (or the administrator of an interest rate which is a constituent element of that Published Rate) determines that that Published Rate should
be calculated in accordance with its reduced submissions or other contingency or fallback policies or arrangements and either:
|
|
(i)
|
the circumstance(s) or event(s) leading to such determination are not (in the opinion of the Parties) temporary;
|
|
(ii)
|
that Published Rate is calculated in accordance with any such policy or arrangement for a period no less than a reasonable period determined by the Parties; or
|
|
(d)
|
in the opinion of the Owners, that Published Rate is otherwise no longer appropriate for the purposes of calculating interest under this Charter.
|
|
"Purchase Option" means the purchase option referred to in Clause 51.1.
|
|
"Purchase Option Date" shall have the meaning ascribed thereto in Clause 51.2.
|
|
"Purchase Option Fee" means:
|
|
(a)
|
if the Purchase Option is exercised on or after the first (1st) anniversary of the Commencement Date and before the second (2nd) anniversary of the Commencement Date, one point
eight per cent. (1.80%) of the Owners' Costs on the applicable Purchase Option Date;
|
|
(b)
|
if the Purchase Option is exercised on or after the second (2nd) anniversary of the Commencement Date and up to, inclusive, the third (3rd) anniversary of the Commencement Date, one
point five per cent. (1.50%) of the Owners' Costs on the applicable Purchase Option Date;
|
|
(c)
|
if the Purchase Option is exercised after the third (3rd) anniversary of the Commencement Date zero per cent. (0%) of the Owners' Costs as at the applicable Purchase Option Date.
|
|
"Purchase Option Notice" shall have the meaning ascribed thereto in Clause 51.2.
|
|
(a)
|
if the Purchase Option Date falls on any Payment Date on or after the first (1st) anniversary of the
Commencement Date but prior to the last day of the Charter Period, the aggregate of:
|
|
(ii)
|
any Variable Charterhire accrued but unpaid as at the date of payment of the Purchase Option Price;
|
|
(iii)
|
any Purchase Option Fee;
|
|
(iv)
|
any Breakfunding Costs;
|
|
(v)
|
|
(vi)
|
aside from the amounts described under paragraphs (i) to (v) above, any other moneys due and owing under the Leasing Documents at the relevant Purchase Option Date,
|
|
(b)
|
if the Purchase Option Date falls on the last day of the Charter Period, the aggregate of:
|
|
(ii)
|
any Charterhire accrued but unpaid as at the date of payment of the Purchase Option Price;
|
|
(iii)
|
|
(iv)
|
aside from the amounts described under paragraphs (i) to (iii) above, any other moneys due and owing under the Leasing Documents at the relevant Purchase Option Date.
|
|
(a)
|
the applicable Term SOFR as of the relevant Quotation Day and for a period equal in length to the relevant Hire Period; or
|
|
(b)
|
as otherwise determined pursuant to Clause 36.5A,
|
|
(a)
|
its Original Jurisdiction;
|
|
(b)
|
any jurisdiction where any property owned by it and charged under a Leasing Document is situated;
|
|
(c)
|
any jurisdiction where it conducts its business; and
|
|
(d)
|
any jurisdiction whose laws govern the perfection of any of the Leasing Documents entered into by it creating a Security Interest.
|
|
(a)
|
formally designated, nominated or recommended as the replacement for a Published Rate by:
|
|
(i)
|
the administrator of that Published Rate (provided that the market or economic reality that such reference rate measures is the same as that measured by that Published Rate); or
|
|
(b)
|
in the opinion of the Owners, generally accepted in the international or any relevant domestic syndicated loan markets as the appropriate successor or alternative to a Published
Rate; or
|
|
(c)
|
in the opinion of the Owners, an appropriate successor or alternative to a Published Rate.
|
|
(a)
|
|
(b)
|
otherwise imposed by any applicable law or regulation by which any Relevant Person is bound or to which it is subject.
|
|
"Sanctions Authority" means:
|
|
(a)
|
the United Nations or its Security Council;
|
|
(b)
|
the United States;
|
|
(c)
|
the European Union or the Council of the European Union;
|
|
(d)
|
the United Kingdom;
|
|
(e)
|
the People's Republic of China (including for the avoidance of doubt, Hong Kong), provided that this paragraph (e) shall not apply to the Weco Charterer when the Vessel is chartered
under the Weco Charter or the operation or use of the Vessel by the Weco Charterer (but not any further sub-lessee of the Vessel) when the Vessel is operated by the Weco Charterer (but not any further sub-lessee of the Vessel), in
each case unless otherwise specified in Clause 50.3; and
|
|
(f)
|
the governments and official institutions or agencies of any of paragraphs (a) to (e) above, including the U.S. Department of the Treasury's Office of Foreign Assets Control, the
United States Department of State, the U.S. Department of Commerce and the Hong Kong Monetary Authority and His Majesty's Treasury.
|
|
(a)
|
a mortgage, charge (whether fixed or floating) or pledge, lien, assignment, hypothecation or any other security interest of any kind or any other agreement or arrangement having the
effect of conferring a security interest;
|
|
(b)
|
the security rights of a plaintiff under an action in rem; or
|
|
(c)
|
any other right which confers on a creditor or potential creditor a right or privilege to receive the amount actually or contingently due to it ahead of the general unsecured
creditors of the debtor concerned; however this paragraph (c) does not apply to a right of set off or combination of accounts conferred by the standard terms of business of a bank or financial institution.
|
|
(a)
|
if the Termination Sum is payable to the Owners before the second (2nd) anniversary of the
Commencement Date, one point eight per cent. (1.80%) of the Owners' Costs as at the relevant date;
|
|
(b)
|
if the Termination Sum is payable to the Owners on or after the second (2nd) anniversary of the
Commencement Date and up to the third (3rd) anniversary, inclusive, of the Commencement Date, one point five per cent. (1.50%) of the Owners' Costs as at
the relevant date; and
|
|
(c)
|
if the Termination Sum is payable after the third (3rd) anniversary of the Commencement Date, one
per cent. (1.00%) of the Owners' Costs as at the relevant date,
|
|
(b)
|
any Variable Charterhire due and payable, but unpaid up to (and including) the date of payment of the Termination Sum;
|
|
(c)
|
the Termination Fee;
|
|
(d)
|
any Breakfunding Costs;
|
|
(g)
|
aside from the amounts described under paragraphs (a) to (f) above, any other moneys due and payable, but unpaid, under the Leasing Documents at the Relevant Date including any
default interest on amounts under (a) to (f) above,
|
|
"Total Loss" means:
|
|
(a)
|
actual, constructive, compromised, agreed or arranged total loss of the Vessel;
|
|
(b)
|
any expropriation, confiscation, requisition or acquisition of the Vessel, whether for full consideration, a consideration less than its proper value, a nominal consideration or
without any consideration, which is effected by any government or official authority or by any person or persons claiming to be or to represent a government or official authority (excluding a requisition for hire for a fixed period
not exceeding one (1) year without any right to an extension) unless it is redelivered within twenty-one (21) days to the full control of the Owners or the Charterers; or
|
|
(c)
|
any arrest, capture, seizure or detention of the Vessel (including any hijacking or theft but excluding any event specified in paragraph (b) of this definition) unless it is
redelivered within thirty (30) days to the full control of the Owners or the Charterers.
|
|
"Total Loss Date" means, in relation to the Total Loss of the Vessel:
|
|
(a)
|
in the case of an actual loss of the Vessel, the date on which it occurred;
|
|
(b)
|
in the case of a constructive, compromised, agreed or arranged total loss of the Vessel, the earlier of:
|
|
(i)
|
the date on which a notice of abandonment is given to the insurers;
|
|
(ii)
|
the date when the Vessel was last heard of; and
|
|
(iii)
|
the date of any compromise, arrangement or agreement made by or on behalf of the Charterers with the Vessel's insurers in which the insurers agree to treat the Vessel as a Total
Loss; and
|
|
(c)
|
in the case of any expropriation, confiscation, requisition or acquisition of the Vessel whether for full consideration, a consideration less than its proper value, a nominal
consideration or without any consideration, which is effected by any government or official authority or by any person or persons claiming to be or to represent a government or official authority (excluding a requisition for hire for
a fixed period not exceeding one (1) year without any right to an extension), on the date on which the expropriation, confiscation, requisition or, as the case may be, the acquisition of the Vessel is completed by delivery of the
Vessel to the relevant government or official authority or the person or persons claiming to be or to represent the relevant government or official authority unless it is redelivered within twenty-one (21) days to the full control of
the Owners or the Charterers; and
|
|
(d)
|
in the case of any arrest, condemnation, capture, seizure or detention of the Vessel (including any hijacking or theft), unless it is redelivered within thirty (30) days to the full
control of the Owners or the Charterers, the date falling on the expiration of such days.
|
|
"Total Loss Payment Date" means, following the occurrence of a Total Loss, the earlier of:
|
|
(a)
|
the date falling one hundred and twenty (120) days after the Total Loss Date or such later date as the Owners may agree; and
|
|
(b)
|
the date on which the Owners receive the Total Loss Proceeds.
|
|
"Total Loss Proceeds" means the proceeds of any policy or contract of insurance or any Requisition Compensation in each case arising in
respect of a Total Loss.
|
|
"US" means the United States of America.
|
|
(a)
|
a Saturday or a Sunday; and
|
|
(b)
|
a day on which the Securities Industry and Financial Markets Association (or any successor organisation) recommends that the fixed income departments of its members be closed for
the entire day for purposes of trading in US Government securities.
|
|
67.2
|
Inconsistency between Charter provisions and Leasing Documents
|
|
In the case of any conflict between the provisions or terms so of this Charter and the terms and provisions of a Leasing Document, the provisions of this Charter shall prevail.
|
|
67.3
|
Construction
|
|
the "Approved Manager", the "Charterers", the "Guarantor",
any "Relevant Person", the "Owners", any "Other Charterer", any "Other Owner",
or any other person shall be construed so as to include its successors in title, permitted assigns and permitted transferees to, or of, its rights and/or obligations under the Leasing Documents;
|
|
"agreed form" means, in relation to a document, such document in a form agreed in writing between the Owners and the Charterers and, if
required by the Owners in their sole discretion, the Owners' Financiers;
|
|
"asset" includes every kind of property, asset, interest or right, including any present, future or contingent right to any revenues or other
payment;
|
|
"company" includes any partnership, joint venture and unincorporated association;
|
|
"consent" means:
|
|
(a)
|
an authorisation, consent, approval, resolution, licence, exemption, filing, registration, notarisation and legalization; and
|
|
(b)
|
in relation to anything which will be prohibited or restricted by law if a governmental or official authority intervenes or acts in any way within a specified period after lodgment,
filing, registration or notification, the expiry of that period without intervention or action.
|
|
"contingent liability" means a liability which is not certain to arise and/or the amount of which remains unascertained;
|
|
"continuing" means, in relation to any Termination Event, a Termination Event which has not been waived by the Owners and in relation to any
Potential Termination Event, a Potential Termination Event which has not been waived by the Owners or remedied to the satisfaction of the Owners;
|
|
"control" over a particular company means the power (whether by way of ownership of shares, proxy, contract, agency or otherwise) to:
|
|
(a)
|
cast, or control the casting of, more than 51 per cent, of the maximum number of votes that might be cast at a general meeting of such company;
|
|
(b)
|
appoint or remove all, or the majority, of the directors or other equivalent officers of such company; or
|
|
(c)
|
give directions with respect to the operating and financial policies of such company with which the directors or other equivalent officers of such company are obliged to comply;
|
|
"document" includes a deed; also a letter, fax or telex;
|
|
the Owners' "cost of funds" in relation to the Owners' Costs or any part thereof is a reference to the average cost (determined either on an
actual or a notional basis) which the Owners would incur if they were to fund or finance, from whatever source(s) they may reasonably select, an amount equal to the amount of the Owners' Costs or any part thereof for a period equal in
length to the Hire Period of the Owners' Costs or any part thereof;
|
|
"expense" means any kind of cost, charge or expense (including all legal costs, charges and expenses) and any applicable value added or other
tax;
|
|
"gross negligence" means a form of negligence which is distinct from ordinary negligence, in which the due diligence and care which are
generally to be exercised have been disregarded to a particularly high degree, in which the plainest deliberations have not been made and that which should be most obvious to everybody has not been followed.
|
|
"law" includes any order or decree, any form of delegated legislation, any treaty or international convention and any regulation or
resolution of the Council of the European Union, the European Commission, the United Nations or its Security Council;
|
|
"legal or administrative action" means any legal proceeding or arbitration and any administrative or regulatory action or investigation;
|
|
"liability" includes every kind of debt or liability (present or future, and including contingent liabilities only in the case of Clause
49.1(g)(ii), Clause 53 - (Indemnities) and the definition of "Financial Indebtedness"), whether incurred as principal or surety or otherwise;
|
|
"months" shall be construed in accordance with Clause 67.4 (Meaning of "month");
|
|
"person" includes any company; any state, political sub-division of a state and local or municipal authority; and any international
organisation;
|
|
"policy", in relation to any insurance, includes a slip, cover note, certificate of entry or other document evidencing the contract of
insurance or its terms;
|
|
"protection and indemnity risks" means the usual risks covered by a protection and indemnity association which is a member of the
International Group of Protection And Indemnity Clubs including pollution risks, extended passenger cover and the proportion (if any) of any sums payable to any other person or persons in case of collision which are not recoverable
under the hull and machinery policies by reason of the incorporation in them of clause 6 of the International Hull Clauses (1/11/02 or 1/11/03), clause 8 of the Institute Time Clauses (Hulls)(1/10/83) or clause 8 of the Institute Time
Clauses (Hulls) (1/11/1995) or the Institute Amended Running Down Clause (1/10/71) or any equivalent provision;
|
|
"regulation" includes any regulation, rule, official directive, request or guideline whether or not having the force of law of any
governmental, intergovernmental or supranational body, agency, department or regulatory, self-regulatory or other authority or organisation; and
|
|
"tax" includes any present or future tax, duty, impost, levy or charge of any kind which is imposed by any state, any political sub-division
of a state or any local or municipal authority (including any such imposed in connection with exchange controls), and any connected penalty, interest or fine.
|
|
(a)
|
on the Business Day following the numerically corresponding day if the numerically corresponding day is not a Business Day or, if there is no later Business Day in the same calendar
month, on the Business Day preceding the numerically corresponding day; or
|
|
(b)
|
on the last Business Day in the relevant calendar month, if the period started on the last Business Day in a calendar month or if the last calendar month of the period has no
numerically corresponding day;
|
|
67.5
|
In this Charter:
|
|
(a)
|
references to a Leasing Document or any other document being in the form of a particular appendix or to any document referred to in the recitals include references to that form with
any modifications to that form which the Owners and the Charterers approve;
|
|
(b)
|
references to, or to a provision of, a Leasing Document or any other document are references to it as amended or supplemented, whether before the date of this Charter or otherwise;
|
|
(c)
|
references to, or to a provision of, any law include any amendment, extension, re-enactment or replacement, whether made before the date of this Charter or otherwise;
|
|
(e)
|
references to a page or screen of an information service displaying a rate shall include:
|
|
(i)
|
any replacement page of that information service which displays that rate; and
|
|
(ii)
|
the appropriate page of such other information service which displays that rate from time to time in place of that information service,
|
|
67.6
|
Construction of Insurance terms
|
|
"approved" means, for the purposes of Clause 39 - (Insurance), approved in writing by the Owners.
|
|
"excess risks" means the proportion of claims for general average, salvage and salvage charges not recoverable under the hull and machinery
policies in respect of the Vessel in consequence of its insured value being less than the value at which the Vessel is assessed for the purpose of such claims.
|
|
"obligatory insurances" means all insurances effected, or which the Charterers are obliged to effect, under Clause 39 - (Insurance) or any other provision of this Charter or another Leasing Document.
|
|
"policy" includes a slip, cover note, certificate of entry or other document evidencing the contract of insurance or its terms.
|
|
"protection and indemnity risks" means the usual risks (including but not limited to freight, demurrage and defence cover) covered by a
protection and indemnity association being a member of the International Group of Protection and Indemnity Clubs, including pollution risks and the proportion (if any) of any sums payable to any other person or persons in case of
collision which are not recoverable under the hull and machinery policies by reason of the incorporation in them of clause 6 of the International Hull Clauses (1/11/02) (1/11/03), clause 8 of the Institute Time Clauses (Hulls)
(1/10/83) (1/11/95) or the Institute Amended Running Down Clause (1/10/71) or any equivalent provision.
|
|
"war risks" includes the risk of mines and all risks excluded by clause 29 of the International Hull Clauses (1/11/02 or 1/11/03), clause 24
of the Institute Time Clauses (Hulls) (1/11/95) or clause 23 of the Institute Time Clauses (Hulls)(1/10/83).
|
|
67.7
|
Headings
|
|
1
|
Corporate Authority
|
|
1.1
|
A copy of the constitutional documents of each Relevant Person (other than the Other Charterers).
|
|
1.2
|
|
(a)
|
approving the terms of, and the transactions contemplated by, the Leasing Documents to which it is a party and resolving that it execute the Leasing Documents to which it is a
party;
|
|
(b)
|
authorizing a specified person or persons to execute the Leasing Documents to which it is a party on its behalf; and
|
|
(c)
|
authorising a specified person or persons, on its behalf, to sign and/or dispatch all documents and notices to be signed and/or dispatched by it under, or in connection with, the
Leasing Documents to which it is a party.
|
|
1.3
|
If required, an original of the power of attorney of any party to a Leasing Document authorising a specified person or persons to execute the Leasing Documents to which it is a
party.
|
|
1.4
|
If required, a specimen of the signature of each person authorized by the resolution referred to in paragraph 1.2 above.
|
|
1.5
|
If required, a copy of the resolutions signed by all the holder(s) of the issued shares of any Relevant Person, approving the terms of, and the transactions contemplated by such
Leasing Document.
|
|
1.6
|
A certificate of an officer or authorized signatory of each Relevant Person certifying that each copy document relating to it specified in this Part A of Schedule 2 is correct,
complete and in full force and effect as at a date no earlier than the date of this Agreement.
|
|
2
|
Documents and other security
|
|
2.1
|
|
2.2
|
|
2.3
|
Evidence that the Charterers' Operating Account have been opened and maintained with the Account Bank.
|
|
3
|
Valuation of Vessel
|
|
4
|
Legal opinion
|
|
4.1
|
|
5.1
|
|
5.2
|
Agreed form of letters of undertaking and certificates of entry (as the case may be) relating to insurances as set out in Clause 39 - (Insurance)
from the relevant insurer, insurance broker, protection and indemnity association or war risks association (as the case may be).
|
|
5.3
|
An insurance report by an insurance advisor appointed by the Owners (but at the cost of the Charterers) in an agreed form acceptable to the Owners.
|
|
6
|
Vessel Documents
|
|
6.1
|
A copy of the Management Agreement and any amendments thereto, establishing that the Vessel will, as from the Commencement Date, be managed by the relevant Approved Manager.
|
|
6.2
|
A copy of the Document of Compliance of the Technical Manager.
|
|
6.3
|
A copy of the Vessel's class certificate evidencing that the Vessel maintains such classification
|
|
6.4
|
Copies of the Vessel's Safety Management Certificate (together with any other details of the applicable safety management system which the Owners may require) and of any other
documents required under the ISM Code and the ISPS Code (including, without limitation, an ISSC and IAPPC).
|
|
7
|
Existing BBC, Existing Sub-BBC and Existing Time Charter
|
|
7.1
|
A copy of the executed Existing BBC (and any addendums thereto).
|
|
7.2
|
A copy of the executed Existing Sub-BBC (and any addendums thereto).
|
|
7.3
|
A copy of the executed Existing Time Charter (and any addendums thereto).
|
|
8
|
Weco Charter
|
|
8.1
|
A copy of the executed Weco Charter (and any addendums thereto).
|
|
8.2
|
Evidence to the satisfaction of the Owners that the Weco Charterer consents to the sale and leaseback of the Vessel contemplated by the Leasing Documents.
|
|
9
|
Escrow Agreement
|
|
10
|
Deed of Release
|
|
11
|
Others
|
|
11.1
|
Evidence that the Arrangement Fee and all other fees, costs and expenses then due from the Charterers to the Owners under the Leasing Documents have been paid
and received by the Owners.
|
|
11.2
|
Documentary evidence that the "Delivery" (as defined under each Other Charter) has occurred.
|
|
11.3
|
Copies of the Original Financial Statements.
|
|
11.4
|
Such evidence relating to the Relevant Person as the Owners may reasonably require for their (or their financiers) to be able to satisfy each of their "know
your customer" or similar identification procedures in relation to the Leasing Documents.
|
|
11.5
|
A copy of any other consents, approvals, authorization or other document, opinion or assurance which the Owners consider to be reasonably desirable in
connection with the entry into and performance of the transactions contemplated by any of the Leasing Documents or for the validity and enforceability of such documents.
|
|
11.6
|
If required, evidence that any process agent referred to under the Leasing Documents has accepted its appointment.
|
|
11.7
|
If any, evidence to the satisfactory to the Owners that the Delivery Shortfall (as defined in the MOA) has been so deposited into the Escrow Account (as defined
in the MOA) or paid to the Existing Charterer no later than one (1) Business Day prior to the Prepositioning Date.
|
|
11.8
|
If required by the Flag State for purposes of registering the Vessel in the name of the Owners, evidence that the Owners have been registered as a foreign
maritime entity under the laws of the Flag State (with such cost to be borne by the Charterers).
|
|
11.9
|
Such other documents as the Owners may require by giving notice to the Charterers.
|
|
1
|
Corporate Authorisations/Confirmation
|
|
1.1
|
A certificate of an authorized signatory of each Relevant Person (other than the Other Charterers) certifying that each copy document provided under paragraph 1 of Part A of
Schedule 2 of the MOA remains correct, complete and in full force and effect as on the Commencement Date.
|
|
1.2
|
A certificate of an authorized signatory of the Charterers certifying that there is no Potential Termination Event or Termination Event has occurred and is continuing as of the
Commencement Date.
|
|
2
|
Security Documents
|
|
2.1
|
Duly executed and dated copies of the General Assignment and each Manager's Undertaking and of each document to be delivered under it and evidence of their delivery within the
timing prescribed under it.
|
|
2.2
|
Documentary evidence that the Security Interests intended to be created by each of the Security Documents have been duly perfected under applicable law or will be perfected under
applicable law within the prescribed period contained in such Security Documents.
|
|
3
|
Delivery and title registration of the Vessel
|
|
3.1
|
Documentary evidence that the Vessel is or will be:
|
|
(a)
|
definitively and permanently registered in the name of the Owners under the flag of the Flag State;
|
|
(b)
|
in the absolute and unencumbered ownership of the Owners;
|
|
(c)
|
unconditionally delivered by the Existing Owner to the Existing Charterer (or its nominee) pursuant to the terms of the Existing BBC, where such documents shall include without
limitation:
|
|
(i)
|
the original (if required by the Flag State) or a copy of the notarized and legalized (if required by the Flag State) copies of the bill of sale duly executed by the Existing Owner
(and where executed by an attorney of the Existing Owner, together with such original or a copy of the notarized and legalised copies (if required by the Flag State) of the Existing Owner's power of attorney); and
|
|
(ii)
|
the original (if required by the Flag State) or a copy of the protocol of delivery and acceptance duly executed by the Existing Owner and the Existing Charterer;
|
|
(d)
|
where applicable, unconditionally delivered by the Existing Charterer to the Charterers pursuant to the terms of the Existing Sub-BBC, where such documents shall include without
limitation:
|
|
(i)
|
the original (if required by the Flag State) or a copy of the notarized and legalized (if required by the Flag State) copies of the bill of sale duly executed by the Existing
Charterer (and where executed by an attorney of the Existing Charterer, together with such original or a copy of the notarized and legalised copies (if required by the Flag State) of the Existing Charterer's power of attorney); and
|
|
(ii)
|
the original (if required by the Flag State) or a copy of the protocol of delivery and acceptance duly executed by the Existing Charterer and the Charterers;
|
|
(e)
|
unconditionally delivered by the Charterers (in their capacity as sellers) to the Owners (in their capacity as buyers) pursuant to the terms of the MOA, where such documents shall
include without limitation:
|
|
(i)
|
a certificate or transcript or an email confirmation issued by the competent authorities of the Flag State on the date of Delivery evidencing the Charterers' ownership of the Vessel
and that the Vessel is free from registered encumbrances and mortgages;
|
|
(ii)
|
where applicable, the original (if required by the Flag State) or a copy of the notarized and legalized (if required by the Flag State) copies of the bill of sale duly executed by
the Charterers (and where executed by an attorney of the Charterers, together with such original or a copy of the notarized and legalised copies (if required by the Flag State) of the Charterers' power of attorney); and
|
|
(iii)
|
where applicable, the original (if required by the Flag State) or a copy of the protocol of delivery and acceptance duly executed by the Charterers and the Owners; and
|
|
(f)
|
delivered to the Weco Charterer in accordance with the Weco Charter.
|
|
3.2
|
The commercial invoice of the Vessel.
|
|
4
|
Deed of Release
|
|
5
|
Legal opinions
|
|
5.1
|
|
5.2
|
|
1
|
Security Interests
|
|
2
|
Legal opinions
|
|
3
|
Insurances
|
|
3.1
|
Not later than five (5) Business Days after the Commencement Date, receipt of copies of the executed letters of undertaking and certificates of entry (as the case may be) relating
to insurances as set out in Clause 39 - (Insurance) acknowledged by the relevant insurer, insurance broker, protection and indemnity association or war risks association (as the case may be),
each in the agreed form under paragraph 5.2 of Part A of Schedule 2 of this Charter.
|
|
3.2
|
Not later than ten (10) Business Days after the Commencement Date, the signed insurance report in the form agreed under paragraph 5 of Part A of Schedule 2 of this Charter.
|
|
OWNERS
|
|||
|
SIGNED by
|
)
|
/s/ CUI Wanying |
|
|
duly authorized
|
) | CUI Wanying |
|
|
for and on behalf of
|
)
|
Attorney-in-fact |
|
|
SEA 179 LEASING CO. LIMITED
|
) | ||
|
|
) | ||
|
in the presence of:
|
/s/ So Yuet Sum Serena |
)
|
|
|
Witness' signature:
|
So Yuet Sum Serena |
)
|
|
|
Witness' name:
|
Suites 4610-4619 Jardine House |
) | |
|
Witness' address:
|
1 Connaught Place, Hong Kong |
)
|
|
|
CHARTERERS
|
|||
|
SIGNED by
|
)
|
/s/ Alexandros Tsirikos |
|
|
duly authorized
|
) | Alexandros Tsirikos | |
|
for and on behalf of
|
)
|
Attomey-in-Fact |
|
|
PCH DREAMING INC.
|
)
|
||
|
|
) | ||
|
in the presence of:
|
)
|
||
|
Witness' signature:
|
/s/ Dimitra Karkaletsi |
)
|
|
|
Witness' name:
|
Dimitra Karkaletsi | ) | |
|
Witness' address:
|
1 Vasilissos Sofias Street |
)
|
|
| & Meg. Alexandrou Street, |
|||
| 15124 Maroussi-Athens, Greece |
|||
| Clause |
Index | Page |
|
1
|
Interpretation
|
1
|
|
2
|
Guarantee
|
2
|
|
3
|
Liability as Principal and Independent Debtor
|
3
|
|
4
|
Expenses
|
3
|
|
5
|
Adjustment of Transactions
|
4
|
|
6
|
Payments
|
4
|
|
7
|
Interest
|
4
|
|
8
|
Subordination
|
5
|
|
9
|
Enforcement
|
5
|
|
10
|
Representations and Warranties
|
6
|
|
11
|
Undertakings
|
9
|
|
12
|
Judgments and Currency Indemnity
|
15
|
|
13
|
Supplemental
|
16
|
|
14
|
Assignment
|
18
|
|
15
|
Notices
|
18
|
|
16
|
Invalidity of Bareboat Charter
|
19
|
|
17
|
Governing Law and Enforcement
|
19
|
|
Schedules
|
||
|
Schedule 1 Form of compliance Certificate
|
21
|
|
| (1) |
| (2) |
| (B) |
The Guarantor is the shareholder of the Charterer and holds all of the issued and outstanding shares in the Charterer.
|
| (C) |
The execution and delivery to the Owner of this Guarantee is one of the conditions to the chartering of the Vessel under the Bareboat Charter.
|
| (D) |
This Guarantee is the Guarantee referred to in the Bareboat Charter.
|
| 1 |
INTERPRETATION
|
| 1.1 |
Defined expressions
|
| 1.2 |
Construction of certain terms
|
| (a) |
cast, or control the casting of, more than 51 per cent, of the maximum number of votes that might be cast at a general meeting of such company;
|
| (b) |
appoint or remove all, or the majority, of the directors or other equivalent officers of such company; or
|
| (c) |
give directions with respect to the operating and financial policies of such company with which the directors or other equivalent officers of such company are obliged to comply.
|
| 2 |
GUARANTEE
|
| 2.1 |
Guarantee and indemnity
|
| (a) |
guarantees the due payment of all amounts payable by each other Relevant Person under or in connection to each Leasing Document to which such Relevant Person is a party;
|
| (b) |
undertakes to pay to the Owner on the Owner's demand any such amount which is not paid by that Relevant Person when due and payable under or in connection to that Leasing Document;
|
| (c) |
guarantees the punctual performance by that Relevant Person of all that Relevant Person's obligations under or in connection with that Leasing Document; and
|
| 2.2 |
No limit on number of demands
|
| 2.3 |
Guarantee of whole amount
|
| 3 |
LIABILITY AS PRINCIPAL AND INDEPENDENT DEBTOR
|
| 3.1 |
Principal and independent debtor
|
| 3.2 |
Waiver of rights and defences
|
| (a) |
any amendment or supplement being made to the Bareboat Charter or any other Leasing Document;
|
| (b) |
any arrangement or concession (including a rescheduling or acceptance of partial payments) relating to, or affecting, the Bareboat Charter or any other Leasing Document;
|
| (c) |
any release or loss (even though negligent) of any right or Security Interest created by any Leasing Document;
|
| (e) |
the Bareboat Charter or any other Leasing Document now being or later becoming void, unenforceable, illegal or invalid or otherwise defective for any reason, including a neglect to register it.
|
| 4 |
EXPENSES
|
| 4.1 |
Costs of preservation of rights, enforcement etc
|
| 4.2 |
Fees and expenses payable under Leasing Documents
|
| 5 |
ADJUSTMENT OF TRANSACTIONS
|
| 5.1 |
Reinstatement of obligation to pay
|
| 6 |
PAYMENTS
|
| 6.1 |
Method of payments
|
| (a) |
in immediately available funds;
|
| (b) |
to such account as the Owner may from time to time notify to the Guarantor;
|
| (c) |
without any form of set‑off, cross‑claim or condition; and
|
| 6.2 |
Grossing-up for taxes
|
| 6.3 |
Indemnity and evidence of payment of taxes
|
| 7 |
INTEREST
|
| 7.1 |
Accrual of interest
|
| 7.2 |
Calculation of interest
|
| 8 |
SUBORDINATION
|
| 8.1 |
Subordination of rights of Guarantor
|
| (a) |
claim, or in a bankruptcy of that Relevant Person prove for, any amount payable to the Guarantor by that Relevant Person, whether in respect of this Guarantee or any other transaction;
|
| (b) |
take or enforce any Security Interest for any such amount;
|
| (c) |
claim to set-off any such amount against any amount payable by the Guarantor to that Relevant Person; or
|
| (d) |
claim any subrogation or other right in respect of any Leasing Document or any sum received or recovered by the Owner under such Leasing Document.
|
| 9 |
ENFORCEMENT
|
| 9.1 |
No requirement to commence proceedings against other Relevant Person
|
| 9.2 |
Conclusive evidence of certain matters
|
| (b) |
any statement or admission of any other Relevant Person in connection with the Bareboat Charter or any other Leasing Document,
|
| 10 |
REPRESENTATIONS AND WARRANTIES
|
| 10.1 |
General
|
| 10.2 |
Status
|
| (a) |
The Guarantor is duly incorporated and validly existing and in good standing under the laws of the Marshall Islands.
|
| (b) |
The Guarantor is not a FATCA foreign financial institution ("FFI") or a US Tax Obligor.
|
| 10.3 |
Corporate power
|
| (a) |
to execute this Guarantee or any other Leasing Document to which it is a party; and
|
| (b) |
to make all the payments contemplated by, and to comply with, this Guarantee or any other Leasing Document to which it is a party.
|
| 10.4 |
Consents in force
|
| 10.5 |
No conflicts
|
| (a) |
any law or regulation applicable to it; or
|
| (b) |
the constitutional documents of the Guarantor; or
|
| (c) |
any contractual or other obligation or restriction which is binding on the Guarantor or any of its assets.
|
| 10.6 |
Legal, valid and binding obligations
|
| 10.7 |
Governing law
|
| 10.8 |
Immunity
|
| 10.9 |
Pari passu ranking
|
| 10.10 |
Legal or administrative action
|
| 10.11 |
No insolvency
|
| 10.12 |
Tax obligor and place of business
|
| 10.13 |
No withholding taxes
|
| 10.14 |
Taxes paid
|
| 10.15 |
No default
|
| 10.16 |
Information
|
| 10.17 |
No litigation
|
| 10.18 |
Sanctions
|
| (a) |
No Relevant Person, nor any of their respective directors, officers, or employees, is a Prohibited Person.
|
| (i) |
prevent and detect incidences of bribery and corruption, money laundering and terrorism financing; and
|
| 10.19 |
Environmental Laws
|
| 10.20 |
Environmental Claim
|
| 10.21 |
Environmental Incident
|
| 10.22 |
| 10.23 |
Status of the Guarantor
|
| (a) |
Save for permitted under the Bareboat Charter, the shares of the Guarantor are traded on the NASDAQ or Over the Counter (OTC); and
|
| (b) |
the Guarantor is an entity reporting with the U.S. Securities and Exchange Commission.
|
| 11 |
UNDERTAKINGS
|
| 11.1 |
General
|
| 11.2 |
Information provided to be accurate
|
| 11.3 |
Provision of financial statements
|
| (b) |
as soon as possible, but in no event later than ninety (90) days after the end of each half-year, the unaudited semi-annual accounts of the Charterers for that half-year;
|
| 11.4 |
Form of financial statements
|
| (a) |
be prepared in accordance with all applicable laws and generally accepted accounting principles in the United States consistently applied;
|
| (c) |
fully disclose or provide for all significant liabilities of the Group; and
|
| (d) |
If not in the English language, be accompanied by an English translation duly certified as to its correctness.
|
| 11.5 |
Shareholder and creditor notices
|
| 11.6 |
Consents
|
| 11.7 |
Valid obligations
|
| 11.8 |
Notification of legal or administrative action
|
| 11.9 |
Notification of damage or default
|
| (b) |
will, and will procure that each other Relevant Person will, notify the Owner immediately of the occurrence of any Termination Event,
|
| 11.10 |
Additional information
|
| (a) |
to themselves and/or the Vessel (including, but not limited to the condition, location and employment status of the Vessel); or
|
| (b) |
to any other matter relevant to, or to any provision of any Leasing Document to which it is a party,
|
| 11.11 |
Compliance with operational laws
|
| 11.12 |
Compliance with other laws
|
| (b) |
The Guarantor:
|
| (d) |
The Guarantor shall, and shall procure that each other Relevant Person and their respective officers, directors and employees, will:
|
| (i) |
conduct its business in compliance with all Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and/or Business Ethics Laws;
|
| (ii) |
maintain systems, controls, policies and procedures designed to promote and achieve ongoing compliance with Anti-Money Laundering Laws, Anti-Terrorism Financing Laws and/or Business Ethics Laws;
|
| 11.13 |
No Security Interests
|
| 11.14 |
Financial covenants
|
| (a) |
The Guarantor shall ensure that, at any time during the Security Period, the Guarantor's Leverage Ratio shall not be more than seventy five per cent (75%).
|
| (a) |
the Total Net Debt; and
|
| (b) |
the aggregate Market Value of all Fleet Vessels adjusted, in each case, to reflect the percentage of ownership by the Guarantor of each such Fleet Vessel.
|
| (a) |
subject to sub-paragraph (b) below, the arithmetic mean of the valuations shown by two (2) valuation reports prepared:
|
| (i) |
on a date no later than thirty (30) days after the Market Value Test Date;
|
| (ii) |
with or without physical inspection of that Vessel;
|
| 11.15 |
Compliance Certificate
|
| 11.16 |
Negative Pledge
|
| (a) |
| 11.17 |
No disposal of assets, change of business
|
| (b) |
make any substantial change (or any change, in the case of the Charterer) to the nature of their respective business or corporate structure from that existing as at the date of this Guarantee.
|
| 11.18 |
No merger etc
|
| 11.19 |
FATCA
|
| 11.20 |
No payment of dividend
|
| 11.21 |
Notification of Financial Indebtedness
|
| 12 |
JUDGMENTS AND CURRENCY INDEMNITY
|
| 12.1 |
Judgments relating to Bareboat Charter and other Leasing Documents
|
| 12.2 |
Currency indemnity
|
| (a) |
making or lodging any claim or proof against the Guarantor, whether in its liquidation, any arrangement involving it or otherwise; or
|
| (b) |
obtaining an order, judgment or award from any court or other tribunal; or
|
| (c) |
enforcing any such order, judgment or award;
|
| 13 |
SUPPLEMENTAL
|
| 13.1 |
Continuing guarantee
|
| 13.2 |
Rights cumulative, non-exclusive
|
| 13.3 |
No impairment of rights under Guarantee
|
| 13.4 |
Severability of provisions
|
| 13.5 |
Guarantee not affected by other Security Interests
|
| 13.6 |
Guarantor bound by Bareboat Charter and other Leasing Documents
|
| 13.7 |
Applicability of provisions of Guarantee to other rights
|
| 13.8 |
Third party rights
|
| 13.9 |
Counterpart
|
| 13.10 |
FATCA Information
|
| (a) |
Subject to paragraph (c) below, each Party shall, on the date of the Bareboat Charter, and thereafter within ten (10) Business Days of a reasonable request by the other Party:
|
| (i) |
confirm to that other party whether it is a FATCA Exempt Party or is not a FATCA Exempt Party; and
|
| 14 |
ASSIGNMENT
|
| 14.1 |
Assignment by Owner
|
| 14.2 |
Assignment by Guarantor
|
| 15 |
NOTICES
|
| 15.1 |
Notices to Guarantor
|
| 15.2 |
Validity of demands
|
| (a) |
on the date on which the amount to which it relates is payable by the Relevant Person under the Leasing Document to which it is a party;
|
| (b) |
| 15.3 |
Notices to Owner
|
| 16 |
INVALIDITY OF BAREBOAT CHARTER
|
| 16.1 |
Invalidity of Bareboat Charter or other Leasing Documents
|
| 17 |
GOVERNING LAW AND ARBITRATION
|
| 17.1 |
Governing law
|
| 17.2 |
Arbitration
|
| (c) |
Where the reference is to three arbitrators the procedure for making appointments shall be in accordance with the procedure for full arbitration stated above.
|
| (d) |
The language of the arbitration shall be English.
|
|
Date:
|
|
|
| 3 |
We confirm that, at any time during the Security Period, Leverage Ratio was not more than 75 per cent (75%).
|
|
Signed:
|
|
|
|
GUARANTOR
|
|||
|
EXECUTED AS A DEED
|
)
|
||
|
by TOP SHIPS INC.
|
)
|
||
|
acting by ALEXANDROS TSIRIKOS
|
)
|
/s/ Alexandros Tsirikos |
|
|
being an attorney-in-fact
|
)
|
||
|
in the presence of:
|
)
|
||
|
)
|
|||
|
)
|
|||
|
Witness' signature:
|
)
|
/s/ Dimitra Karkaletsi |
|
|
Witness' name:
|
Dimitra Karkaletsi |
)
|
|
|
Witness' address:
|
1 Vasilissos Sofias Street |
)
|
|
| & Meg. Alexandrou Street, |
|||
| 15124 Maroussi-Athens, Greece |
|||
|
OWNER
|
|||
|
SIGNED, SEALED AND DELIVERED
|
)
|
||
|
by SEA 179 LEASING CO. LIMITED
|
)
|
||
|
acting by CUI Wanying
|
)
|
/s/ CUI Wanying | |
|
being an attorney-in-fact
|
)
|
||
|
)
|
|||
|
in the presence of:
|
)
|
||
|
)
|
|||
|
)
|
|||
|
Witness' signature:
|
/s/ So Yuet Sum Serena |
)
|
|
|
Witness' name:
|
So Yuet Sum Serena |
)
|
|
|
Witness' address:
|
Suites 4610-4619 Jardine House |
)
|
|
| 1 Connaught Place, Hong Kong |
|||
|
|
CMBFL Top Ships II
Signature page to Guarantee – Eco Marina Del Rey
|
| - |
The HSBC Loan. The Company has performed all obligations required to be performed by it and is in compliance with all debt covenants with respect to the HSBC Loan, including the payment of capital and interest (true and complete evidence
of which has been provided to the Buyer). The Seller has delivered or made available to the Buyer true and complete copies, including all amendments and supplements thereof, of the HSBC Loan, the HSBC
Share Pledge and all other security documents relating to its or its affiliates obligations thereunder.
|
|
If to the Seller:
|
Via Arona 3, 7500
St. Moritz, Switzerland
Email:
|
|
If to the Buyer:
|
c/o Top Ships Inc.
20 Iouliou Kaisara Str, 19002
Paiania, Athens-Greece
Attention: Alexandros Tsirikos
Facsimile:
Email:
|
|
With a copy to (which shall not constitute notice):
|
Watson Farley & Williams LLP
120 West 45th Street
New York, NY 10036
Attn: Will Vogel
|
|
BUYER:
|
||
|
By:
|
/s/ Alexandros Tsirikos | |
|
Name:
|
Alexandros Tsirikos
|
|
|
Title:
|
Director
|
|
|
SELLER
|
||
|
By:
|
/s/ Evangelos J. Pistiolis | |
|
Name:
|
Evangelos J. Pistiolis
|
|
| TOP SHIPS INC, in respect Section 1.2(i) only | ||
|
By:
|
/s/ Alexandros Tsirikos | |
|
Name:
|
Alexandros Tsirikos
|
|
|
Title:
|
Chief Financial Officer, Director
|
|

| - |
the Newbuilding Contract with SANLORENZO SPA for the building of the Vessel (as set forth in Schedule A). The Company has performed all obligations required to be performed by it and is in compliance with all the terms and
conditions contained therein. The Seller has delivered or made available to the Buyer true and complete copies, including all amendments and supplements thereof, of the Newbuilding Contract.
|
|
If to the Seller:
|
Via Arona 3, 7500
St. Moritz, Switzerland
Email:
|
|
If to the Buyer:
|
c/o Top Ships Inc.
20 Iouliou Kaisara Str, 19002
Paiania, Athens-Greece
Attention: Alexandros Tsirikos
Facsimile:
Email:
|
|
With a copy to (which shall not constitute notice):
|
Watson Farley & Williams LLP
120 West 45th Street
New York, NY 10036
Attn: Will Vogel
|
|
BUYER:
|
||
|
By:
|
/s/ Alexandros Tsirikos
|
|
|
Name:
|
Alexandros Tsirikos
|
|
|
Title:
|
President and Director
|
|
|
SELLER
|
||
|
By:
|
/s/ Evangelos J. Pistiolis
|
|
|
Name:
|
Evangelos J. Pistiolis
|
|

|
1
|
Definitions and Interpretation
|
1
|
|
2
|
Subject of Contract
|
2
|
|
3
|
Contract Price and Payment
|
5
|
|
4
|
Property
|
8
|
|
5
|
Buyer’s Decisions and Buyer’s Supplies
|
8
|
|
6
|
Buyer’s Right of Inspection
|
10
|
|
7
|
Modifications
|
13
|
|
8
|
Acceptance Sea Trials
|
15
|
|
9
|
Delivery of the Yacht
|
18
|
|
10
|
Liquidated Damages
|
21
|
|
11
|
Performance Warranties
|
22
|
|
12
|
Risk and Insurance
|
25
|
|
13
|
Default by the Buyer
|
26
|
|
14
|
Default by the Builder
|
29
|
|
15
|
Limitations
|
30
|
|
16
|
Warranty
|
31
|
|
17
|
Assignment
|
34
|
|
18
|
Intellectual Property
|
34
|
|
19
|
Patent Infringement
|
35
|
|
20
|
Law and Jurisdiction
|
35
|
|
21
|
Notices
|
36
|
|
22
|
General Provisions
|
37
|
|
Schedule 1 : Specifications
|
41
|
|
|
Schedule 2 : General Arrangement Plan
|
42
|
|
|
Schedule 3 : Change Order Form
|
43
|
|
|
Schedule 4 : Protocol of Final Delivery and Acceptance
|
45
|
|
|
Schedule 5 : Form of Milestone Certificate
|
46
|
|
|
Schedule 6 : Buyer’s Decision List
|
47
|
|
|
Schedule 7 : Form of Refund Guarantee
|
48
|
|
| (1) |
Sanlorenzo S.P.A., a company duly organised and existing in Italy whose registered office is at Via Armezzone 3, Ameglia (La Spezia) Italy, with tax code No. 00142240464, duly represented by its
Executive Chairman and Chief Executive Officer, Mr Massimo Perotti (the Builder); and
|
| (2) |
Roman Explorer Inc. with address in Marshall Islands at the Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Republic of the Marshall Islands, for itself and its legal
representatives, successors and assigns (the Buyer)
|
| (A) |
The Builder and the Buyer executed on 11 September 2023 a letter of intent (the LOI) relating to the purchase by the Buyer of a 60.00 metre motor yacht model 1150Exp with Hull No. 158, to be
constructed by the Builder.
|
| (B) |
The Builder and the Buyer, hereby agree as follows:
|
| 1 |
Definitions and Interpretation
|
| 2 |
Subject of Contract
|
| 2.1 |
Yacht’s Description
|
| 2.1.1 |
The Builder undertakes to design, engineer, build, outfit, launch, complete and deliver to the Buyer one (1) Sanlorenzo 60.00 m Motor Yacht more fully described in Clause 2.1.6 and provisionally
known as Hull No. 158 (the Yacht) and the Buyer agrees to purchase and accept delivery of the same for the Contract Price and otherwise upon and subject to the terms and conditions of this Contract,
the Specifications and the General Arrangement Plan which are annexed hereto at Schedule 1 and Schedule 2 which form an integral part of this Contract.
|
| 2.1.2 |
The quality of workmanship and finish of the Yacht’s interior will be performed in accordance with first class Italian yacht building standards and in line with the Builder’s highest standards of quality for this type/size of Yacht and,
as a minimum standard, reference shall also be made to the MY Para Bellvm, SLM146/500Exp (the Reference Yacht) but being agreed that this provision only
relates to the quality of workmanship and finish and does not provide for the duplication of outfit, installations or interior décor elements, furniture, fabrics and/or materials employed by the Builder on board the Reference Yacht.
|
| 2.1.3 |
The Parties are familiar with the quality contemplated by the Reference Yacht and hereby acknowledge that the same is reflected in the Specifications.
|
| 2.1.4 |
The Specifications consist of the following documents:
|
| (a) |
the Sales Specifications (Annex A1) and Spec. Review (Annex A2);
|
| (b) |
the List of Variations (Annex B);
|
| (c) |
the Décor Specification (Annex C1) and Crew Area Book (Annex C2);
|
| (d) |
the Entertainment System Spec. (Annex D)
|
| (e) |
the Nav. & Com. Spec. (Annex E)
|
| (f) |
the Book of STD Drawings (Annex F)
|
| (g) |
Domestic Appliances Spec. (Annex G)
|
| 2.1.5 |
In the event of any conflict between the Contract and the Specifications and/or General Arrangement Plan the following order of precedence shall be applied:
|
| - |
the Contract;
|
| - |
the Specifications; and
|
| - |
the General Arrangement Plan.
|
| 2.1.6 |
The Yacht shall have the dimensions and characteristics stated in the Specifications, including the following main particulars:
|
|
-
|
length overall
|
Approximately 60.00 m
|
|
-
|
breadth overall
|
Approximately 10,80 m
|
|
-
|
draft amidship
|
Approximately 5,40 m
|
|
-
|
gross tonnage
|
Approximately 1150 GT
|
|
-
|
maximum speed at half load displacement
|
16 knots
|
|
-
|
main engines
|
2 x MTU 12V 4000 M63
|
| 2.1.7 |
The Builder shall design, build, outfit and complete the Yacht in accordance with first class Italian yacht building standards.
|
| 2.2 |
Subcontracting
|
| 2.2.1 |
The Builder shall be entitled to subcontract any parts (but not the whole) of the Works for the construction of the Yacht to reputable, creditworthy and suitably qualified specialist sub-contractors, provided that the Builder shall
nevertheless remain responsible towards the Buyer for all work undertaken by sub-contractors and shall ensure that all Work so undertaken is in accordance with the terms and conditions of this Contract.
|
| 2.2.2 |
All contacts and communications with the Builder’s suppliers and sub-contractors shall be made by the Builder only and any instructions/orders will only come from the Builder directly. The Buyer may communicate with a sub-contractor
subject to the Builder’s prior consent and shall not in any way interfere or disrupt the Works and the construction process. For the avoidance of doubt all contact with the Builder’s suppliers concerning supplies intended for the Yacht
under this Contract shall be made exclusively by and through the Builder.
|
| 2.3 |
Classification and Flag
|
| 2.3.1 |
The Yacht shall comply with the laws, rules, regulations and enactments as stated in the Specifications and as published by the Classification Society and by the Regulatory Bodies as in force at the Applicable Date.
|
| 2.3.2 |
The Yacht shall be built under the survey of the Classification Society to achieve the following Class notation:
|
“ 100 A1 SSC, Yacht, Mono, G6 |
| 2.3.3 |
The Builder shall appoint and retain the Classification Society and submit all construction drawings and calculations as necessary to the Classification Society for approval. Classification survey and testing charges relating to the
design, construction, and certification (in compliance with the terms of this Contract and the Specifications) of the Yacht shall be for the Builder’s account.
|
| 2.3.4 |
Save as provided at Clause 7.3 below, the Builder will not be obliged to construct the Yacht to comply to the changes to rules and regulations that come into force after the Applicable Date.
|
| 2.3.5 |
Registration of the Yacht with the Flag State on Delivery shall be for the account of the Buyer.
|
| 2.3.6 |
In order to assist the Buyer, at the request of and at no additional cost to the Buyer, the Builder shall provide to the Buyer immediately prior to Delivery of the Yacht specifically requested defaced or non-defaced (where possible)
copies of the delivery documents necessary to assist the pre-registration of the Yacht with the Flag State by the Buyer.
|
| 2.3.7 |
The Flag State shall not be altered until the Delivery and acceptance of the Yacht as mentioned at Clause 9. The decision of the Classification Society, and other Regulatory Bodies (as the case may be) shall be final and binding on both
Parties as to the Yacht’s compliance or non-compliance with the relevant rules and regulations observance of which is controlled by (as the case may be) the Classification Society or any other Regulatory Bodies.
|
| 3 |
Contract Price and Payment
|
| 3.1 |
Contract Price
|
| 3.1.1 |
The price of the Yacht (the Contract Price) is agreed as € 49.000.000,00 (forty-nine million Euros) and the Builder acknowledges that the Buyer has already paid on account of the Contract Price €
1.000.000 (one million Euros) (the Deposit) on 27 September 2023 in accordance with the terms of the LOI. The Contract Price may be subject to variations in accordance with Clause 3.1.3, Clause 7 (Modifications), Clause 10.1 (Delay) and Clause 11 (Performance Warranties) and the
relevant provisions hereof relating to the charging of interest for late payment by the Buyer, but save for these references the Contract Price is fixed.
|
| 3.1.2 |
The Contract Price is exclusive of all value added tax, sales tax, customs and excise duty chargeable in or by the Italian Republic in respect of the sale, supply or delivery of the Yacht. If the Buyer considers that the Builder should
not be liable to charge value added tax then it will be the Buyer’s responsibility to take all such steps and provide all such evidence as the Builder may reasonably require to ensure and show that this is the case under the applicable
rules. If the Buyer considers that value added tax shall not be applicable because the Buyer intends to export the Yacht outside the European Union, then in such case the Buyer agrees to deliver to the Builder within and no later than sixty
(60) Days from Delivery the following documents: (i) copy of the Yacht’s registration certificate with a non-EU flag, (ii) copy of the constitutional documents of the Yacht’s owning company (being a non-EU based company), (iii) official
written evidence that the Yacht has entered a non-EU port, stamped by the competent port authority and (iv) evidence or a declaration from the Buyer confirming that the Yacht’s beneficial owner is a non-EU resident. The Buyer hereby
guarantees to indemnify and hereby indemnifies the Builder for the payment of the same.
|
| 3.1.3 |
If, at the end of each calendar Year following the date/Year of the Building Contract (i.e. at the end of each calendar Year of 2024, 2025 and 2026), the official Italian consumer all-item price index for the whole Nation (“CPI”), as
determined by the Italian National Bureau of Statistics’ (“ISTAT”), is determined by ISTAT to be greater than 3% (the “Threshold”) for such calendar Year, the Builder shall be entitled to increase the Contract Price by a proportion equal to
50% of the excess of the CPI above the Threshold whereby Buyer’s share shall be up to a maximum capped amount equal to € 500.000 (five hundred thousand Euros), subject to providing relevant written notice to the Buyer together with
appropriate documentary evidence of such official determination of the CPI by ISTAT for the relevant calendar Year. Similarly, if the CPI for a corresponding calendar Year as aforesaid is lower than the Threshold, the Buyer shall be
entitled to decrease the Contract Price by a proportion equal to 50% of such shortfall whereby Buyer’s share shall be up to a maximum capped amount equal to € 500.000 (five hundred thousand Euros) by providing to the Builder relevant
written notice. The Builder shall provide the Buyer with the appropriate documentary evidence of the official determination of the CPI by ISTAT for each of the aforesaid relevant calendar Years as soon as such determination is made and in
any case no later than the 31st March of the calendar Year that follows the Year to which the determined CPI refers. Any such notice by the Builder for the increase of the Contract Price must be tendered latest by the 20th April of the
calendar Year that follows the Year to which the determined CPI refers, after which the right of the Builder to increase the Contract Price shall be automatically waived, the relevant right being lost.
|
| 3.2 |
Payment Schedule
|
| 3.2.1 |
Payment of the Contract Price shall be made by the Buyer to the Builder by the following instalments and in accordance with the following milestones of the construction programme:
|
|
a)
|
€ 1.000.000
|
Deposit already paid on 27 September 2023 upon signing of the LOI;
|
|||
|
b)
|
€ 2.000.000
|
Upon signing of this Contract.
|
|||
|
c)
|
€ 2.000.000
|
Upon beginning of hull nesting drawing issuing but not earlier than 10 June 2024.
|
|||
|
d)
|
€ 1.000.000
|
Upon substantial commencement of steel plates cutting of hull central blocks but not earlier than10 September 2024.
|
|||
|
e)
|
€ 1.000.000
|
Upon substantial completion of hull central body single blocks (excluded aft & forward block) but not earlier than 15 December 2024.
|
|||
|
f)
|
€ 3.000.000
|
Upon the main engines being placed on board on their seatings, not earlier than 10 June 2025.
|
|||
|
g)
|
€ 3.500.000
|
Upon commencement of internal crew wall erection not earlier than 10 December 2025
|
|||
|
h)
|
€ 9.000.000
|
Upon commencement of furniture installation on the lower deck guest area but not earlier than 10 June 2026.
|
|||
|
i)
|
€ 9.000.000
|
Upon SD and OD teak decks being laid down excluded staircases, steps, hard top supports floor and scuppers margin planks but not earlier than 10 December 2026.
|
|||
|
i)
|
€ 8.000.000
|
Upon launch of the Yacht but not earlier than 28 February 2027 provided that if the Scheduled Delivery Date on account of delays known at the time of the launch of the Yacht has been extended, such date will be extended for the same
amount of Days.
|
|||
|
j)
|
€ 9.500.000 (subject to any adjustments of the Contract Price pursuant to the terms of this Contract).
|
Upon Delivery of the Yacht
|
| 3.3 |
Payment Terms
|
| 3.3.1 |
The foregoing instalments other than the first, the second and the last instalment will become due and payable within three (3) Banking Days after endorsement by the Buyer’s Representative of the relevant milestone certificate in the
form attached hereto as Schedule 5 stating that the relevant construction milestone has been completed in accordance with this Contract (the Due Date). If the Buyer’s Representative declines or fails
to endorse any such milestone certificate within three (3) Banking Days of receipt, then the Builder shall be entitled (provided the Buyer has not submitted the matter to the Technical Expert referred to in Clause 20.1.3) to submit the Milestone Certificate for signature by the Classification Society and the Buyer shall accept the relevant milestone certificate so signed as valid and binding and with the same force and effect as a
milestone certificate endorsed by the Buyer’s Representative.
|
| 3.3.2 |
Except for the instalments described under Clause 3.2.1 letter a) and b) above, the Builder will give the Buyer at least five (5) Banking Days’ notice of the date on which each payment is expected to become due in accordance with the
above payment schedule. The Builder will issue an invoice for each instalment as aforesaid.
|
| 3.3.3 |
All payments made by the Buyer before the Yacht is delivered and accepted are in the nature of advances to the Builder and are liable to be refunded to the Buyer on lawful termination of this Contract subject to and in accordance with
the provisions of this Contract.
|
| 3.3.4 |
It is a fundamental term of this Contract that the Builder’s obligation to reimburse all payments made by the Buyer to the Builder on account of the Contract Price in accordance with Clause 3.2.1 above, but with the exclusion of the
instalment described under Clause 3.2.1 letter (j), shall be secured under and pursuant to refund guarantees issued by a First Class International Bank (the Refund Guarantee(s)) and the form and
substance of such Refund Guarantees to be in the terms of the draft annexed hereto at Schedule 7.
|
| 3.3.5 |
Notwithstanding anything to the contrary contained in this Contract, the Buyer shall be under no obligation to pay to the Builder any of the instalments of the Contract Price specified at Clause 3.2.1 above (but excluding always the
instalment described at Clause 3.2.1 letter (j)) unless and until a Refund Guarantee for an amount equal to such relevant instalment shall have been issued and delivered by the Builder to the Buyer.
|
| 3.3.6 |
The Builder will be responsible for arranging the Refund Guarantees. The cost for placing and maintaining the Refund Guarantees will be for the Buyer’s account and such cost for the Buyer shall be capped at a maximum of 0,4% calculated
on an annual basis on the amounts being secured from time to time. Any cost over such capped amount shall be for the account of the Builder.
|
| 3.4 |
Payment for Modifications
|
| 3.4.1 |
Unless otherwise agreed in writing, payment for any modification under Clause 7 will be made as follows:
|
| (a) |
50% within five (5) Banking Days after the modification is agreed and the relevant Change Order in the same form appended hereto as Schedule 3 is signed by both Parties; and
|
| (b) |
the remaining balance of 50% to be paid on Delivery.
|
| 3.5 |
Payment Details
|
| 3.5.1 |
Unless the Builder directs otherwise all payments must be made to the credit of the Builder’s bank account which will be communicated in writing by the Builder and confirmed by telephone.
|
| 3.5.2 |
All expenses of remitting payments will be for the Buyer’s account.
|
| 3.5.3 |
Save for any liquidated damages payable by the Builder in accordance with this Contract, all sums due and owing by the Buyer under this Contract will be paid without set-off, counterclaim or deduction on any account whatsoever.
|
| 3.5.4 |
If any sum owing to the Builder is not received by the Due Date then the Builder may charge interest thereon from the Due Date until the date of payment calculated on a daily basis at the rate three (3) percentage points above (3)
three-month Euribor from time to time.
|
| 3.5.5 |
If any sum which is properly due and payable to the Builder is not received by five (5) Banking Days after the Due Date then the period from the Due Date until payment in full is received will constitute a Permissible Delay and the
Scheduled Delivery Date will be extended accordingly and the Builder may suspend Works on the Yacht until such sum and all accrued interest thereon are received in full.
|
| 4 |
Property
|
| 4.1.1 |
The Yacht shall be registered by the Builder in the relevant Italian registry of vessels under construction under the Builder’s name and property and shall remain at all times property of the Builder until Delivery to the Buyer in
accordance with this Contract and payment by the Buyer to the Builder of any sum due to the Builder under this Contract.
|
| 4.1.2 |
Prior to Delivery and acceptance of the Yacht and payment by the Buyer to the Builder of any sum due to the Builder under this Contract, the Buyer will not be entitled at any time and to create or incur, or permit to be created or
incurred any mortgages, charges, liens or other whatsoever encumbrances on the Yacht, its materials or equipment.
|
| 5 |
Buyer’s Decisions and Buyer’s Supplies
|
| 5.1 |
Buyer’s Timetable
|
| 5.1.1 |
To enable the Builder to complete and deliver the Yacht in accordance with this Contract the Buyer is required to make and notify certain decisions, approvals and selections with respect of colours, decorative schemes, internal and
external layout of the Yacht’s living areas, furniture and other optional items (hereinafter called the Buyer’s Decisions) and to supply certain materials and equipment (hereinafter called the Buyer’s Supplies) within specific dates. The Builder is to accommodate and assist in the safe storage/embarkation of all the Buyer’s Supplies without any extra cost but excluding objects d’art and
valuables. The Buyer acknowledges that timely completion and Delivery of the Yacht by the Builder is dependent on timely notification of the Buyer’s Decisions and timely delivery of the Buyer’s Supplies, all of which must conform to the
requirements of this Contract and the Specifications.
|
| 5.1.2 |
The due date for certain of the Buyer’s Decisions is set out in the Buyer’s Decision List attached hereto as Schedule 6 and in each case not later than the due date therein indicated, the Buyer must:
|
| (a) |
notify the Builder of the Buyer’s Decisions; and
|
| (b) |
deliver all Buyer’s Supplies to the Builder in good condition, ready for immediate installation on board the Yacht.
|
| 5.1.3 |
Notification of a Buyer’s Decision must include all supporting information reasonably required to enable the Builder immediately to implement the same, as notified in advance by the Builder. Once notified to the Builder a Buyer’s
Decision will be final and binding and any subsequent variation of a Buyer’s decision will be treated as modification pursuant to Clause 7 below.
|
| 5.2 |
Buyer’s Delay
|
| 5.2.1 |
If the Buyer fails to notify the Builder of any Buyer’s Decision by the Due Date or fails to deliver in a timely manner or by the relevant date indicated from time to time by the Builder any Buyer’s Supplies which require installation
then:
|
| (a) |
the delay in completion of the Yacht caused by the Buyer’s failure will constitute a Permissible Delay and the Scheduled Delivery Date will be extended accordingly; and
|
| (b) |
the Builder may, at its sole discretion, suspend Work on any affected part of the Yacht until such notification of that Buyer’s Decision or delivery of that Buyer’s Supply is received.
|
| 5.2.2 |
Without prejudice to the above, any failure by the Buyer to notify its decision or deliver the Buyer’s Supplies as aforesaid will entitle the Builder (at any time by not less than fifteen (15) Days’ notice in writing to the Buyer) to
specify a final deadline for such notification or delivery. If the Buyer fails to comply with such notice then the Builder will be entitled, at its own discretion, to proceed with construction of the Yacht using its own reasonable judgment
on the matter to be approved, decided or selected and either without the Buyer’s Decision or without the Buyer’s Supplies in question or with such substitute materials and equipment as may reasonably be necessary in the circumstances.
|
| 5.2.3 |
The provisions of this Clause 5.2 will not apply to loose items of Buyer’s Supply not requiring to be fitted to the Yacht by the Builder. If the Buyer fails to deliver any such item by the Due Date
indicated as aforesaid and/or as otherwise required by this Clause 5 then:
|
| (a) |
the Builder will be entitled to deliver the Yacht without such item and its absence will not prevent the Yacht from being ready for delivery in accordance with this Contract; and
|
| (b) |
the Buyer must accept any consequential effect on the characteristics and performance of the Yacht (for example, increased noise levels resulting from the absence of loose furniture which would otherwise have absorbed noise).
|
| 5.3 |
Buyer’s Supplies
|
| 5.3.1 |
When received the Builder will be responsible for storing the Buyer’s Supplies and installing them on or in the Yacht, provided that the Buyer must pay the documented additional cost of insuring the Buyer’s Supplies (excluding without
limitation paintings, sculptures, art objects and the like which will be insured at the Buyer’s care and cost) having an aggregate total value greater than €500,000 (five hundred thousand Euros). When delivering Buyer’s Supplies, the Buyer
must provide all supporting information, diagrams, manuals and the like reasonably requested by the Builder to enable the Builder immediately to install and commission the same. The Builder will have no obligation to inspect or test any
Buyer’s Supplies and no responsibility for any defect therein or any adverse effect they may have on the overall design, integrity and performance of the Yacht.
|
| 5.3.2 |
Any value added tax, duties, taxes, customs, levies and other charges which might be imposed on the importation of the Buyer’s Supplies into Italy and all fees and expenses of customs agents, bonded warehouses and the like will be for
the Buyer’s account and the Buyer will indemnify the Builder against the same. The Buyer shall promptly provide the Builder with such evidence as the Builder may reasonably request to evidence the Buyer’s importation of the said Buyer’s
Supplies.
|
| 5.3.3 |
The Builder shall provide the reasonable assistance and cooperation to the Buyer in relation to the delivery of Buyer’s Supplies and storage to the Yard and the Buyer shall be entitled to request the Builder to purchase certain items of
Buyer’s Supplies directly from the relevant suppliers. The Builder will have full liberty to reasonably accept and/or reject the Buyer’s request and upon acceptance, the Builder will issue an “Additional Items of Supply Form” setting out
the price to be paid by the Buyer to the Builder with respect to the relevant item to be supplied by the Builder in accordance with this Clause 5.3.3 and any consequences, if any to the Scheduled Delivery Date based on the delivery schedule
of such item of additional supply. The Builder shall not be entitled to apply any mark-up in respect of such Buyer’s Supplies.
|
| 5.3.4 |
It is further agreed that the terms of Clause 5.2 above with respect to Permissible Delays attributable to late delivery of Buyer’s Supplies will apply to any delay that may arise with respect to the late delivery of any additional items
of supply that may be ordered from time to time by the Builder under the terms of Clause 5.3.3 above and being agreed that the Builder shall not be responsible for any delays in delivery of such items by the relevant supplier.
|
| 5.3.5 |
Additional items of supply ordered in accordance with Clause 5.3.3 will be insured in accordance with Clause 12.2.1. The Buyer will be obliged to pay any additional premium costs for any increase in the limit of cover required for such
additional items of supply.
|
| 6 |
Buyer’s Right of Inspection
|
| 6.1 |
Buyer’s Representative
|
| 6.1.1 |
The Buyer may nominate a representative (the Buyer’s Representative) who will be based at the Builder’s premises and will have access to the Yard, during normal working hours and at any other time
when work is being carried out on the Yacht, for the purpose of inspecting the Yacht during construction. The Builder will use its best and reasonable endeavours to arrange similar rights of access to the premises of sub-contractors where
substantial Works in relation to the Yacht are being carried out.
|
| 6.1.2 |
The Buyer may from time to time nominate a replacement Buyer’s Representative in accordance with this Clause 6.1 but it will be a condition of any such nomination that the replacement Buyer’s
Representative is fully briefed on all matters relevant to this Contract by his predecessor or otherwise on behalf of the Buyer.
|
| 6.1.3 |
The Buyer’s Representative may be accompanied by up to three (3) other suitably qualified persons when attending the Builder’s Yard, herein including the designated crew of the Yacht, provided that at least three (3) Banking Days’ prior
written notice must be given by the Buyer to the Builder before each visit of the Buyer’s Representative and its assistants (the Builder’s consent not to be unreasonably withheld or delayed).
|
| 6.1.4 |
The Buyer’s Representative and any other persons as aforesaid must be accompanied, whenever the Builder deems reasonably necessary, by a Builder’s authorised representative during attendances at the Yard and at any sub-contractors’
premises and while in proximity to any yachts (including the Yacht) under construction at the Yard, provided that the Builder undertakes that the appointment of such Builder’s authorised representative will not delay or hinder the Buyer’s
Representative. One office at no extra cost with internet and printing facility for the Buyer’s Representatives and crew to be arranged in facilities and office spaces owned by the Builder in close proximity of the Yard.
|
| 6.1.5 |
Within and no later than ten (10) Days from signature of this Contract the Buyer will notify to the Builder in writing all details of the appointed Buyer’s Representative who will have full authority to represent the Buyer. This Clause
6.1.5 will apply each time the Buyer nominates a replacement in accordance with Clause 6.1.2 above.
|
| 6.1.6 |
If the Builder (acting reasonably and in good faith) considers the Buyer’s Representative to be unsuitable, not performing its duties under this Contract and/or interfering with the Works, the Builder may request the Buyer to replace the
Buyer’s Representative with a substitute and suitable Buyer’s Representative and the Buyer shall give prompt consideration to the Builder’s request if the Builder’s concerns are reasonably founded.
|
| 6.1.7 |
At least forty-five (45) Days prior to Delivery, the Buyer’s appointed Captain and appointed chief engineer will be granted access to the Yard and to the Yacht in order to familiarise themselves with the Yacht and her equipment. Any
costs relating to such visits of the appointed Captain and appointed Chief Engineer will be for the Buyer’s account and the Buyer will notify the Builder in writing and at least ten (10) Days in advance before their first visit and
thereafter reasonably prior notice for any subsequent visit.
|
| 6.2 |
Builder’s Designated Personnel
|
| 6.2.1 |
The Builder shall appoint a suitably qualified and experienced project manager who is fluent in English (the Builder’s Project Manager) who shall be responsible for supervision of the construction
of the Yacht in accordance with the terms and conditions of this Contract and who shall have the authority to represent and speak on behalf of the Builder in connection with the construction of the Yacht. The Builder’s Project Manager shall
be the direct contact of the Buyer and the Buyer’s Representative for the performance and execution of this Contract. The Builder’s Project Manager shall receive on behalf of the Builder all consents, approvals, orders, instructions,
communication and information given by the Buyer or Buyer’s Representative within a reasonable time.
|
| 6.2.2 |
The Builder’s Project Manager may (from time to time) designate other personnel within the Builder’s organisation to whom the Buyer’s Representative must notify all material remarks and make all reports concerning the Yacht. The Buyer’s
Representative must not otherwise make any material remarks or give any direct instructions to any of the Builder’s employees, sub-contractor or suppliers. Approvals and/or decisions given or made by the Buyer’s Representative in writing
will be binding upon the Buyer.
|
| 6.3 |
Notification of Defects and Non Conformities
|
| 6.3.1 |
The Buyer’s Representative will notify the Builder’s designated personnel promptly of any alleged defects or non-conformities that have come to his attention, giving reasonable particulars of the nature and extent of the alleged defect
or non-conformity and (if practicable and appropriate) suggestions for rectifying the same. If any such alleged defect or non-conformity is disputed by the Builder and/or the Buyer considers that the Builder has failed to take the
necessary steps to rectify the same then either party may refer the dispute for resolution in accordance with Clause 20.
|
| 6.3.2 |
Notwithstanding anything to the contrary contained in this Contract, no failure by Buyer or the Buyer’s Representative to discover any defect or non-conformity shall relieve the Builder of its obligation to design, construct, equip,
outfit and finish the Yacht in accordance with the requirements of this Contract and the Specifications.
|
| 6.4 |
Duties, Facilities and Expense
|
| 6.4.1 |
The Buyer’s Representative will:
|
| (a) |
obey the Works rules prevailing at the Yard and the premises of sub-contractors;
|
| (b) |
perform his duties diligently and carefully and do nothing to impede or delay construction and delivery of the Yacht; and
|
| (c) |
be deemed to speak for and have authority to represent the Buyer in all matters relating to the construction of the Yacht and this Contract.
|
| 6.4.2 |
The Builder will furnish the Buyer’s Representative and his assistants with reasonable facilities at the Yard to enable them to fulfil their duties including telephone and internet connection.
|
| 6.5 |
Risk
|
| 6.5.1 |
The Buyer’s Representative shall attend the Yard and sub-contractors’ premises at the risk and expense of the Buyer and the Builder shall be under no liability whatsoever to the Buyer or the Buyer’s Representative for any death, personal
injury, loss or damage whatsoever suffered by them, including, but not limited to, any death, or personal injury of the Buyer’s Representative or any damage to or loss to or destruction of any property of the Buyer’s Representative unless
and to the extent that any such death, personal injury, damage, loss or destruction is caused by the gross negligence or reckless disregard of the probable consequences of the Builder or any sub-contractor or any of their respective
employees.
|
| 6.5.2 |
Save to the extent that any death, personal injury, damage, loss or destruction is caused by any such reckless disregard or gross negligence on the part of the Builder or any sub-contractors or any of their respective employees acting
within the scope of their employment, the Buyer shall indemnify the Builder and hold it harmless against any claims and costs whatsoever and howsoever arising which may be brought by the Buyer’s Representative as a direct result or an
indirect result of the Buyer’s Representative’s attendance at the Yard or supervision of any part to the Works.
|
| 6.5.3 |
The Buyer’s Representative and/or officers and/or crew attending the Yard from time to time shall be adequately insured under a policy covering personal injury and third party liability claims (at the Buyer’s cost) and the Buyer shall
provide the Builder with a copy of such insurance cover.
|
| 6.5.4 |
The Buyer shall be under no liability whatsoever to the Builder for any death, personal injury, loss or damage whatsoever suffered by it or its employees, sub-contractors and agents, including, but not limited to, any death, or personal
injury unless and to the extent that any such death, personal injury, damage, loss or destruction is caused by the gross negligence or reckless disregard of the probable consequences of the Buyer or any of its employees or representatives.
|
| 7 |
Modifications
|
| 7.1 |
Buyer’s Modifications
|
| 7.1.1 |
The Buyer may request, in writing, modifications to the Specifications, including the General Arrangement Plan and/or the design and construction of the Yacht as they are defined in this Contract (the Modification).
Upon receipt of a request for a Modification and unless such Modification or accumulation of such Modifications will, in the Builder’s reasonable judgement, acting in good faith, materially and adversely affect the Builder’s planning or
programme in relation to the Builder’s other commitments, the Builder shall promptly (but as soon as practicably possible) advise the Buyer of the following consequences (if any) caused by such modification (together the Consequential Effects), by means of a change order substantially in the same form appended hereto as Schedule 3 (the Change Order):
|
| (a) |
adjustment of the Contract Price;
|
| (b) |
adjustment of the Scheduled Delivery Date;
|
| (c) |
adjustment of the speed, range, noise, vibration values and/or other performance of the Yacht as defined in the Specifications;
|
| (d) |
adjustment of light ship weight (which directly impacts on the draught of the Yacht); and
|
| (e) |
any other adjustment of this Contract, the Specifications and the General Arrangement Plan or to the Buyer’s interior outfitting or the Yacht’s accommodation.
|
| 7.1.2 |
The Buyer shall have five (5) Banking Days within which to make a final decision as to whether or not to accept or reject the Change Order. Should the Buyer fail to respond within five (5) Banking Days, the Builder’s proposal shall be
deemed to be rejected and the Builder shall proceed with the construction of the Yacht as if no such Modification had been requested by the Buyer.
|
| 7.1.3 |
All material engineering time incurred in pricing and investigating any Modification shall be for the account of the Buyer whether or not the Modification is agreed by the Buyer. The Builder will provide reasonably detailed
documentation relating to the engineering cost incurred by reason of the Modification’s request.
|
| 7.1.4 |
The Buyer will use reasonable endeavours to keep the Modifications to the Specifications and to the General Arrangement Plan to a minimum. The Builder shall be entitled to continue production on the basis of the Specifications and
General Arrangement Plan until an agreement has been reached, as stated above.
|
| 7.1.5 |
The Builder will be entitled as its sole discretion to refuse any Modification request received by the Buyer in the six (6) Months falling prior to the Scheduled Delivery Date.
|
| 7.2 |
Builder’s Modifications
|
| 7.2.1 |
Subject to the Buyer’s written consent (which shall not be unreasonably withheld or delayed), the Builder will be entitled to make minor changes to the Specifications and drawings, not affecting the Yacht’s performance characteristics
under this Contract if such changes are found necessary to suit the Yard’s local conditions and facilities, the availability of materials and equipment, the introduction of improved production methods or otherwise.
|
| 7.3 |
Modifications by Regulatory Bodies and Classification Society
|
| 7.3.1 |
In the event that subsequent to the Applicable Date (in accordance with Clause 2.3) any modifications, deletions or additions are made to the laws, rules, regulations or enactments of the Regulatory
Bodies and such modifications, deletions or additions are compulsory for the Yacht, the Builder shall forthwith notify the Buyer of a Change Order according to Clause 7.1 and the Buyer shall approve it
as may be appropriate in the circumstances.
|
| 7.3.2 |
If there is a possibility of obtaining a waiver, the Buyer may, at its option, apply for a formal waiver of compliance from the Classification Society or the relevant Regulatory Body. Should such waiver be applied for, the Buyer shall
agree with the Builder a time limit after which, if the waiver has not yet been obtained, the Builder will proceed with the compulsory modifications, deletions or additions. Any documented additional cost of constructing the Yacht arising
from the application for such waiver whether or not obtained shall be for the account of the Buyer and shall be payable by the Buyer on demand, provided that the Builder undertakes to provide to the Buyer as much notice as is reasonably
possible of any such additional cost. The Scheduled Delivery Date of the Yacht may be extended by the delay to the completion of the Yacht directly caused by such application, provided always that the Builder undertakes to continue any work
on the Yacht during the waiver application which is not directly affected by the waiver application.
|
| 7.3.3 |
If there is no possibility of obtaining a waiver, or the Buyer elects not to apply for a waiver, or if an application for a waiver is finally refused, then the Modification will be treated as a compulsory Modification which the Builder
must carry out subject to agreement or determination of the Consequential Effects as hereinafter provided.
|
| 7.3.4 |
The parties will negotiate in good faith and endeavour to agree as soon as possible the Consequential Effects of any compulsory modification. If the parties cannot reach agreement on such Consequential Effects within fifteen (15) Days
after the Builder’s notification under Clause 7.3.1 then such dispute shall be referred for resolution in accordance Clause 20.1.3 (but with the exclusion of price quotes and price estimates of the
Builder which are outside the jurisdiction of the Technical Expert), but any time required to obtain such final determination shall constitute a Permissible Delay, provided that the Builder shall not suspend Works on those parts of the
construction which are unaffected by such decision.
|
| 7.4 |
Payment for adjustments of price
|
| 7.4.1 |
The adjustments to the Contract Price made under Clause 7 shall be paid by the Buyer in accordance with Clause 3.4.
|
| 7.4.2 |
For all modifications (whether voluntary or compulsory), any proposed consequential adjustments to the Contract Price will be supported by a breakdown showing the manner in which the adjustment has been calculated, including (without
limitation) such matters as the number of man-hours (labour, design and engineering personell) together with the quotations in respect of the cost of materials on top of which 10% mark-up will be added calculated on the following basis:
|
| (a) |
The labour charges are calculated as follows: €50.00 (fifty Euros) per hour for production personnel and €90.00 (ninety Euros) per hour for engineering personnel; and
|
| (b) |
All additional materials and equipment, and amounts required under subcontractors and suppliers in respect of the Modification shall be charged at the verified cost plus an agreed profit margin of ten (10) per cent (10%) net of any taxes
and import duties on such materials,
|
| 7.4.3 |
In the event of any adjustment to the Scheduled Delivery Date pursuant to a Modification, the Builder shall procure a commensurate extension to the expiry date of the Refund Guarantee issued pursuant to Clause 3.3.4 above.
|
| 8 |
Acceptance Sea Trials
|
| 8.1 |
Notice
|
| 8.1.1 |
The Builder shall provide not less than ten (10) Days’ written notice to the Buyer of the time and place of the acceptance Sea Trials (Sea Trials) of the Yacht and the Buyer shall promptly
acknowledge receipt of such notice. The Buyer shall have the right to have the Buyer’s Representative attend on board the Yacht to witness the Sea Trials and the Builder shall arrange for the attendance of representatives of the
Classification Society and, if applicable and required, representatives of the manufacturers and/ or suppliers of the Yacht’s main equipment, the Flag State and any other relevant Regulatory Bodies as may be applicable. If the Buyer or the
Buyer’s Representative does not attend any Sea Trial for any reason such Sea Trial shall be repeated with the Buyer or the Buyer’s Representative being present upon the Builder’s providing not less than ten (10) Days’ written notice to the
Buyer of the time and place of such Sea Trial and the Scheduled Delivery Date will be automatically postponed by the number of Days calculated from the date of the Builder’s first notice of Sea Trials until the date of completion of the Sea
Trial. Failure by the Buyer and/or by the Buyer’s Representative to attend shall be deemed to be a waiver by the Buyer of its right to be present and shall not invalidate such Sea Trials or the results and conclusions thereof. The Builder
may thereupon conduct the Sea Trials without the Buyer’s Representative being present and the Buyer shall accept the results of the relevant Sea Trials as being validly completed on the basis of a certificate signed by the Builder and,
where applicable, signed by the representatives of the Classification Society and/or by any relevant Regulatory Body present at the Sea Trials confirming such results, unless the Buyer or the Buyer’s Representative fail to attend such Sea
Trials for reasons of any Force Majeure Event (as defined in Clause 9.4), in which case the Sea Trials shall be subsequently scheduled in accordance with the procedure above, after the Force Majeure Event is no longer continuing and the
Scheduled Delivery Date will be postponed by an equivalent number of Days starting from the Builder’s notice under this Clause 8.1.1 until the date when the Sea Trials are carried out.
|
| 8.1.2 |
In addition, the Buyer shall be permitted to have onboard the Yacht during the Sea Trials such members of the Buyer’s crew and technical consultants as the Buyer may deem necessary to invite, provided that the number of persons attending
the Sea Trials at the Buyer’s or his Representatives invitation may not exceed five (5). The attendance of any additional person on behalf of the Buyer will be subject to the Builder’s prior written approval, such approval not to be
unreasonably withheld.
|
| 8.2 |
Weather Conditions
|
| 8.2.1 |
The Sea Trials shall be conducted under weather and sea conditions set out at Section 1.12.3 of the Specifications. Any delay in Delivery caused by delay in the Sea Trials due to weather or sea conditions not meeting the specified
weather and sea conditions for the Sea Trials shall be a Permissible Delay. The Sea Trials must take place as soon as possible following the postponements. Any delay in the Sea Trial due to adverse weather conditions shall not invalidate
notices given pursuant to Clause 8.1.1 hereto.
|
| 8.3 |
Carrying Out of Sea Trials
|
| 8.3.1 |
All trials and measurements will be conducted in the presence of representatives from the Classification Society and the Regulatory Bodies (where applicable and as the case may be) in a manner and to the extent as described in the
Specifications to establish the Yacht’s proper functioning and fulfilment of the performance parameters for the Sea Trials as set out in the Specifications and its compliance with this Contract and the Specifications. The performance of any
of the Sea Trials shall be at the risk and expense of the Builder, as will any adjustments to the Yacht’s equipment. The Builder shall bear all of the costs associated with the Sea Trials. The procedure of Sea Trials and the Sea Trials
schedule is to be submitted to the Buyer’s Representative and to the Classification Society at least ten (10) Days prior the Sea Trial’s date.
|
| 8.3.2 |
Without prejudice to the generality of the foregoing the Builder shall have the right to repeat any Sea Trial whatsoever. The Buyer shall have the right to receive at least three (3) Banking Days’ written notice of any such repeated
trials and to attend the same in accordance with Clause 8.1.2.
|
| 8.3.3 |
All expenses except those of the Buyer’s Representative and its assistant(s) in connection with the Sea Trials shall be for the account of the Builder, including without limitation all necessary crew.
|
| 8.3.4 |
Should during any Sea Trial, any breakdowns occur which entail interruption or irregular performance which can be repaired by the normal means available on board the Yacht, the Sea Trials shall be continued after repairs and shall be
valid in all respects. However, should the Yacht require to return to a port to enable the breakdown to be remedied, a further Sea Trial shall be held in respect of that part (and all items related) of the Yacht which was defective and any
other part of the Sea Trials which was not completed immediately prior to the return to port. Where such breakdown occurs as a result of a failure for which the Builder or any of its sub-contractor is liable for, the delay in Delivery of
the Yacht resulting therefrom shall not be a Permissible Delay.
|
| 8.4 |
Acceptance of Yacht
|
| 8.4.1 |
Upon completion of the Sea Trials and when the results of the Sea Trials are available and if the Builder considers the results thereof to demonstrate that the Yacht conforms to this Contract, the Builder shall immediately give the Buyer
a written notice of completion (together with a report detailing the full results of the Sea Trials), stating that the Yacht is ready for Delivery having achieved technical conformity with this Contract and the Specifications as set out at
Clause 2.1 (the Technical Conformity) save for any Minor Non-Conformities (as defined below) and accompanied by the Builder’s proposals for the rectification thereof. The Buyer, upon receipt of such
notice, must notify its acceptance or rejection of the Yacht within seven (7) Banking Days and, in the case of rejection of the Yacht, the notice must clearly state the Buyer’s reasons and give in writing full particulars of all defects and
non-conformities in the Yacht which in the Buyer’s opinion justify such rejection.
|
| 8.4.2 |
The Buyer will only be entitled to reject the Yacht on account of defects and non-conformities which (whether taken alone or in aggregate):
|
| (a) |
render the Yacht unseaworthy;
|
| (b) |
prevent the issuance of the classification certificates (free of condition and/or recommendation) by the Classification Society;
|
| (c) |
materially impair the use of the Yacht;
|
| (d) |
in the case of major machinery or equipment which breaks down or suffers any major damage and/or any kind of damage to the hull structures due to grounding and/ or heavy contact occurring prior to Delivery and which require complete
replacement and the Builder has failed to replace with new machinery or equipment;
|
| (e) |
exceed €500,000 (five hundred thousand Euros) by way of estimated rectification cost based on the Builder’s cost excluding painting and fairing; or
|
| (f) |
prevent the safe and proper operation of the Yacht’s systems or machinery.
|
| 8.4.3 |
All defects and non-conformities other than those described in Clause 8.4.2 will be treated as minor non-conformities (together the Minor Non-Conformities)
and be subject to Clause 8.5. In the event of a dispute between the Parties as to whether or not a defect or non-conformity constitutes a Minor Non-Conformity, the matter shall be referred to the
Technical Expert in accordance with Clause 20.1.3 below.
|
| 8.4.4 |
If the Buyer fails to notify either its acceptance or its rejection in accordance with this Clause 8.4 it will be deemed to have accepted the Yacht. Acceptance or deemed acceptance of the Yacht as
aforesaid will be final and binding and shall preclude the Buyer from refusing delivery on the basis of any alleged deficiency in any parts of the Yacht which were tested during the Sea Trials or any Minor Non-Conformity.
|
| 8.4.5 |
Notwithstanding anything to the contrary, if the Yacht becomes an actual, constructive, arranged or comprised total loss prior to Delivery, any deemed acceptance by the Buyer of the Yacht following to Sea Trials shall be set aside.
|
| 8.5 |
Minor Non-Conformities
|
| 8.5.1 |
Minor Non-Conformities will be rectified where possible prior to Delivery of the Yacht or as soon as reasonably practicable after Delivery of the Yacht but always on condition that the Buyer makes the Yacht available to the Builder for
that purpose.
|
| 8.5.2 |
A list of Minor Non-Conformities shall be attached to the Protocol of Final Delivery and Acceptance but Delivery of the Yacht will not be delayed on this account and the agreed list of Minor Non-Conformities attached to the Protocol of
Final Delivery and Acceptance shall be the agreed extent of the Builder’s responsibility in respect of defects discovered prior to Delivery of the Yacht. If the Builder does not accept matters considered by the Buyer to be Minor
Non-Conformities and/or the Parties are unable to agree a list as aforesaid then the Buyer will be at liberty at any time before Delivery to notify the Builder with full particulars of matters that it considers to be Minor Non-Conformities
and to reserve its rights under Clause 16 in respect thereof. Any technical dispute as to whether matters notified by the Buyer as aforesaid constitute Minor Non-Conformities will (unless otherwise
agreed) be resolved after Delivery in accordance with Clause 20.
|
| 8.6 |
Surplus Consumable Stores
|
| 8.6.1 |
Any fuel oil, furnished by the Builder for the Sea Trials and remaining on board the Yacht at the time of Delivery shall be purchased by the Buyer from the Builder at the verified original purchase price and payment effected by the Buyer
on Delivery of the Yacht.
|
| 9 |
Delivery of the Yacht
|
| 9.1 |
Scheduled Delivery Date and Readiness for Delivery
|
| 9.1.1 |
Delivery of the Yacht by the Builder to the Buyer shall take place on the Scheduled Delivery Date as the same may be extended from time to time under the terms of this Contract. In the absence of acceptance by the Buyer the Yacht will
be deemed to be ready for delivery in accordance with this Contract on the eight (8th ) Banking Day after the Yacht’s Sea Trials have been completed in
accordance with Clause 8 and the Builder has notified the results in accordance with Clause 8.4, provided that, if in accordance with that Clause 8.4 the Buyer has
notified its rejection of the Yacht on account of defects within the meaning of Clause 8.4.2, then the Yacht will be deemed ready for delivery when the Builder has rectified the defects so notified and
repeated any applicable trials.
|
| 9.2 |
Where and How Effected
|
| 9.2.1 |
Provided that the Builder and the Buyer shall have fulfilled all their obligations under this Contract in all respects and, for the avoidance of doubt simultaneously upon payment by the Buyer to the Builder of the balance of the Contract
Price and all other sums due and owing to the Builder, Delivery of the Yacht shall be effected forthwith by signing and the delivering by each of the Parties to the other of the Protocol of Final Delivery and Acceptance, on the standard
form attached hereto as Schedule 4 acknowledging delivery of the Yacht by the Builder and acceptance thereof by the Buyer. Upon signing of the Protocol of Final Delivery and Acceptance all rights, interest, title and responsibility in and
to the Yacht remaining with the Builder shall be transferred by the Builder to the Buyer.
|
| 9.2.2 |
The Yacht will be delivered EXW (Incoterms 2010) to the Buyer safely afloat at the Port of La Spezia (Italy). After Delivery to the Buyer and acceptance by the Buyer, the Yacht may remain at the Port of La Spezia (Italy) in the
Builder’s Yard but at the Buyer’s risk and under the Buyer’s insurances without any berthing fees for up to a period of one week after Delivery, save that any other cost relating to the maintenance and operation of the Yacht and other costs
relating to the staying of the Yacht at the Yard (including without limitation insurances, crew and consumables such as water, electricity, security patrols, sewage) will be for the Buyer’s account.
|
| 9.3 |
Documents to be Delivered to the Buyer
|
| 9.3.1 |
Upon delivery and acceptance of the Yacht and against payment in full of the Contract Price and all other sums due and owing to the Builder under this Contract the Builder will deliver to the Buyer the following documents:
|
| (a) |
Builder’s Certificate, notarially attested or legalised with apostille as the case may be, and (if reasonably required by the Buyer for the purposes of registering the Yacht with the Flag State) a Bill of Sale in respect of the Yacht
transferring title to the Buyer and warranting that the Yacht is free and clear of all debts, liens, mortgages and encumbrances whatsoever and notarially attested or legalised with apostille as the case may be;
|
| (b) |
Original (originals include electronic copies as issued by the relevant authorities) permanent or provisional certificates confirming the Yacht’s compliance with the requirements of the Classification Society, the Flag State and other
relevant authorities as specified in this Contract (provided that if provisional certificates are issued the Builder shall ensure that permanent certificates are issued as soon as possible and in any event prior to the expiry of the
provisional certificates);
|
| (c) |
preliminary international tonnage certificate issued by the Classification Society and final certificate to be delivered as soon as practicable but in any event no later than three (3) Months from Delivery and in any event prior to the
expiry of the preliminary certificate;
|
| (d) |
inventory of equipment and manufacturers’ spare parts, if any, as required by the Specifications;
|
| (e) |
all manuals, drawings, instructions, passwords (unless providing such passwords prejudices the warranty of the particular equipment) and in any event excluding any passwords relating to the programming of the A/V and NAVCOM systems and
other documents pertaining to the operation and maintenance of the Yacht’s machinery and equipment and it being agreed that if any of the systems warranties’ will be voided as a consequence of the Buyer
accessing the passwords, the Builder will be relieved from any obligations in respect of such system;
|
| (f) |
a copy of all manufacturers’ and suppliers’ warranties in respect of the Yacht’s main and auxiliary engines and generators;
|
| (g) |
protocol of the Yacht’s Sea Trials and the results thereof;
|
| (h) |
commercial invoice (marked as ‘fully paid subject to and upon receipt by the Builder of the balance of the Contract Price together with any other sums due to the Builder under this Contract’);
|
| (i) |
Addendum to the International Tonnage Certificate (1969);
|
| (j) |
International Tonnage Certificate;
|
| (k) |
Load Line Certificate;
|
| (l) |
Stability Booklet (endorsed by Class);
|
| (m) |
IAPP Certificates;
|
| (n) |
IOPP Certificates;
|
| (o) |
Statement of Compliance for Sewage Pollution Prevention ;
|
| (p) |
“As built” plans (class approved where applicable), drawings and specifications will be delivered by the Builder to the Buyer in PDF format provided in a USB;
|
| (q) |
Suez Canal tonnage certificate;
|
| (r) |
Panama Canal PC/UMS Documentation of Total Volume (this Certificate will be provided subject to a Change Order having been agreed and signed by both Parties otherwise the Builder will not have any obligation to provide this Certificate);
|
| (s) |
all other certificates, documents, and things expressly listed in the Specifications, as well as all certificates and documents required for the commercial use of the Yacht to the extent that these can be provided by the Builder at no
additional cost and to the extent that these documents are within the Builder’s control and responsibility; and
|
| (t) |
and any other document necessary for the registration of the Yacht (to the extent that such documents are within the Builder’s control and responsibility).
|
| 9.3.2 |
Without prejudice to the Builder’s obligations under this Contract and in particular 2.3.3., the Buyer will (on notice from the Builder) do and execute all acts, matters, things and documents
necessary on its part to enable the Builder to provide necessary certificates and documents for the Yacht including (without limitation) all necessary applications to the Flag State to register the Yacht, all in good time to enable the
Builder to complete and deliver the Yacht in accordance with this Contract. Any delay to the delivery of the Yacht caused by the Buyer in this respect will be a Permissible Delay and the Scheduled Delivery Date will be extended
accordingly.
|
| 9.3.3 |
Upon delivery and acceptance of the Yacht, the Buyer will promptly return to the Builder any original Refund Guarantees delivered by the Builder to the Buyer in accordance with this Contract.
|
| 9.4 |
Force Majeure Events
|
| 9.4.1 |
For the purpose of this Clause 9 a “Force Majeure Event” means any unforeseeable event or circumstance beyond the Builder’s reasonable control which delays or prevents the construction, completion
or Delivery of the Yacht or otherwise renders the Builder (and its sub-contractors) unable to perform any of its obligations under this Contract comprising acts of God, delays caused by governmental authorities, engagement in war or other
hostilities or preparations therefor, civil unrest, riots or insurrections, terrorism, requirements imposed by civil or military authorities, plague or other epidemics, pandemics, quarantines officially declared by the relevant local
authorities, public health emergencies of international concern as declared by the World Health Organisation, blockades, embargoes, vandalism, sabotage, strikes, lockouts, unusual severe weather conditions not included in normal planning,
damage to the Yacht from any of the events mentioned herein and time taken to repair such damage, shortage of materials and equipment or inability to obtain delivery thereof (provided it is documented that such materials were ordered on
time) defects in materials and equipment which could have not been detected by the Builder using reasonable care, casting, forging or machinery rejects or the like which could have not been detected by the Builder using reasonable care.
|
| 9.5 |
Consequences of Force Majeure Events
|
| 9.5.1 |
Subject to Clause 9.5.2 below, the Builder will not be liable for any delay in construction, completion or delivery of the Yacht or any failure to perform or delay in performing any of its
obligations as a result of any Force Majeure Event and any delay caused by such Force Majeure Event will be a Permissible Delay and the Scheduled Delivery Date will be extended accordingly.
|
| 9.5.2 |
As soon as reasonably practicable after the commencement of any Force Majeure Event the Builder will notify the Buyer giving reasonable details of its nature, the Builder’s estimate of the effects and likely duration thereof and the
Builder’s intended measures to minimize the consequences. Failure by the Builder to give notice in accordance with this 9.5.2 shall preclude the Builder from claiming an extension of the Scheduled
Delivery Date on account of the relevant events and circumstances.
|
| 9.5.3 |
The Builder shall take all reasonable steps to avoid or minimise any adverse consequences of Force Majeure, including if appropriate the re-organisation of work schedules so as to enable construction to continue on parts unaffected by
the relevant events and circumstances.
|
| 9.5.4 |
Failure by the Buyer to respond to a Builder’s Force Majeure notice within seven (7) Banking Days from receipt will be deemed as acceptance of the consequences set out in the Builder’s notice.
|
| 9.6 |
Termination for Excessive Force Majeure
|
| 9.6.1 |
If the total amount of Permissible Delay occasioned by Force Majeure Events exceeds two hundred and seventy (270) Days, then the Buyer will have the option to terminate this Contract and the provisions of Clause 14.1 will apply save that the Builder will not be liable to pay any liquidated damages in accordance with Clause 10.
|
| 9.7 |
Permissible Delay Generally
|
| 9.7.1 |
The Builder may claim a Permissible Delay under this Contract whether the relevant events or circumstances occur before or after the Scheduled Delivery Date.
|
| 10 |
Liquidated Damages
|
| 10.1 |
Delay
|
| 10.1.1 |
Should the Yacht not be delivered on or before the Scheduled Delivery Date (as the same may be extended from time to time under the terms of this Contract) and the delay exceeds 30 (Thirty) Days (the Grace
Period), the Builder shall pay to the Buyer starting from first day after the end of the Grace Period, as liquidated damages and not as penalty and as full and final settlement of all the Buyer’s rights, claims and causes of action
relating to delay in delivery of the Yacht the following:
|
| (a) |
from the 31stst Day to the 180thth Day of delay €27,000 (twenty-seven
thousand Euros) for each day of delay;
|
| 10.1.2 |
If the total delay exceeds 240 (two hundred and forty) Days after the Scheduled Delivery Date (as it may be extended in accordance with the provisions of this Contract and including any Permissible delays accrued) plus the grace period
of 30 (Thirty) Days then, as an alternative to claiming any liquidated damages, the Buyer will have the option to terminate this Contract and the provisions of Clause 14 will apply.
|
| 10.1.3 |
For the avoidance of doubt, save as provided by Clause 10.1.4 liquidated damages payable to the Buyer pursuant to Clause 10.1.1 shall never exceed € 4,023,000 (four million twenty three thousand Euros).
|
| 10.1.4 |
At any time after the Buyer’s right to terminate this Contract arises under Clause 9.6 or this Clause 10 the Builder may give a notice in writing to the Buyer specifying a new Scheduled Delivery Date
and requiring the Buyer to elect either to terminate this Contract or to agree such new Scheduled Delivery Date. If within ten (10) Days after receipt of such notice the Buyer does not give notice terminating this Contract then the new
Scheduled Delivery Date specified by the Builder will become the Scheduled Delivery Date for the purposes of this Contract.
|
| 11 |
Performance Warranties
|
| 11.1 |
Warranted Maximum Speed
|
| 11.1.1 |
The warranted maximum speed of the Yacht in trial condition in accordance with the procedures outlined in Section 1.1 of the Specifications is 16 knots. If the maximum warranted speed of the Yacht in trial conditions in accordance with
the Specifications and during the Sea Trials carried out under Clause 8 above is less than 16 knots, the Builder will pay to the Buyer as liquidated damages and in full and final settlement of all claims whatsoever of the Buyer in respect
of such deficiency the following amounts:
|
| (a) |
for the first half knot of speed deficiency, nothing; and
|
| (b) |
for each successive half knot thereafter (fractions being disregarded), €200.000 (two hundred thousand Euros).
|
| 11.1.2 |
Provided that if the deficiency in the Yacht’s speed is more than 2 knots, as an alternative to receiving the above mentioned liquidated damages, the Buyer may accept the Yacht on such terms as might be mutually agreed between the
Builder and the Buyer or, provided the Builder fails to remedy the speed performance, shall have the option to terminate this Contract with the consequences provided for in Clause 14.
|
| 11.1.3 |
For the avoidance of doubt, liquidated damages payable to the Buyer pursuant to this Clause 11.1 shall never exceed €600.000 (six hundred thousand Euros).
|
| 11.2 |
Warranted Range
|
| 11.2.1 |
If the Yacht’s range, as per the technical specification in Section 1.1 is less than 4.000 nautical miles then the Builder shall pay to the Buyer as liquidated damages for the following amounts:
|
| (a) |
for the first 100 nautical miles of range deficiency below 4.000 nautical miles, nothing;
|
| (b) |
for each successive 100 nautical miles thereafter (distances less than 50 nautical miles being disregarded) €200.000 (two hundred thousand Euros),
|
| 11.2.3 |
If the deficiency in the Yacht’s range is more than 500 nautical miles then the Buyer shall have the option to accept the Yacht on such terms as might be mutually agreed between the Builder and Buyer or as an alternative to receiving the
above mentioned liquidated damages and provided the Builder fails to remedy the range level, the Buyer shall have the option to terminate this Contract with the consequences provided for in Clause 14.2.
|
| 11.3 |
Noise levels
|
| 11.3.1 |
If the actual noise level measured in any owner or guest rooms/areas or in any room for which specific noise levels are defined in the Specification exceed the maximum noise levels defined in the Specifications in each of harbour mode or
at cruising speed by more than 1.5 dB(A), the Builder shall pay to the Buyer as liquidated damages for each successive 0.5 dB(A) beyond 1.5 dB(A) or thereafter €20.000 (twenty thousand Euros) for each room/area identified in the
Specifications.
|
| 11.3.2 |
Provided that if the actual noise level in any such room/area exceeds the level for which liquidated damages become due as mentioned above in each of harbour mode or at cruising speed by more than 4 dB(A) then the Buyer shall have the
option to accept the Yacht on such terms as might be mutually agreed between the Builder and Buyer or, as an alternative to receiving the above mentioned liquidated damages and provided the Builder fails to remedy the noise levels, shall
have the option to terminate this Contract with the consequences provided for in Clause 14.2.
|
| 11.3.3 |
For the avoidance of doubt, liquidated damages payable to the Buyer pursuant to this Clause 11.3 shall never exceed €350.000 (three hundred and fifty thousand Euros).
|
| 11.4 |
Vibration
|
| 11.4.1 |
If the actual vibration level measured in any owner or guest rooms/areas or in the upper salon and the main salon/dining room of the Yacht identified as such in the Specifications and for which vibration levels are defined in the
Specifications and measured in accordance with the conditions as defined in the Specifications exceeds the vibration level set out in the Specifications for that room/area the Builder shall pay to the Buyer as liquidated damages the
following amounts:
|
| (a) |
for the first 1 mm/s of excessive vibration level above the vibration levels set out in the Specifications, nothing;
|
| (b) |
for each successive 0,2 mm/s, thereafter €5.500 (five thousand five hundred Euros) for each room/area identified in the Specification as a room/area for which vibration levels are defined in the Specifications.
|
| 11.4.2 |
Provided that if the actual vibration level in any such room/area exceeds the level for which liquidated damages become due as mentioned above by more than 2 mm/sec the Buyer and provided the Builder fails to remedy the vibration level,
as an alternative to receiving the above mentioned liquidated damages, shall have the option to terminate this Contract with the consequences provided for in Clause 14.2 or to accept the Yacht on such terms as might be mutually agreed
between the Buyer and the Builder.
|
| 11.4.3 |
For the avoidance of doubt, liquidated damages payable to the Buyer pursuant to this Clause 11.4 shall never exceed €160.000 (one hundred and sixty thousand Euros).
|
| 11.5 |
Limitation of Liability – Exclusive Remedy
|
| 11.5.1 |
The liquidated damages expressly provided for in this Contract shall be in full and final settlement of the Buyer’s specified claims arising hereunder and Buyer shall not be entitled to claim any additional damages, indemnification or
other compensation of any nature whatsoever in respect of such specified claims (save in the event that the Buyer exercises a right of termination in which case the provisions of Clause 14.2 shall apply).
|
| 11.5.2 |
Notwithstanding anything elsewhere herein contained, the Builder’s maximum aggregate liability for liquidated damages under Clauses 10 and Clause 11 of this Contract shall never exceed an amount equal to five per cent (5%) of the
Contract Price. For the avoidance of doubt, liquidated damages payable under Clause 10 and this Clause 11 are cumulative and not mutually exclusive subject always to the maximum cap under this Clause 11.5.2.
|
| 11.5.3 |
The Builder undertakes to rectify all defect(s) relating to the Yacht’s paintwork in accordance with the Specifications and to achieve the quality parameters set out therein and in accordance with the Builder’s obligations under Clause
16 (to the extent that such defects fall within the meaning of warranty works under Clause 16).
|
| 11.6 |
Exclusion of Liability
|
| 11.6.1 |
Any liability of the Builder under or in connection with this Contract shall be limited to the rights and remedies provided for the Buyer in this Contract and there shall be no further liability of the Builder whatsoever for any damages,
losses or expenses (whether special, direct, indirect or consequential), including (without limitation) loss of income, earnings, profit, enjoyment or use.
|
| 11.7 |
General
|
| 11.7.1 |
The Builder shall be entitled before Delivery to take such remedial actions as the Builder considers appropriate (without thereby adversely affecting any other characteristic of the Yacht) to correct any deficiency in the Yacht’s
performance, provided that no such remedial action shall constitute grounds for an extension to the Scheduled Delivery Date.
|
| 11.7.2 |
The Buyer further acknowledges that the payment of liquidated damages under this Clause 11 is a last resort and the Builder will use all reasonable endeavours to try to remedy the relevant deficiency before tendering the Yacht for
Delivery.
|
| 11.7.3 |
The Buyer shall not delay and/or set off any payment due to the Builder under this Contract in case of any dispute relating to the amount of liquidated damages.
|
| 12 |
Risk and Insurance
|
| 12.1 |
Risk
|
| 12.1.1 |
From the date of this Contract until Delivery, the Yacht and such parts as have been constructed and all Materials will be at the Builder’s risk. All risk associated with the Yacht will pass to the Buyer on Delivery.
|
| 12.2 |
Insurance
|
| 12.2.1 |
The Yacht and such parts, materials, etc. as aforesaid shall be marked with the Yacht’s Hull Number and shall until Delivery be insured by the Builder with a reputable, first class insurance company at its own expense against all risks
(including war risks and risks associated with the conduct of trials) customarily insured against in the yacht construction industry, upon terms comparable to the Institute Clauses for Builders’ Risks 1/6/88 amended to include earthquake
risks, and for a sum not less than the Contract Price and the value (as notified from time to time by the Buyer to the Builder) of those items of Buyer’s Supplies delivered to the Shipyard up to an aggregate total limit of €1.000.000 (one
million euros) but excluding without limitation paintings, sculptures, art objects and the like which will be insured at the Buyer’s care and cost at their full cost. Such insurance shall be effected and maintained in the name of the
Builder and the Buyer as co-assureds for their respective interests but without any liability on the part of the Buyer for premiums, provided that the insurance for the items of Buyer’s Supplies that have been delivered to the Shipyard
shall be effected and maintained solely in the name of the Builder and the Buyer as the only co-assureds. Copies of all policies, certificates of insurance and/or cover notes in relation to the Yacht’s insurances pursuant to this Clause
12, shall be supplied by the Builder to the Buyer (redacted if necessary) to provide evidence that the Yacht and the Buyer’s Supplies are insured under the Builder’s policy in accordance with this Clause but it being agreed that the Buyer
will not have any right to contact or speak directly with the Builder’s underwriters. For the avoidance of doubt the Buyer will not have any direct recourse nor any direct access to the Builder’s insurances and any sums which might be due
to the Buyer in respect of Buyer’s Supplies insured under the Builder’s policy will be paid by the Builder to the Buyer after receipt by the Builder of the relevant insurance proceeds.
|
| 12.2.2 |
For the avoidance of doubt the Buyer will be obliged to pay any additional premium costs for any increase in the limit of cover of Buyer’s Supplies required by the Buyer.
|
| 12.3 |
Partial Loss
|
| 12.3.1 |
If before Delivery, the Yacht and/or such parts, materials, etc. as aforesaid before sustain damages for any cause whatsoever not constituting an actual, constructive, arranged or compromised total loss then:
|
| (a) |
any moneys payable under the insurances in respect of such damage shall be applied by the Builder with all due despatch and without any additional cost to the Buyer in making good such damage and thus restore the Yacht to the condition
required under the terms of this Contract and of the Specifications; and
|
| (b) |
unless caused by the gross negligence or default of the Builder or its sub-contractors, any delay in completion of the Yacht occasioned by repair and rectification of the damage will constitute a Permissible Delay and the Scheduled
Delivery Date will be extended accordingly.
|
| 12.3.2 |
Notwithstanding the above terms of Clause 12.3.1, the Buyer may be entitled to reject the Yacht in accordance with Clause 8.4.2 above where an item of major machinery or equipment breaks down or suffers any major damage and/or any kind
of damage to the hull structures due to grounding and/ or heavy contact occurs prior to delivery and which require complete replacement and the Builder has failed to replace with new machinery or equipment.
|
| 12.4 |
Total Loss
|
| 12.4.1 |
If before Delivery the Yacht from any cause whatsoever becomes an actual, constructive, arranged or compromised total loss then subject only to the provisions of this Clause 12.4 this Contract will
be deemed to have terminated on the date such total loss occurs and the Builder shall refund the Buyer any sums received by the Builder from the Buyer up to the date such total loss occurred on account of the Contract Price within forty
five (45) Banking Days from receipt of the Buyer’s demand. If the Builder has not refunded the Buyer within such forty five (45) Banking Day period, the Buyer will be entitled to make a claim under the Refund Guarantees.
|
| 12.4.2 |
Following the payment by the Builder to the Buyer under Clause 12.4.1 above, the Builder shall have no further liability towards the Buyer in relation to the total loss.
|
| 12.4.3 |
Under no circumstances will the Builder be obliged to rebuild or reinstate the Yacht following an actual, constructive, arranged or compromised total loss.
|
| 13 |
Default by the Buyer
|
| 13.1 |
Builder’s Right to Terminate
|
| 13.1.1 |
In addition to such rights as it may have at general law the Builder may suspend construction of the Yacht and/or terminate this Contract at any time by notice to the Buyer:
|
| (a) |
if the Buyer fails to pay any sum due and owing under this Contract within forty-five (45) Days after the Due Date;
|
| (b) |
if the Buyer fails to accept delivery of the Yacht within ten (10) Days after she is properly tendered for Delivery;
|
| (c) |
if in breach of Clause 17 the Buyer purports to assign or transfer any of its rights or benefits under this Contract or there is any change in the beneficial ownership and control of the Buyer (other
than due to the death of the beneficial owner);
|
| (d) |
if the Buyer commits a repudiatory breach going to the root of this Contract or is a party to dishonest or fraudulent conduct in relation to this Contract;
|
| (e) |
if a bona fide petition is presented, order made or resolution passed in any part of the world for the winding up, liquidation or dissolution of the Buyer or if a receiver, receiver and manager, administrator or comparable official is
appointed of the whole or a material part of the Buyer’s undertaking, property or assets;
|
| (f) |
if the Buyer suspends payment of its debts or states or intimates any intention of so doing; or
|
| (g) |
if the Builder is entitled to terminate this Contract pursuant to any other terms thereof.
|
| 13.2 |
Effects of Builder’s Termination
|
| 13.2.1 |
Upon lawful termination of this Contract by the Builder the Builder will be entitled either (i) to sell the incomplete Yacht and her machinery, equipment and components, or (ii) to complete the Yacht to the same or a different
specification and sell her after completion, and any such sale may be by public auction (in which case the Builder or its agents may bid for or acquire the Yacht) or by private contract at such time, at such price and upon such terms and
conditions as the Builder in its discretion (but always acting reasonably and in good faith) may determine, provided that the Builder shall use all reasonable endeavours to attain the best possible price for the Yacht.
|
| 13.2.2 |
If the Yacht is sold by the Builder in an incomplete state pursuant to Clause 13.2.1 above, the Builder will retain the instalments of the Contract Price already paid by the Buyer. In addition the Builder will apply the proceeds of sale
in payment of:
|
| (a) |
First, the expenses of the sale (including, for the avoidance of doubt, in relation to any prospective sale which does not complete) and all other costs and expenses incurred by reason of the Buyer’s default including, but without
limitation, the Builder’s liability to the sub-contractors and suppliers (unless included in one of the categories below), legal fees (on a full indemnity basis), marketing and advertising expenses, commissions and brokerage fees pursuant
to a written agreement, and the management, administrative and marketing time incurred in each case by the Builder, all such costs being in relation to the Yacht;
|
| (b) |
Second, the total amount of the instalments of the Contract Price due at the time of termination but not paid by the Buyer;
|
| (c) |
Third, any costs incurred by the Builder in modifying the Yacht to comply with the requirements of the purchaser;
|
| (d) |
Fourth, interest on any instalments of the Contract Price due, but unpaid, at the time of termination, calculated in accordance with Clause 3.5.4 from the Due Date for the payment thereof until the date of receipt by the Builder
of the proceeds of sale;
|
| (e) |
Fifth, the cost of additional work and materials (if any) supplied by the Builder in the construction of the Yacht that have not been included in the pre-delivery instalments of the Contract Price payable under Clause 13.2.2(b) at
the time of termination;
|
| (f) |
Sixth, an amount equal to five per cent (5%) of the Contract Price representing the Builder’s reasonably estimated loss of profit in respect of this Contract;
|
| 13.2.3 |
If the Yacht is sold by the Builder in a completed state pursuant to Clause 13.2.1 above the Builder will retain the instalment(s) of the Contract Price already paid by the Buyer. In addition, the Builder will apply the proceeds of sale
in payment of:
|
| (a) |
First, the expenses of the sale (including, for the avoidance of doubt, in relation to any prospective sale which does not complete) and all other costs and expenses incurred by reason of the Buyer’s default including, but
without limitation, the Builder’s liability to the sub-contractors and suppliers (unless included in one of the categories below), legal fees (on a full indemnity basis), marketing and advertising expenses, commissions and brokerage fees
pursuant to a written agreement, and the management, administrative and marketing time incurred in each case by the Builder, all such costs being in relation to the Yacht;
|
| (b) |
Second, any costs incurred by the Builder in modifying the Yacht to comply with the requirements of the purchaser;
|
| (c) |
Third, the total amount of the instalments of the Contract Price due at the time of termination but not paid by the Buyer;
|
| (d) |
Fourth, interest on any unpaid instalments of the Contract Price calculated in accordance with Clause 3.5.4 from the Due Date for the payment thereof until the date of receipt by the Builder of the proceeds of sale;
|
| (e) |
Fifth, all other instalments of the Contract Price not paid or due at the time of termination (i.e. not retained by the Builder or paid under Clause 13.2.3(c)),
|
| 13.2.4 |
Upon lawful termination by the Builder under this Clause 13, the Buyer will promptly return to the Builder any original Refund Guarantees delivered by the Builder to the Buyer in accordance with this Contract.
|
| 13.2.5 |
Notwithstanding the foregoing if the benefit of this Contract is held by way of security by a bank or financial institution as contemplated by Clause 17.1.1(a) then before exercising any right to terminate this Contract in accordance
with this Clause 13 the Builder will give the bank or financial institution in question ten (10) Days’ notice of intention to terminate and the opportunity within such period of ten (10) Days to rectify
all subsisting breaches by the Buyer of its obligations under this Contract and to take over and undertake unconditionally to perform all the Buyer’s remaining obligations under this Contract.
|
| 13.2.6 |
This Clause 13 sets forth the entire obligation of the Buyer in the event of termination of this Contract by the Builder. .
|
| 14 |
Default by the Builder
|
| 14.1 |
Buyer’s Right to Terminate
|
| 14.1.1 |
In addition to such rights as it may have at general law the Buyer may terminate this Contract at any time by notice to the Builder:
|
| (a) |
if the Builder commits a material breach of this Contract or is a party to dishonest or fraudulent conduct or act in gross negligence or wilful misconduct or deliberate default in relation to this Contract;
|
| (b) |
if a bona fide petition is presented, order made or resolution passed in any part of the world for the winding up, liquidation or dissolution of the Builder or if a receiver, receiver and manager, administrator or comparable official is
appointed of the whole or a material part of the Builder’s undertaking, property or assets;
|
| (c) |
If the total cumulative time of all Force Majeure delays exceeds two hundred and seventy (270) Days, unless the Buyer elects to agree to a new delivery date on such terms and conditions as the Buyer may agree;
|
| (d) |
if the Scheduled Delivery Date is delayed by more than two hundred and forty (240) Days plus the grace period of 30 (Thirty) Days and unless the Buyer elects to agree to a new Scheduled Delivery Date in accordance with Clause 10.1.4
above;
|
| (e) |
if the Builder becomes subject to fallimento, concordato preventivo, liquidazione coatta amministrativa or amministrazione straordinaria or is subject
to or applies for any other similar insolvency and/or winding up (as amended and supplemented from time to time);
|
| (f) |
if the Builder suspends payment of its debts or ceases to carry on its present business or states or intimates any intention of so doing;
|
| (g) |
if the Builder suspends Works on the Yacht for a period of thirty (30) consecutive Days, other than as permitted in accordance with this Contract;
|
| (h) |
if the Yacht becomes an actual, constructive or agreed total loss;
|
| (i) |
if the Buyer is entitled to terminate this Contract pursuant to any other terms thereof.
|
| 14.2 |
Effects of Buyer’s Termination
|
| 14.2.1 |
Upon lawful termination of this Contract by the Buyer the Buyer will be entitled by notice in writing given at any time thereafter to require the Builder:
|
| (a) |
to refund all amounts paid by the Buyer on account of the Contract Price together with interest on each such amount from the date of payment until the date of refund calculated on a daily basis at (3) three-Month Euribor and such refund
shall be paid by the Builder within forty five (45) Banking Days from receipt by the Builder of the Buyer’s notice (save where such termination is disputed, in which case such amounts shall be paid in accordance with the arbitration award
issued under Clause 20.1.4);
|
| (b) |
to return all the Buyer’s Supplies which can be removed from the Yacht without causing any damage to the Yacht; and
|
| (c) |
if and to the extent that the Buyer’s Supplies cannot be returned to the Buyer in the same condition in which they were delivered to the Builder, to pay to the Buyer the acquisition cost thereof (as evidenced by the relevant purchase
invoices) plus interest calculated at (3) three-Month Euribor from the respective date of payment thereof by the Buyer;
|
| 14.2.2 |
If the Buyer has not received a refund as required by Clause 14.2.1 within forty five (45) Banking Days from such demand (save where such termination is disputed, in which case such amounts shall be paid in accordance with the
arbitration award issued under Clause 20.1.4) then the Buyer shall be entitled to make a claim under the Refund Guarantees.
|
| 14.2.3 |
Following termination of this Contract the Builder will have no obligation or liability whatsoever except as expressly provided by this Clause 14 and in particular (without limitation) the Builder will be not liable for any loss or
damage consequential or otherwise of whatsoever nature in any way deriving from or connected with its default.
|
| 15 |
Limitations
|
| 15.1 |
Maximum Liability
|
| 15.1.1 |
Save as expressly appears in this Contract or where the liability is in respect of personal injury or death caused by the Builder’s wilful misconduct or negligence the Builder’s maximum aggregate liability under or pursuant to this
Contract or any termination will be an amount equal to the amount paid by the Buyer on account of the Contract Price and interest thereon calculated at (3) three-Month Euribor from time to time.
|
| 15.2 |
Consequential Loss
|
| 15.2.1 |
Save as expressly appears in this Contract , the Builder will have no liability for claims of whatsoever nature and howsoever arising (in contract, tort or otherwise) for any loss of use, profits, time or charter income, for any
consequential, indirect or contingent loss or damage, or for any losses, damage, costs or expenses that are consequential upon or indirectly or contingently caused by the breakdown, malfunctioning, fault or failure of any kind whatsoever of
the Yacht.
|
| 15.3 |
Dealers and Brokers
|
| 15.3.1 |
The Buyer acknowledges that save as expressly appears in this Contract the dealer or broker (if any) with whom the Buyer has dealt in relation to this Contract has at no time had any power or authority to bind the Builder or to make any
representation or incur any liability or obligation for or on behalf of the Builder.
|
| 16 |
Warranty
|
| 16.1 |
Extent of Warranty
|
| 16.1.1 |
The express provisions of this Contract constitute the Builder’s exclusive warranty as to the description, quality, merchantability and fitness for purpose of the Yacht and the express provisions of this Clause 16 constitute the full extent of the Builder’s obligations after delivery of the Yacht notwithstanding any act, matter or thing done or omitted to be done by the Builder (whether negligently or otherwise) in or about her
construction.
|
| 16.1.2 |
The Buyer or the Buyer’s Representative shall notify the Builder as soon as possible and in any event within ten (10) Days after the discovery of any defect for which a claim is made under this Clause 16
and the Buyer’s written notice shall describe the defect in reasonable detail. If the Buyer fails to notify the Builder within such ten (10) Day period, the Builder shall have no liability in respect of any further deterioration or
additional damage caused by the delay in notification.
|
| 16.1.3 |
The Builder shall have no liability under this Clause 16 for any defects discovered by the Buyer prior to the expiry of the Warranty Period, unless notice of such defects is given by the Buyer not
later than ten (10) Days after such expiry date. The Builder shall have no liability under this Clause 16 for any defects discovered after the expiry of the Warranty Period.
|
| 16.1.4 |
Prior to the delivery of the Yacht to the Yard, or to any shipyard indicated and/or approved by the Builder, for any warranty work, the Buyer warrants that all of the Yacht’s customary insurances remain in place. The Buyer shall provide
the Builder with copies of such insurances and shall ensure that all customary insurance remain valid and in place during the period of the warranty works.
|
| 16.2 |
Undertaking to Rectify Defects
|
| 16.2.1 |
The Builder undertakes to rectify as soon as practicably possible taking into consideration the nature of the defects and subject the Yacht’s being made available to the Builder:
|
| (a) |
all Minor Non-Conformities agreed between the parties or notified by the Buyer before delivery in accordance with Clause 8.5; and
|
| (b) |
any defect in the Yacht due to faulty design, faulty materials/spares /tools (which the Builder shall be obligated to supply) or equipment and/or bad workmanship, on condition that such defect becomes apparent and is notified to the
Builder as described at Clause 16.1.
|
| 16.2.2 |
During the foregoing Warranty Period the Builder will have the option from time to time to place on board one (1) Builder’s representative who will act as its observer and to whom all reasonable
assistance will be granted for the fulfilment of his/her tasks.
|
| 16.3 |
Exclusions from Warranty
|
| 16.3.1 |
The Builder’s obligations under Clause 16.2 will not extend to defects arising from:
|
| (a) |
normal wear and tear or average damage;
|
| (b) |
work done and/or alterations made by persons other than the Builder or its servants or agents, save for emergency work and/or work carried out by third party’s approved by the Builder;
|
| (c) |
any unusual use or operation of the Yacht not reasonably within her design or operational limitations;
|
| (d) |
wilful misconduct, mismanagement or gross negligence in the use of the Yacht; and
|
| (e) |
lack of proper maintenance of the Yacht or any failure to implement and follow in all material respects any care and/or maintenance instructions given by the Builder in writing.
|
| 16.4 |
Performance of Rectification Work
|
| 16.4.1 |
All rectification work will be carried out by the Builder with reasonable despatch during normal working hours at its Yard or at a shipyard indicated by the Builder.
|
| 16.4.2 |
If the Yacht cannot be brought to the Yard due to the nature of the defects, or if the Buyer reasonably and acting in good faith considers it to be impractical or inconvenient to bring the Yacht back to the Yard, then the Builder will
promptly either:
|
| (a) |
send its own nominated engineers at Builders expense to carry out the work at the place where the Yacht is located; or
|
| (b) |
arrange for the work to be carried out at the nearest convenient and suitable shipyard or facility indicated by the Builder.
|
| 16.4.3 |
Delivery of the Yacht to the Yard or to any other shipyard shall be at the Buyer’s cost and responsibility unless the defects (falling within the Builder’s responsibility under this Clause 16) affect the seaworthiness and safe navigation
of the Yacht and would impair the Yacht’s insurance cover, in which case, delivery of the Yacht to the Yard or to any other shipyard approved in writing by the Builder shall be at the Builder’s cost and responsibility.
|
| 16.4.4 |
The Builder will have no liability whatsoever for repair and replacement work carried out elsewhere than in the Yard without its prior agreement. The Builder will not be responsible to pay any cost for repair and replacement work carried
out without the prior written approval by the Builder of such estimates and costs.
|
| 16.4.5 |
During the execution of the warranty works at the Builder’s shipyard, the Yacht shall be fully insured by the Buyer at its own expense against all risks customarily insured by a marine Hull & Machinery Policy and will procure a
waiver of subrogation rights from the yacht’s insurers in respect of any recourse action they may otherwise have against the Builder with respect to any loss or claim in so far as such loss or claims, or the aggregate of any such losses or
claims exceeds € 1.000.000 (one million Euros). The Buyer must provide evidence of such coverage to the Builder in the form of a copy of the relevant valid insurance certificates. The Builder shall maintain, at no cost to the Buyer, its
usual general liability insurance, which insurance will be primary and non-contributory to any insurance carried by the Buyer. The Builder shall, at the Buyer’s request, make immediately available to the Buyer copies of the insurance
policies, such policy shall include third party physical damage.
|
| 16.5 |
Payment and/or Reimbursement of Costs and Expenses
|
| 16.5.1 |
In all cases the Buyer must pay and/or reimburse:
|
| (a) |
all costs connected with moving or towing the Yacht to the place selected for any repair and replacement work save where the Yacht cannot be brought back to the Yard or to the place selected for any repair and replacement due to defects
affecting the seaworthiness and safe navigation of the Yacht and impairing the Yacht’s insurance cover, in which case the cost for moving or towing the Yacht to the shipyard indicated by the Builder will be for the Builder’s account.
|
| (b) |
all ordinary operating costs that are not directly related to warranty works including, without limitation, electricity and water supply, sewage and other similar expenses; and
|
| (c) |
all costs and expenses incurred by the Builder in and about investigating, repairing or replacing at the Buyer’s request or insistence any alleged defect which proves not to have been the Builder’s responsibility under the terms of this
Clause 16 including (without limitation) all travel and living expenses incurred in that behalf.
|
| 16.6 |
Subsisting Warranties
|
| 16.6.1 |
If at the end of the Warranty Period for which the Builder is liable as aforesaid there are subsisting warranties in respect of the Yacht or her machinery or equipment from any of the Builder’s sub-contractors or suppliers which are
capable of legal assignment, then the Builder will arrange assignment of the same to the Buyer or if no assignment is permitted, directly enforce the same for the benefit of the Buyer. All expenses of any such assignment will be for the
Buyer’s account and the Builder accepts no responsibility for the performance by its sub-contractors or suppliers of their obligations under any such warranty after the expiry of the Builder’s Warranty Period.
|
| 17 |
Assignment
|
| 17.1 |
Permitted Assignments
|
| 17.1.1 |
The Buyer may assign all its rights and benefits of this Contract:
|
| (a) |
by way of security to a bank or financial institution providing finance in connection with this Contract; or
|
| (b) |
to a corporation wholly owned and controlled by the beneficial owner; or
|
| (c) |
(after delivery and acceptance and payment and satisfaction in full of the Contract Price) to a bona fide Buyer of the Yacht subject always to such assignee complying with the Builder’s KYC requirements and verification and the Builder
having received the relevant supporting documentation and having cleared its risk compliance process..
|
| 17.1.2 |
It will be a condition of any assignment of this Contract by the Buyer that the Builder’s rights are not thereby diminished nor its obligations increased and the Buyer must indemnify the Builder against all legal fees and other expenses
incurred in connection with the assignment.
|
| 17.2 |
Prohibited Assignments and Maintenance of Beneficial Ownership
|
| 17.2.1 |
Save as expressly provided by this Clause 17 neither party may assign any of its rights under this Contract without the prior written consent of the other such consent not to be unreasonably
withheld.
|
| 17.2.2 |
The Buyer acknowledges that this Contract has been negotiated and concluded on the understanding that its beneficial owner will remain the same, as disclosed to the Builder, until delivery and acceptance of the Yacht and that there must
not be any change in the beneficial ownership of the Buyer without the Builder’s prior written consent.
|
| 18 |
Intellectual Property
|
| 18.1.1 |
Save as set out at Clause 4, the Builder retains ownership of all rights pertaining to the General Arrangement Plan, the Specifications and any and all drawings, technical descriptions, calculations, test results and other data
calculation, renderings information and documents concerning the design and construction of the Yacht.
|
| 18.1.2 |
The Builder warrants that no patents, copyright or other design rights or intellectual property or industrial rights of third parties will be infringed by the design, construction or outfit of the Yacht, by the General Arrangement Plan,
the Specifications, the Design Drawings, plans, instructions or other documents, or by any article supplied by or on behalf of the Builder in connection with the Yacht and/or this Contract. Nonetheless, should a third party raise claims
for infringement of any patent, copyright or other design rights or intellectual property or industrial rights, the Builder shall indemnify the Buyer, and hereby indemnifies the Buyer, against any action, claim, demand, liability, costs,
expenses and losses (including legal fees and expenses) incurred by the Buyer as a result of such claim; and the Parties shall, at the Builder’s expense, give each other all such assistance in the defence of such claims as the other Party
may reasonably request in connection therewith.
|
| 18.1.3 |
The Buyer undertakes not to publish or disclose any of the foregoing to third parties or to seek to exploit them without the Builder’s written consent, (such consent not to be unreasonably withheld, where necessary to enable the Buyer to
operate and maintain the Yacht and effect repairs or pursuant to Clause 14.2).
|
| 18.1.4 |
Ownership of all rights to any and all working drawings, technical descriptions, calculations, test results and other data, information and documents concerning the design and construction of the Yacht which have been or will be produced
by any third party designers appointed by the Buyer shall remain with the Buyer or such third party designers (as applicable). The Builder undertakes not to publish or disclose any of the foregoing to third parties or to seek to exploit
them without the Buyer’s written consent provided that the Builder shall have a licence to use the same for the purpose of constructing and completing the Yacht and effecting any repairs pursuant to Clause 14.2.
|
| 19 |
Patent Infringement
|
| 19.1 |
Builder’s Indemnity
|
| 19.1.1 |
The Builder will indemnify the Buyer against all loss, liabilities, costs and expenses (including costs and expenses of litigation if any) incurred or suffered by reason of any infringement of any intellectual property rights in
connection with the Yacht and her construction but the Builder will have no liability in respect of the Buyer’s Supplies or any elements of the Yacht’s design provided by or on behalf of the Buyer.
|
| 20 |
Law and Jurisdiction
|
| 20.1.1 |
This Contract is subject to English Law.
|
| 20.1.2 |
In the event of a dispute, difference or claim regarding matters governed by the rules of the Classification Society or Flag State, the matter shall be referred to that agency or regulatory body, whose decision shall be final and binding
on the parties hereto.
|
| 20.1.3 |
Subject to Clause 20.1.2, all disputes relating to purely technical aspects of the construction of the Yacht, including but without limiting the generality of the foregoing, purely technical disputes
as to whether the Yacht suffers from any defect and/or complies with this Contract and the Specifications when tendered for Delivery by the Builder and purely technical disputes relating to the Consequential Effects of compulsory
modifications within the meaning of Clause 7.3) (but with the exclusion of price quotes and estimates of the Builder) and any other purely technical disputes, which cannot be resolved by negotiation and
agreement between the Builder and the Buyer, will at the written request of either Party be submitted to and finally determined by an independent marine expert who has specific experience in connection with the matter to be determined and
being a senior marine surveyor for the time being of the firm Winterbotham Ltd. (the Technical Expert). The Technical Expert shall act as a technical expert and not as an arbitrator provided that if
he is unwilling or unable to act or failing agreement by the Parties on the identity of an alternative independent technical expert having specific experience in connection with the matter for which there is a technical dispute within 10
(ten) Days after the parties’ receipt of notice that such expert is unwilling or unable to act then the appointment of the Technical Expert will be made by the President for the time being of the London Maritime Arbitrators’ Association.
All costs and expenses incurred by the Technical Expert shall be for the account of the Party found to be wrong. The Builder shall be entitled to Permissible Delays flowing from the intervention in the build of the Yacht by the technical
dispute referred to the Technical Expert.
|
| 20.1.4 |
Subject to Clauses 20.1.2 and 20.1.3 above, all disputes arising under this Contract which cannot be resolved by negotiation and agreement between the Parties
will be submitted to and settled by binding arbitration in London in accordance with the Arbitration Act 1996 (or any re-enactment or modification for the time being in force) and the rules then in force of the LMAA as follows:
|
| (a) |
the Parties must use their best endeavours and co-operate and dedicate such resources as may be necessary to ensure that a final award can be published as quickly and as cost-effectively as possible;
|
| (b) |
the claimant must serve the other Party with written notice of arbitration specifying the matters in dispute and proposing 3 (three) persons acceptable to it as sole arbitrator and the Parties must then co-operate in good faith to try to
agree a sole arbitrator (being one of the 3 (three) persons proposed by the claimant or some other suitably qualified person);
|
| (c) |
if no sole arbitrator is agreed within fifteen (15) Days after service of the notice of arbitration the claimant may serve a second notice requiring the matter to be referred to a tribunal of 3 (three) arbitrators (one to be appointed by
each Party and the third by the 2 (two) so chosen) and giving notice of the appointment of its arbitrator.
|
| (d) |
if the other Party fails to appoint its arbitrator within five (5) Days following service of the second notice it will be deemed to have accepted and appointed as its own arbitrator the arbitrator appointed by the claimant and the
arbitration will proceed before that arbitrator as sole arbitrator;
|
| (e) |
the arbitrator(s) so appointed will determine the proper proportions in which each Party will pay the expenses and legal and other costs of the arbitration;
|
| (f) |
the decision of the arbitrator(s) will be final and binding and not subject to appeal or other judicial review; and
|
| (g) |
judgment on any award by the arbitrator(s) may be entered in any court of competent jurisdiction for enforcement thereof.
|
| 21 |
Notices
|
| 21.1 |
Address for Notices
|
| 21.1.1 |
All correspondence and/or notice required to be sent under or in connection with this Contract shall be in writing and shall be (i) delivered by hand or by courier to the address(es) and marked for the attention of the individuals set
out below or (ii) sent by email to the email address(es) specified below. Communication by telephone and verbal communication which will be used for practical reasons between representatives of the Builder and the Buyer, will be confirmed
in writing as stated above if crucial for the execution of the Contract.
|
| 21.1.2 |
The addresses and email addresses for correspondence and service of notices are:
|
| (a) |
to the Builder:
|
|
Attn:
|
Massimo Perotti
|
|
|
Address:
|
Sanlorenzo S.p.A
|
|
|
Via Armezzone, 3
|
||
|
19031 Ameglia (SP)
|
||
|
Italy
|
||
|
Email:
|
|
|
|
c.c.
|
|
| (b) |
to the Buyer:
|
|
Attn:
|
Andreas Louka / Konstantinos Patis
|
|||
|
Address:
|
91 Megalou Alexandrou Street 15124, Marousi Greece
|
|||
|
Email
|
|
/ |
c.c | |
| 21.1.3 |
A Party may change its details given in Clause 21.1.2 above by giving written notice to the other Party.
|
| 21.1.4 |
Any correspondence or notice shall be deemed to have been received:
|
| (a) |
if delivered by hand or by courier, at the time the notice is left at the proper address, or, if this time falls outside business hours in the place of receipt, when business hours resume; and
|
| (b) |
if sent by email, at the time of transmission, or, if this time falls outside business hours in the place of receipt, when business hours resume,
|
| 21.1.5 |
This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.
|
| 21.2 |
Notice to Buyer’s Representative
|
| 21.2.1 |
In addition, any notice or communication given by or on behalf of the Builder to the Buyer’s Representative will be deemed to have been given to the Buyer.
|
| 21.3 |
Notice to Builder’s Project Manager
|
| 21.3.1 |
In addition, any notice or communication given by or on behalf of the Buyer to the Builder’s Project Manager will be deemed to have been given to the Builder.
|
| 22 |
General Provisions
|
| 22.1 |
Publicity and Confidentiality
|
| 22.1.1 |
The Builder may take photographs and video footage of the Yacht during construction and Sea Trials and at the time of Delivery. The Buyer (without disclosing the identity of the Yacht’s beneficial owner) will allow the publication of
pictures (excluding the UBO’s room) and a brochure of the Yacht for advertising purposes and will consider to make the Yacht available to the Builder for exhibition at the Monaco Yacht Show in the first Year edition falling after Delivery
on terms to be agreed with the Builder and provided that the Builder the Builder shall provide a thirty (30) Days’ prior written notice to the Buyer and will bear all costs in relation to such exhibition, including any costs for decorating
or setting up the Yacht save that any other ordinary cost regarding the operation of the Yacht (including without limitation crew and insurance) will be for the Buyer’s account. Save as provided in this Clause 22.1.1, the Yacht shall not
be used for any other marketing or social events, unless agreed and consented and any damages occurred not caused by the Buyer, by the Buyer’s crew and/or by anyone acting on the instructions of the Buyer shall be for the account of the
Builder.
|
| 22.1.2 |
Before delivery and acceptance of the Yacht and payment and satisfaction in full of the Contract Price neither the Buyer nor any of its servants or agents may publish any image or text concerning the Yacht or claiming or foreshadowing
ownership of the same except with the Builder’s prior written consent or for the purpose of exercising or performing its express rights or obligations under this Contract.
|
| 22.1.3 |
Subject as aforesaid neither Party will publish or disclose to any person without the prior written approval of the other party the contents or import of this Contract, the General Arrangement Plan or the Specifications or the Contract
Price and the Builder will not publish or disclose (and will take all reasonable precautions to ensure that its servants and agents do not publish or disclose) to any person the identity of the beneficial owner of the Yacht or of any member
of the beneficial owner’s family. The undertakings of this Clause 22.1.3 shall be effective during the term of this Contract and remain effective at any time post Delivery and after termination of this Contract (howsoever arising).
|
| 22.1.4 |
The foregoing restrictions will not apply to the disclosure of information by a party to its legal or other professional representatives or financiers or as required by law or as reasonably necessary in connection with the construction
of the Yacht or where such information is already in the public domain otherwise than as a result of a breach of such party’s obligations.
|
| 22.2 |
Rights of Third Parties
|
| 22.2.1 |
The Contracts (Rights of Third Parties) Act 1999 will apply to this Contract insofar as is necessary or expedient to give full force and effect to the express provisions of this Contract, but otherwise no person who is not a Party to
this Contract may enforce or otherwise have the benefit of any provision of this Contract under that Act.
|
| 22.3 |
Entire Contract
|
| 22.3.1 |
This Contract, the General Arrangement Plan and the Specifications (and amendments thereof) constitute the whole of the agreement between the Builder and the Buyer relating to the Yacht and save as appears expressly in this Contract, the
General Arrangement Plan and the Specifications the Builder makes no representation or warranty concerning the description, quality, merchantability or performance of the Yacht or her fitness for any particular purpose and it is further
agreed that the Sale of Good Act 1979 as the same might be amended or implemented will not apply to this Contract. In particular but without limitation this Contract extinguishes all prior warranties and representations (whether written or
oral) concerning its subject matter which may have been made by or on behalf of the Builder.
|
| 22.4 |
Variation
|
| 22.5 |
Counterparts
|
| 22.6 |
Know your customer (KYC)
|
| 22.7 |
Sanctions
|
| 22.8 |
Illegality
|
|
Signed by
Builder
duly authorised for and on behalf of
Sanlorenzo Spa
|
)
)
)
)
|
|
|
|
sign here:
|
/s/ Massimo Perotti |
||
|
title:
|
Chairman and CEO |
||
|
print name:
|
Massimo Perotti |
||
|
Signed by
Buyer
duly authorised for and on behalf of
Roman Explorer Inc.
|
)
)
)
)
|
|
|
|
sign here:
|
/s/ Andreas Louka |
||
|
title:
|
Attorney in fact |
||
|
print name:
|
Andreas Louka |
||
![]() CHANGE ORDER n°
|
Hull number [●]
|
|
Modification description:
|
| CHANGE ORDER DUE TO | |||||
|
|
|
|
|||
| ☐ |
|
Owner’s request
|
☐
|
|
Classification Society’s request
|
| ☐ |
|
Captain’s request |
☐
|
|
Regulatory body’s request |
| ☐ |
|
Subcontractor’s request |
☐
|
|
Indicated material not available |
| ☐ |
|
Other |
|
|
|
|
|
|
|
|||
| CHANGE ORDER AFFECTING | |||||
| ☐ | Delivery date (No) | ||||
| ☐ | Cost | ☐ | Noise and vibration (No) | ||
| ☐ | Weight (No.) |
☐ | Other | ||
| ☐ | Speed and Range (No.) | ||||
| PRICE (see annexed price breakdown) | ||
| Additional Price (€): |
Price Reduction (€): |
|
| Sanlorenzo S.p.A. | Approved for and on behalf of the Owner | |||
![]() CHANGE ORDER n° [●]
|
Hull number [●]
|
|
Description
|
Total
|
||
| “[ |
]” |
| To: | ||
|
[Beneficiary’s name]
|
||
|
[Beneficiary’s address]
|
||
| A. |
in accordance with the terms and conditions of an agreement dated [date of the contract] entered into between Sanlorenzo S.p.A. (the “Builder”) and [—] (the “Buyer”)
for the construction, sale and purchase of a 60.00 metre motor yacht model 1150Exp with Hull No. 158 (the “Motor Yacht”) and entered into between Sanlorenzo S.p.A. and [Buyer’s name] (the “Buyer”) (the “Contract”), the Builder has agreed to design, construct, launch, complete, test and deliver the Motor Yacht in consideration for the agreed price of
€ [price in figures] ([price in letters] Euros).
|
| B. |
In accordance with Clause 3.3 of the Contract, you have to pay to the Builder [instalments in figures] ([instalments in letters]) instalments prior to delivery of the said Motor Yacht, each against an irrevocable refund guarantee from a
first class bank in your favour for an equal amount to the respective instalment, as security for the Builder’s obligation to refund such instalment on proven lawful termination of the Contract by you.
|
| C. |
According to Clause 3.2.1 [instalment letter] of the Contract, you have to pay the Builder an instalment for the amount of € [amount in figures] ([amount in letters] Euros).
|
| (i) |
the Builder’s written agreement to payment of the amount claimed, or
|
| (ii) |
a certified copy of a Court decision declaring the Builder’s insolvency (“sentenza dichiarativa di fallimento”) or any other Court decision, Court order or court resolution which acknowledges and/or declares the Builder’s insolvency
and/or leads the Builder becoming subject to “concordato preventivo” or “accordo di ristrutturazione dei debiti”, or “amministrazione controllata straordinaria” or substantially equivalent procedures as confirmed by a court declaration,
order or decision, or of a resolution for winding-up or a winding up (“liquidazione”) of the Builder as confirmed by a certified copy of a Court declaration or by a certified copy of an abstract from the Register of Companies, or
|
| (iii) |
confirmation from insurers of the total loss of the Motor Yacht and unfulfillment of the Builder’s obligation to reimburse any amounts due to the Buyer according to clause [●] of the Contract, or
|
| (iv) |
an Arbitration Award issued according to Clause 20.1.4 of the Contract recognizing the lawful termination of the Contract from your side.
|
| 1. |
presentation by the Builder to our counters of a copy of a document named “Protocol of Delivery and Acceptance” of the above mentioned Motor Yacht duly signed by the Builder and the Buyer, or
|
| 2. |
[scheduled delivery date + 200 days] (the “Expiry Date”), or
|
| 3. |
restitution, within the Expiry Date or the New Expiry Date as defined below, by the Builder to our counters of the original of this Refund Guarantee
|
|
Name of Subsidiary
|
Place of Incorporation
|
|
Top Tanker Management Inc.
|
Marshall Islands
|
|
Monte Carlo Seven Shipping Company Limited
|
Marshall Islands
|
|
Monte Carlo 39 Shipping Company Limited
|
Marshall Islands
|
|
PCH Dreaming Inc.
|
Marshall Islands
|
|
South California Inc.
|
Marshall Islands
|
|
Malibu Warrior Inc.
|
Marshall Islands
|
|
Augustus Enterprises Inc.
|
Marshall Islands
|
|
Roman Empire Inc.
|
Marshall Islands
|
|
Athenian Empire Inc.
|
Marshall Islands
|
|
Eco Oceano Ca Inc.
|
Marshall Islands
|
|
Julius Caesar Inc.
|
Marshall Islands
|
|
Legio X Inc.
|
Marshall Islands
|
|
Rubico Inc.
|
Marshall Islands
|
|
Top Mega Yachts Inc.
|
Marshall Islands
|
|
Seawolf Ventures Limited
|
Marshall Islands
|
|
Roman Explorer Inc.
|
Marshall Islands
|
|
Date: April 14, 2025
|
|
|
|
/s/ Evangelos J. Pistiolis
|
|
|
|
Evangelos J. Pistiolis
|
|
|
|
President, Chief Executive Officer and Director (Principal Executive Officer)
|
||
|
Date: April 14, 2025
|
||
| /s/ Alexandros Tsirikos | ||
| Alexandros Tsirikos | ||
| Chief Financial Officer (Principal Financial Officer) | ||
|
(1)
|
the Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and
|
|
(2)
|
the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.
|
|
Date: April 14, 2025
|
||
|
/s/ Evangelos J. Pistiolis
|
||
|
Evangelos J. Pistiolis
|
||
|
President, Chief Executive Officer and Director (Principal Executive Officer)
|
||
|
(1)
|
the Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and
|
|
(2)
|
the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.
|
|
Date: April 14, 2025
|
||
|
/s/ Alexandros Tsirikos
|
||
|
Alexandros Tsirikos
|
||
|
Chief Financial Officer (Principal Financial Officer)
|
||
|
/s/ Watson Farley & Williams LLP
|
|
|
Watson Farley & Williams LLP
|
|
|
New York, New York
|
|
|
April 14, 2025
|
|