Argan Inc 10-Q for FY2023 Q1
Argan Inc (AGX)
About this 10-Q
Argan Inc filed this 10-Q on June 8, 2022, covering the quarter ended April 30, 2022 (FY2023 Q1).
Headline figures
Quarter ended April 30, 2022, as reported in this filing, compared with the same period a year earlier where the filing states it.
- Revenue
- $100.28M
- down 20.6% from $126.34M a year earlier
- Net income
- $7.49M
- down 30.5% from net income of $10.77M a year earlier
- Diluted EPS
- $0.50
- down 25.4% from $0.67 a year earlier
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
FORM
(Mark One)
QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the Quarterly Period Ended
or
TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT |
For the Transition Period from to
Commission File Number
(Exact Name of Registrant as Specified in Its Charter)
| ||
(State or Other Jurisdiction of Incorporation) | | (I.R.S. Employer Identification No.) |
(Address of Principal Executive Offices) (Zip Code)
(
(Registrant’s Telephone Number, Including Area Code)
(Former Name, Former Address and Former Fiscal Year, if Changed since Last Report)
Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15 (d) of the Securities Exchange Act of 1934 (the “Exchange Act”) during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.
Indicate by check mark whether the Registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the Registrant was required to submit such files).
Indicate by check mark whether the Registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act.
Large accelerated filer ☐
If an emerging growth company, indicate by check mark if the Registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐
Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes
| | |||
Title of Each Class |
| Trading Symbol(s) |
| Name of Each Exchange on Which Registered |
| |
Indicate the number of shares outstanding of each of the Registrant’s classes of common stock, as of the latest practicable date.
Common stock, $0.15 par value:
ARGAN, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS
(In thousands, except per share data)
(Unaudited)
| | Three Months Ended | | ||||
| | April 30, | | ||||
|
| 2022 |
| 2021 | | ||
REVENUES | | $ | | | $ | | |
Cost of revenues | |
| | |
| | |
GROSS PROFIT | |
| | |
| | |
Selling, general and administrative expenses | |
| | |
| | |
INCOME FROM OPERATIONS | |
| | |
| | |
Other income, net | |
| | |
| | |
INCOME BEFORE INCOME TAXES | |
| | |
| | |
Income tax expense | |
| ( | |
| ( | |
NET INCOME | |
| | |
| | |
Net income attributable to the non-controlling interest | |
| — | |
| — | |
NET INCOME ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. | | | | | | | |
Foreign currency translation adjustments | | | ( | | | ( | |
COMPREHENSIVE INCOME ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. | | $ | | | $ | | |
| | | | | | | |
NET INCOME PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. | | | | | | | |
Basic | | $ | | | $ | | |
Diluted | | $ | | | $ | | |
| | | | | | | |
WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING | | | | | | | |
Basic | |
| | |
| | |
Diluted | |
| | |
| | |
| | | | | | | |
CASH DIVIDENDS PER SHARE | | $ | | | $ | | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
2
ARGAN, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED BALANCE SHEETS
(Dollars in thousands, except per share data)
|
| April 30, |
| January 31, | ||
|
| 2022 |
| 2022 | ||
| | (Unaudited) | | (Note 1) | ||
ASSETS | | | | | | |
CURRENT ASSETS | | | | | | |
Cash and cash equivalents | | $ | | | $ | |
Short-term investments | | | | | | |
Accounts receivable, net | |
| | |
| |
Contract assets | |
| | |
| |
Other current assets | |
| | |
| |
TOTAL CURRENT ASSETS | |
| | |
| |
Property, plant and equipment, net | |
| | |
| |
Goodwill | |
| | |
| |
Other purchased intangible assets, net | | | | | | |
Right-of-use, deferred tax and other assets | | | | | | |
TOTAL ASSETS | | $ | | | $ | |
| | | | | | |
LIABILITIES AND EQUITY | | | | | | |
CURRENT LIABILITIES | | | | | | |
Accounts payable | | $ | | | $ | |
Accrued expenses | |
| | |
| |
Contract liabilities | |
| | |
| |
TOTAL CURRENT LIABILITIES | |
| | |
| |
Noncurrent liabilities | | | | | | |
TOTAL LIABILITIES | |
| | |
| |
| | | | | | |
COMMITMENTS AND CONTINGENCIES | | | | | | |
| | | | | | |
STOCKHOLDERS’ EQUITY | | | | | | |
Preferred stock, par value $ | |
| |
| ||
Common stock, par value $ | |
| | |
| |
Additional paid-in capital | |
| | |
| |
Retained earnings | |
| | |
| |
Less treasury stock, at cost – | | | ( | | | ( |
Accumulated other comprehensive loss | | | ( | | | ( |
TOTAL STOCKHOLDERS’ EQUITY | |
| | |
| |
Non-controlling interest | |
| ( | |
| ( |
TOTAL EQUITY | |
| | |
| |
TOTAL LIABILITIES AND EQUITY | | $ | | | $ | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
3
ARGAN, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY
FOR THE THREE MONTHS ENDED APRIL 30, 2022 AND 2021
(Dollars in thousands)
(Unaudited)
| | Common Stock | | Additional | | | | | | | Accumulated | | | | | | | ||||||
|
| Outstanding |
| Par |
| Paid-in |
| Retained |
| Treasury |
| Other Comprehensive |
| Non-controlling |
| Total | |||||||
| | Shares | | Value | | Capital | | Earnings | | Stock | | Loss | | Interest | | Equity | |||||||
Balances, February 1, 2022 |
| | | $ | | | $ | | | $ | | | $ | ( | | $ | ( | | $ | ( | | $ | |
Net income |
| — | | | — | | | — | | | | | | — | | | — | | | — | | | |
Foreign currency translation loss | | — | | | — | | | — | | | — | | | — | | | ( | | | — | | | ( |
Stock compensation expense | | — | | | — | | | | | | — | | | — | | | — | | | — | | | |
Stock option exercises and other share-based award settlements |
| | | | | | | | | | — | | | — | | | — | | | — | | | |
Common stock repurchases | | ( | | | — | | | — | | | — | | | ( | | | — | | | — | | | ( |
Cash dividends |
| — | | | — | | | — | | | ( | | | — | | | — | | | — | | | ( |
Balances, April 30, 2022 |
| | | $ | | | $ | | | $ | | | $ | ( | | $ | ( | | $ | ( | | $ | |
| | | | | | | | | | | | | | | | | | | | | | | |
Balances, February 1, 2021 | | | | $ | | | $ | | | $ | | | $ | ( | | $ | ( | | $ | | | $ | |
Net income | | — | | | — | | | — | | | | | | — | | | — | | | — | | | |
Foreign currency translation loss | | — | | | — | | | — | | | — | | | — | | | ( | | | — | | | ( |
Stock compensation expense | | — | | | — | | | | | | — | | | — | | | — | | | — | | | |
Stock option exercises and other share-based award settlements |
| | | | | | | | | | — | | | — | | | — | | | — | | | |
Cash dividends | | — | | | — | | | — | | | ( | | | — | | | — | | | — | | | ( |
Balances, April 30, 2021 | | | | $ | | | $ | | | $ | | | $ | ( | | $ | ( | | $ | | | $ | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
4
ARGAN, INC. AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS
(In thousands)
(Unaudited)
|
| Three Months Ended April 30, | | ||||
|
| 2022 |
| 2021 | | ||
CASH FLOWS FROM OPERATING ACTIVITIES | | | | | | | |
Net income | | $ | | | $ | | |
Adjustments to reconcile net income to net cash (used in) provided by operating activities | | | | | | | |
Stock compensation expense | | | | | | | |
Depreciation | |
| | |
| | |
Lease expense | | | | | | | |
Deferred income tax expense | | | | | | | |
Amortization of purchased intangible assets | |
| | |
| | |
Other | |
| ( | |
| ( | |
Changes in operating assets and liabilities | | | | | | | |
Accounts receivable | |
| ( | |
| ( | |
Contract assets | | | ( | | | | |
Other assets | |
| ( | |
| | |
Accounts payable and accrued expenses | |
| ( | |
| ( | |
Contract liabilities | | | ( | | | | |
Net cash (used in) provided by operating activities | |
| ( | |
| | |
| | | | | | | |
CASH FLOWS FROM INVESTING ACTIVITIES | | | | | | | |
Purchases of short-term investments | | | ( | | | — | |
Maturities of short-term investments | | | 90,000 | | | 20,000 | |
Purchases of property, plant and equipment | |
| (238) | |
| (844) | |
Investments in solar energy projects | |
| — | |
| ( | |
Net cash (used in) provided by investing activities | |
| ( | |
| | |
| | | | | | | |
CASH FLOWS FROM FINANCING ACTIVITIES | | | | | | | |
Common stock repurchases | | | ( | | | — | |
Payments of cash dividends | |
| ( | |
| ( | |
Proceeds from the exercise of stock options | |
| | |
| | |
Net cash used in financing activities | |
| ( | |
| ( | |
| | | | | | | |
EFFECTS OF EXCHANGE RATE CHANGES ON CASH | | | ( | | | ( | |
NET (DECREASE) INCREASE IN CASH AND CASH EQUIVALENTS | |
| ( | |
| | |
CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD | | | | | | | |
CASH AND CASH EQUIVALENTS, END OF PERIOD | | $ | | | $ | | |
| | | | | | | |
SUPPLEMENTAL CASH FLOW INFORMATION (see Notes 7 and 10) | | | | | | | |
The accompanying notes are an integral part of these condensed consolidated financial statements.
5
ARGAN, INC. AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
April 30, 2022
(Tabular dollar amounts in thousands, except per share data)
(Unaudited)
NOTE 1 – DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION
Description of the Business
Argan, Inc. (“Argan”) conducts operations through its wholly-owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”
Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the United States (the “U.S.”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “U.K.”). GPS and APC, including a consolidated variable interest entity (“VIE”), represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeastern region of the U.S. and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the Mid-Atlantic region of the U.S.
Basis of Presentation and Significant Accounting Policies
The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and the VIE. All significant inter-company balances and transactions have been eliminated in consolidation.
In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions.
The Company’s fiscal year ends on January 31 of each year. The condensed consolidated balance sheet as of April 30, 2022, the condensed consolidated statements of earnings and stockholders’ equity for the three months ended April 30, 2022 and 2021, and the condensed consolidated statements of cash flows for the three months ended April 30, 2022 and 2021 are unaudited. The condensed consolidated balance sheet as of January 31, 2022 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the U.S. Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2022 (“Fiscal 2022”).
In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of April 30, 2022, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.
6
Accounting Policies
There are no recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.
Fair Values
The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.
Variable Interest Entity
In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consequently, the account balances of the VIE are included in the Company’s consolidated financial statements, including development costs incurred by the VIE during the project development period. Consideration for the Company’s engineering and financial support provided to the project included the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that was negotiated and announced.
GPS provided financing for the development efforts through notes receivable from the consolidated VIE that was established by the project owner. The project owner was unable to obtain the necessary equity financing for the project and GPS ceased providing project development funding. The repayment of the notes to GPS is overdue and the VIE has rejected the Company’s efforts to foreclose on the defaulted debt in an orderly fashion. Accordingly, the Company believes that the completion of the development of this project has been significantly jeopardized and that it is doubtful that construction of this power plant will occur. Accordingly, during the fourth quarter of Fiscal 2022, we recorded an impairment loss related to the capitalized project development costs of this project in the amount of $
NOTE 2 – REVENUES FROM CONTRACTS WITH CUSTOMERS
The Company’s accounting for revenues on contracts with customers is based on a single comprehensive five-step model that requires reporting entities to:
| 1. | Identify the contract, |
| 2. | Identify the performance obligations of the contract, |
| 3. | Determine the transaction price of the contract, |
| 4. | Allocate the transaction price to the performance obligations, and |
| 5. | Recognize revenue. |
The Company focuses on the transfer of the contractor’s control of the goods and/or services to the customer, as opposed to the transfer of risk and rewards. Major provisions of the current guidance cover the determination of which goods and services are distinct and represent separate performance obligations, the appropriate treatments for variable consideration, and the evaluation of whether revenues should be recognized at a point in time or over time.
When a performance obligation is satisfied over time, the related revenues are recognized over time. The Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed-price or a time-and-materials basis, and primarily over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer.
Revenues from fixed-price contracts, including portions of estimated gross profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the cost-to-cost approach. If, at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period in which it is identified and the loss amount becomes estimable. Revenues from time-and-materials contracts are recognized when the related services are provided to the customer.
7
Almost all of the Company’s fixed-price contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of such contracts because contract promises included therein are interrelated or the contracts require the Company to perform critical integration so that the customer receives a completed project. Warranties provided under the Company’s contracts with customers are assurance-type primarily and are recorded as the corresponding contract work is performed.
The transaction price for a contract represents the value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as changes in the scope and price of contracts, claims, incentives and liquidated damages.
Contract assets include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities include amounts that reflect obligations to provide goods or services for which payment has been received. Contract retentions are billed amounts which, pursuant to the terms of the applicable contract, are not paid by project owners until a defined phase of a contract or project has been completed and accepted. These retained amounts are reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retainage amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at April 30, 2022 and January 31, 2022 were $
Variable Consideration
Amounts for contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. The aggregate amounts of such contract variations included in the transaction prices that were used to determine project-to-date revenues at April 30, 2022 and January 31, 2022 were $
The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. These contract requirements generally relate to specified activities that must be completed by an established date or by the achievement of a specified level of output or efficiency. Each applicable contract defines the conditions under which a project owner may be entitled to any liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not subtracted from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract. The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved. The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects.
In other cases, the Company may have the grounds to assert liquidated damages against subcontractors, suppliers, project owners or other parties related to a project. Such circumstances may arise when the Company’s activities and progress are adversely affected by delayed or damaged materials, challenges with equipment performance or other events out of the Company’s control where the Company has rights to recourse, typically in the form of liquidated damages.
8
In general, the Company does not adjust the corresponding contract accounting until it is probable that the favorable cost relief will be realized. Such adjustments have been and could be material.
The Company records adjustments to revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.
Remaining Unsatisfied Performance Obligations (“RUPO”)
The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under the revenue recognition rules of U.S. GAAP. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations.
At April 30, 2022, the Company had RUPO of $
It is important to note that estimates may be changed in the future and that cancellations, deferrals, or scope adjustments may occur related to work included in the amount of RUPO at April 30, 2022. Accordingly, RUPO may be adjusted to reflect project delays and cancellations, revisions to project scope and cost and foreign currency exchange fluctuations, or to revise estimates, as effects become known. Such adjustments may materially reduce future revenues below Company estimates.
Disaggregation of Revenues
The following table presents consolidated revenues for the three months ended April 30, 2022 and 2021, disaggregated by the geographic area where the corresponding projects were located:
| Three Months Ended April 30, | ||||
| 2022 |
| 2021 | ||
United States | $ | | | $ | |
United Kingdom |
| | |
| |
Republic of Ireland |
| | |
| |
Consolidated Revenues | $ | | | $ | |
The major portion of the Company’s consolidated revenues are recognized pursuant to fixed-price contracts with most of the remaining portions earned pursuant to time-and-material contracts. Consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements.
NOTE 3 – CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS
At April 30, 2022 and January 31, 2022, significant amounts of cash equivalents were invested in money market funds with net assets invested in high-quality money market instruments. Such investments include U.S. Treasury obligations; obligations of U.S. government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by U.S. government obligations. Due to market conditions, returns on money market instruments are currently minimal. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.
9
Short-term investments as of April 30, 2022 and January 31, 2022 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of less than
The Company has a substantial portion of its cash on deposit in the U.S. with the Bank. The Company also maintains certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the U.K. in support of the operations of APC. Management does not believe that the combined amount of the CDs and the cash deposited with the Bank and cash balances maintained at financial institutions in Ireland and the U.K., in excess of government-insured levels, represent material risks.
NOTE 4 – ACCOUNTS AND NOTES RECEIVABLE
The Company generally extends credit to a customer based on an evaluation of the customer’s financial condition, without requiring tangible collateral. Exposure to losses on accounts and notes receivable is expected to differ due to the varying financial condition of each customer. The Company monitors its exposure to credit losses and may establish an allowance for credit losses based on management’s estimate of the loss that is expected to occur over the remaining life of the particular financial asset. The amounts of any credit losses for the three months ended April 30, 2022 and 2021 were insignificant. The amount of the allowance for credit losses at both April 30, 2022 and January 31, 2022 was $
NOTE 5 – PURCHASED INTANGIBLE ASSETS
At both April 30, 2022 and January 31, 2022, the goodwill balances related to the acquisitions of GPS and TRC were $
The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of April 30, 2022 and January 31, 2022:
| | | | April 30, 2022 | | January 31, | ||||||||
| | Estimated | | Gross | | Accumulated | | Net | | 2022, (net | ||||
|
| Useful Life |
| Amounts |
| Amortization |
| Amounts |
| amounts) | ||||
|
| | | | | | | | | | | | | |
Trade name (TRC) | | | $ | | | $ | | | $ | | | $ | | |
Process certifications (TRC) |
| |
| | | | | | | | | | | |
Customer relationships (TRC) | | | | | | | | | | | | | | |
Customer contracts (SMC) | | < | | | | | | — | | | | | | |
Totals | | | | $ | | | $ | | | $ | | $ | | |
NOTE 6 – FINANCING ARRANGEMENTS
During April 2021, the Company amended its Amended and Restated Replacement Credit Agreement with the Bank (the “Credit Agreement”). The amendment extended the expiration date of the Credit Agreement to May 31, 2024 and reduced the borrowing rate. The Credit Agreement includes the following features, among others: a lending commitment of $
The Company may also use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business as defined in the Credit Agreement.
At April 30, 2022, the Company did not have any borrowings outstanding under the Credit Agreement. However, the Bank has issued outstanding letters of credit in the total amount of $
10
30, 2022 and January 31, 2022, for which the Company has provided cash collateral. As of April 30, 2022, no amounts have been drawn against this letter of credit.
The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement includes other terms, covenants and events of default that are customary for a credit facility of its size and nature, including a requirement to achieve positive adjusted earnings before interest, taxes, depreciation and amortization, as defined, over each rolling twelve-month measurement period. As of April 30, 2022 and January 31, 2022, the Company was in compliance with the covenants of the Credit Agreement.
The Company expects to amend the Credit Agreement during Fiscal 2023 in order to replace LIBOR with an equivalent benchmark rate. The Company does not expect that the change will materially impact its consolidated financial statements.
NOTE 7 – COMMITMENTS
Leases
The Company’s leases are primarily operating leases that cover office space, expiring on various dates through September 2031, and certain equipment used by the Company in the performance of its construction services contracts. Some of these equipment leases may be embedded in broader agreements with subcontractors or construction equipment suppliers. The Company has no material finance leases. None of the operating leases includes significant amounts for incentives, rent holidays or price escalations. Under certain leases, the Company is obligated to pay property taxes, insurance, and maintenance costs.
Operating lease right-of-use assets and associated lease liabilities are recorded in the balance sheet at the lease commencement date based on the present value of future minimum lease payments to be made over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate (currently LIBOR plus
Operating lease expense amounts are recorded on a straight-line basis over the expected lease terms and were $
The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of April 30, 2022.
Years Ending January 31, | |||
2023 (remainder) |
| $ | |
2024 | | | |
2025 | | | |
2026 | | | |
2027 | | | |
Thereafter | | | |
Total lease payments | | | |
Less interest portion | | | |
Present value of lease payments | | | |
| | | |
| $ | | |
11
Monthly payments for the occupancy by TRC of its primary offices and plant, which are made to the founder and retired chief executive officer of TRC based on an annual rental rate of $
The Company also uses equipment and occupies other facilities under short-term rental agreements. Rent expense amounts incurred under operating leases and short-term rental agreements (including portions of the lease expense amounts disclosed above) and included in costs of revenues for the three months ended April 30, 2022 and 2021 were $
Performance Bonds and Guarantees
In the normal course of business and for certain major projects, the Company may be required to obtain surety or performance bonding, to cause the issuance of letters of credit, or to provide parent company guarantees (or some combination thereof) in order to provide performance assurances to clients on behalf of its contractor subsidiaries. As these subsidiaries are wholly-owned, any actual liability is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. When sufficient information about claims on guaranteed or bonded projects would be available and monetary damages or other costs or losses would be determined to be probable, the Company would record such losses. Any amounts that may be required to be paid in excess of the estimated costs to complete contracts in progress as of April 30, 2022 are not estimable.
As of April 30, 2022, the value of the Company’s unsatisfied bonded performance obligations, covering all of its subsidiaries, was approximately $
As of April 30, 2022 and January 31, 2022, the Company had also provided a financial guarantee, subject to certain terms and conditions, on behalf of GPS to an original equipment manufacturer in the amount of $
Warranties
The Company generally provides assurance-type warranties for work performed under its construction contracts. The warranties cover defects in equipment, materials, design or workmanship, and most warranty periods typically run from to
NOTE 8 – LEGAL CONTINGENCIES
In the normal course of business, the Company may have pending claims and legal proceedings. In the opinion of management, based on information available at this time, there are no current claims and proceedings that are expected to have a material adverse effect on the condensed consolidated financial statements as of April 30, 2022.
NOTE 9 – STOCK-BASED COMPENSATION
On June 23, 2020, the Company’s stockholders approved the adoption of the 2020 Stock Plan (the “2020 Plan”), and the allocation of
12
The features of the 2020 Plan are similar to those included in the 2011 Plan. Awards may include nonqualified stock options, incentive stock options, and restricted or unrestricted stock. The specific provisions for awards are documented in a written agreement between the Company and the awardee. All stock options awarded under the Stock Plans have exercise prices per share at least equal to the common stock’s market value on the date of grant. Stock options have terms no longer than
As of April 30, 2022, there were
Stock Options
A summary of stock option activity under the Stock Plans for the three months ended April 30, 2022, along with corresponding weighted average per share amounts, is presented below (shares in thousands):
| | | | Exercise | | Remaining | | | ||
|
| Shares |
| Price |
| Term (years) |
| Fair Value | ||
Outstanding, February 1, 2022 |
| | | $ | |
| | $ | | |
Granted | | | | $ | | | | | | |
Exercised | | ( | | $ | | | | | | |
Forfeited | | ( | | $ | | | | | | |
Outstanding, April 30, 2022 | | | | $ | |
| | $ | | |
Exercisable, April 30, 2022 |
| | | $ | | | | $ | | |
| | | | | | | | | | |
Outstanding, April 30, 2021 | | | | $ | |
| | $ | | |
Exercisable, April 30, 2021 |
| | | $ | |
| | $ | | |
The changes in the number of non-vested options to purchase shares of common stock for the three months ended April 30, 2022, and the weighted average fair value per share for each number, are presented below (shares in thousands):
|
| Shares |
| Fair Value | |
Non-vested, February 1, 2022 |
| | | $ | |
Granted |
| | | $ | |
Vested |
| ( | | $ | |
Non-vested, April 30, 2022 |
| | | $ | |
| | | | | |
Non-vested, April 30, 2021 |
| | | $ | |
The total intrinsic value amounts of the stock options exercised during the three months ended April 30, 2022 and 2021 were not significant. At April 30, 2022, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $
Restricted Stock Units
The Company awards restricted stock units to senior executives, members of the Company’s board of directors and certain other employees. Awardees earn the right to receive shares of common stock as certain performance goals are achieved and/or service periods are satisfied. Each restricted stock unit expires on the three-year anniversary of the award.
During the three months ended April 30, 2022, the Company awarded
13
The changes in the maximum number of restricted stock units for the three months ended April 30, 2022, and the weighted average fair value per share for each number, are presented below (shares in thousands):
|
| Shares |
| Fair Value | |
Outstanding, February 1, 2022 |
| | | $ | |
Awarded |
| | $ | | |
Issued | | ( | | $ | |
Forfeited | | ( | | $ | |
Outstanding, April 30, 2022 |
| | | $ | |
| | | | | |
Outstanding, April 30, 2021 |
| | | $ | |
| | | | | |
Fair Value
The fair value amounts of stock options and restricted stock units are recorded as stock compensation expense over the terms of the corresponding awards. Expense amounts related to stock awards were $
The Company estimates the weighted average fair value of stock options on the date of award using a Black-Scholes option pricing model. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. Risk-free interest rates are determined by blending the rates for to-
The fair value amounts for the performance-based restricted stock units have been determined by using the per share market price of the Company’s common stock on the dates of award and the target number of shares for the awards (
NOTE 10 – INCOME TAXES
Income Tax Expense Reconciliations
The Company’s income tax amounts for the three months ended April 30, 2022 and 2021 differed from corresponding amounts computed by applying the federal corporate income tax rate of
|
| Three Months Ended April 30, | | ||||
|
| 2022 |
| 2021 | | ||
Computed expected income tax expense | | $ | ( | | $ | ( | |
Difference resulting from: | | | | | | | |
State income taxes, net of federal tax effect | |
| ( | |
| ( | |
Deferred tax asset adjustments | | | ( | | | ( | |
Other permanent differences and adjustments, net | |
| ( | |
| ( | |
Income tax expense | | $ | ( | | $ | ( | |
Foreign income tax expense amounts for the three months ended April 30, 2022 and 2021 were not material.
14
Net Operating Loss (“NOL”) Carryback
In an effort to combat the adverse economic impacts of the COVID-19 crisis, the U.S. Congress passed the Coronavirus, Aid, Relief, and Economic Security Act ( the “CARES Act”) that was signed into law on March 27, 2020. This wide-ranging legislation was an emergency economic stimulus package that included spending and tax breaks aimed at strengthening the U.S. economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19.
The tax changes of the CARES Act included a temporary suspension of the limitations on the future utilization of certain NOLs and re-established a carryback period for certain losses to
Research and Development Tax Credits
During the year ended January 31, 2019 (“Fiscal 2019”), the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development tax credits that may have been available to reduce prior year income taxes. This study focused on project costs incurred during the
The research and development credits claimed by the Company in its federal income tax returns were examined by the IRS. The conclusions of the IRS were formally protested by the Company and the results of the appeals hearing that occurred in May 2022 are described in Note 15.
Income Tax Refunds
As of April 30, 2022 and January 31, 2022, the balances of other current assets in the condensed consolidated balance sheet included income tax refunds receivable and prepaid income taxes in the total amounts of approximately $
Income Tax Returns
The Company is subject to federal and state income taxes in the U.S., and income taxes in Ireland and the U.K. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2018 (“Fiscal 2018”) except for several notable exceptions including Ireland, the U.K. and several states where the open periods are one year longer.
Solar Energy Projects
The Company has invested in limited liability companies that make equity investments in solar energy projects that are eligible to receive energy tax credits. The passive investments have been accounted for under the equity method and the balances are included in other assets in our condensed consolidated balance sheets. Each tax credit, when recognized, is recorded as a reduction of the corresponding investment balance with an offsetting reduction in the balance of accrued taxes payable in accordance with the deferral method. At April 30, 2022 and January 31, 2022, the investment account balances were $
15
For the three-month period ended April 30, 2022, the investment balance was adjusted to reflect its share of the income of the investment entities in the amount of approximately $
The Company has also established deferred taxes related to the difference in the book and tax bases of the investments.
Supplemental Cash Flow Information
The Company was not required to make any income tax payments during the three months ended April 30, 2022 or 2021. During the three months ended April 30, 2022 and 2021, the Company did not receive any income tax refunds that were material.
NOTE 11 – NET INCOME PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN
Basic and diluted net income per share amounts are computed as follows (shares in thousands except in the note):
| | Three Months Ended April 30, | ||||
|
| 2022 |
| 2021 | ||
| | | | | | |
Net income attributable to the stockholders of Argan | | $ | | | $ | |
| | | | | | |
Weighted average number of shares outstanding – basic | | | | | | |
Effect of stock awards (1) | | | | | | |
Weighted average number of shares outstanding – diluted | | | | | | |
| | | | | | |
Net income per share attributable to the stockholders of Argan | | | | | | |
Basic | | $ | | | $ | |
Diluted | | $ | | | $ | |
| (1) | For the three months ended April 30, 2022 and 2021, the weighted average numbers of shares determined on a dilutive basis exclude the effects of antidilutive stock options covering an aggregate of |
NOTE 12 – CASH DIVIDENDS AND COMMON STOCK REPURCHASES
On April 11, 2022, Argan’s board of directors declared a regular quarterly cash dividend in the amount of $
Pursuant to authorizations provided by Argan’s board of directors (the “Share Repurchase Plan”), the Company repurchased shares of its common stock during the three months ended April 30, 2022. During this period, the Company repurchased
NOTE 13 – CUSTOMER CONCENTRATIONS
The majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided
The Company’s most significant customer relationship for the three months ended April 30, 2022 included
16
The accounts receivable balances from
NOTE 14 – SEGMENT REPORTING
Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than
Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three months ended April 30, 2022 and 2021. The “Other” column in each summary includes the Company’s corporate expenses.
Three Months Ended | | Power | | Industrial | | Telecom | | | | | |||||
April 30, 2022 |
| Services |
| Services |
| Services |
| Other |
| Totals | |||||
Revenues | | $ | | | $ | | | $ | | | $ | — | | $ | |
Cost of revenues | |
| | |
| | |
| | |
| — | |
| |
Gross profit | |
| | |
| | |
| | |
| — | |
| |
Selling, general and administrative expenses | |
| | | | | | | | | | | | | |
Income (loss) from operations | | | | | | | | | | | | ( | | | |
Other income, net | |
| | |
| — | |
| | |
| | |
| |
Income (loss) before income taxes | | $ | | | $ | | | $ | | | $ | ( | |
| |
Income tax expense | | | | | | | | | | | | | |
| ( |
Net income | | | | | | | | | | | | | | $ | |
| | | | | | | | | | | | | | | |
Amortization of intangibles | | $ | — | | $ | | | $ | — | | $ | — | | $ | |
Depreciation | | | | | | | | | | | | | | | |
Property, plant and equipment additions | | | | | | | | | | | | — | | | |
| | | | | | | | | | | | | | | |
Current assets | | $ | | | $ | | | $ | | | $ | | | $ | |
Current liabilities | | | | | | | | | | | | | | | |
Goodwill | | | | | | | | | | | | — | | | |
Total assets | | | | | | | | | | | | | | | |
17
Three Months Ended | | Power | | Industrial | | Telecom | | | | | |||||
April 30, 2021 |
| Services |
| Services |
| Services |
| Other |
| Totals | |||||
Revenues | | $ | | | $ | | | $ | | | $ | — | | $ | |
Cost of revenues | |
| | |
| | |
| | |
| — | |
| |
Gross profit | |
| | |
| | |
| | |
| — | |
| |
Selling, general and administrative expenses | |
| | | | | | | | | | | |
| |
Income (loss) from operations | | | | | | | | | | | | ( | | | |
Other income, net | |
| | |
| — | |
| — | |
| | |
| |
Income (loss) before income taxes | | $ | | | $ | | | $ | | | $ | ( | |
| |
Income tax expense | | | | | | | | | | | | | |
| ( |
Net income | | | | | | | | | | | | | | $ | |
| | | | | | | | | | | | | | | |
Amortization of intangibles | | $ | | | $ | | | $ | — | | $ | — | | $ | |
Depreciation | | | | | | | | | | | | | | | |
Property, plant and equipment additions | | | | | | | | | | | | | | | |
| | | | | | | | | | | | | | | |
Current assets | | $ | | | $ | | | $ | | | $ | | | $ | |
Current liabilities | | | | | | | | | | | | | | | |
Goodwill | | | | | | | | | — | | | — | | | |
Total assets | | | | | | | | | | | | | | | |
NOTE 15 – SUBSEQUENT EVENTS
Income Tax Return Examinations
During the fiscal year ended January 31, 2021, the IRS concluded examinations of the Company’s consolidated federal income tax returns for Fiscal 2016, as amended; Fiscal 2017, as amended; and Fiscal 2018 with its focus on the research and development tax credits included therein.
In January 2021, the IRS issued its final revenue agents reports that documented its understanding of the facts, attempted to summarize the Company’s arguments in support of the research and development claims and stated its position which disagreed with the Company’s treatment of a substantial amount of the costs that support the Company’s claims. In March 2021, the Company submitted a formal protest of the findings of the IRS examiner and requested an appeals hearing.
At the conclusion of the hearing that occurred in May 2022, the Company agreed to accept a settlement offer from the IRS in the amount of approximately $
Common Stock Repurchases
Subsequent to April 30, 2022, the Company repurchased shares of its common stock pursuant to the Share Repurchase Plan. As of June 8, 2022, the Company had repurchased
ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS
The following discussion summarizes the financial position of Argan, Inc. and its subsidiaries as of April 30, 2022, and the results of their operations for the three month periods ended April 30, 2022 and 2021, and should be read in conjunction with (i) the unaudited condensed consolidated financial statements and notes thereto included elsewhere in this Quarterly Report on Form 10-Q and (ii) the consolidated financial statements and accompanying notes included in our Annual Report on Form 10-K for Fiscal 2022 that was filed with the SEC on April 13, 2022 (the “Annual Report”).
18
Cautionary Statement Regarding Forward Looking Statements
The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for certain forward-looking statements. We have made statements in this Item 2 and elsewhere in this Quarterly Report on Form 10-Q that may constitute “forward-looking statements.” The words “believe,” “expect,” “anticipate,” “plan,” “intend,” “estimate,” “foresee,” “should,” “would,” “could,” or other similar expressions are intended to identify forward-looking statements. Our forward-looking statements, including those relating to the potential effects of the COVID-19 pandemic on our business, financial position and results of operations, are based on our current expectations and beliefs concerning future developments and their potential effects on us. There can be no assurance that future developments affecting us will be those that we anticipate. All comments concerning our expectations for future revenues and operating results are based on our forecasts for existing operations and do not include the potential impact of any future acquisitions.
Our forward-looking statements, by their nature, involve significant risks and uncertainties (some of which are beyond our control) and assumptions. They are subject to change based upon various factors including, but not limited to, the risks and uncertainties described in this Quarterly Report on Form 10-Q and our Annual Report. Should one or more of these risks or uncertainties materialize, or should any of our assumptions prove to be incorrect, actual results may vary in material respects from those projected in the forward-looking statements. We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise.
Business Description
Argan is a holding company that conducts operations through its wholly-owned subsidiaries, GPS, APC, SMC and TRC. Through GPS and APC, we provide a full range of engineering, procurement, construction, commissioning, operations management, maintenance, development, technical and consulting services to the power generation market, including the renewable energy sector, for a wide range of customers, including independent power project owners, public utilities, global energy plant construction firms and other commercial firms with significant power requirements. GPS and APC represent our power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeast region of the U.S. and that are based on its expertise in producing, delivering and installing fabricated steel components such as piping systems and pressure vessels. Through SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the Mid-Atlantic region of the U.S.
We intend to make additional opportunistic acquisitions and/or investments by identifying companies with significant potential for profitable growth and realizable synergies with one or more of our existing businesses. However, we may have more than one industrial focus depending on the opportunity. We expect that significant acquired companies will be operated in a manner that best provides cash flows for the Company and value for our stockholders.
Overview
Operating Results
Consolidated revenues for the three months ended April 30, 2022 were $100.3 million, which represented a decrease of $26.0 million, or 20.6%, from consolidated revenues of $126.3 million reported for the three months ended April 30, 2021.
The revenues of the power industry services segment decreased by $23.2 million to $73.9 million for the three months ended April 30, 2022, from $97.2 million reported for the three months ended April 30, 2021. The revenues of this reportable segment of our business represented 73.7% and 76.9% of corresponding consolidated revenues for the three months ended April 30, 2022 and 2021, respectively. The industrial services business reported revenues of $22.5 million for the three months ended April 30, 2022. This amount represented a decrease of $4.2 million, or 15.7%, from revenues of $26.7 million reported by TRC for the three months ended April 30, 2021. Revenues provided by this reportable business segment represented 22.4% and 21.1% of corresponding consolidated revenues for the three months ended April 30, 2022 and 2021, respectively.
19
Consolidated gross profit for the three-month period ended April 30, 2022 was $19.7 million, or 19.6% of the corresponding consolidated revenues, which reflected primarily favorable contributions from the power industry services and industrial services segments. For the three-month period ended April 30, 2021, the consolidated gross profit was $23.7 million, which represented approximately 18.8% of the corresponding amount of consolidated revenues.
Selling, general and administrative expenses for the three months ended April 30, 2022 and 2021 were $10.6 million, or 10.6% of corresponding consolidated revenues, and $9.9 million, or 7.8% of corresponding consolidated revenues, respectively.
Due primarily to the decrease in consolidated pre-tax book income to $9.8 million for the three months ended April 30, 2022 from $14.5 million for the three months ended April 30, 2021, we reported income tax expense in the amount of $2.3 million for the current period. Income tax expense for the three months ended April 30, 2021 was $3.8 million.
For the three months ended April 30, 2022, our favorable overall operating profit performance resulted in net income attributable to our stockholders in the amount of $7.5 million, or $0.50 per diluted share. For the comparable period last year, we reported net income attributable to our stockholders in the amount of $10.8 million, or $0.67 per dilutive share.
The primary drivers of our financial performance for the three months ended April 30, 2022 and 2021 were the revenues and gross margin contributions associated with the construction projects of GPS. These projects represented the largest portion of our business for the periods.
All of our businesses have been adversely impacted, to some degree, by difficulties presented by the COVID-19 pandemic.
We believe that all of our operating companies have managed the challenges presented by this ongoing pandemic with relative success so far. A significant amount of effort has been spent by senior and project management to ensure the safety of our employees during the COVID-19 pandemic while we continued to satisfy our customer obligations. However, the resurgence of new COVID-19 virus variants represents uncertainty regarding our realizing expected financial results for the remainder of the year if new outbreaks prevent our work crews from completing project work as scheduled.
Engineering, Procurement and Construction Service Contracts
At April 30, 2022, our consolidated project backlog amount of $0.7 billion substantially consisted of the projects of the power industry services reporting segment. The comparable backlog amount as of January 31, 2022 was also $0.7 billion. Our reported amount of project backlog at a point in time represents the total value of projects awarded to us that we consider to be firm as of that date less the amounts of revenues recognized to date on the corresponding projects (project backlog is larger than the value of remaining unsatisfied performance obligations, or RUPO, on active contracts; see Note 2 to the accompanying consolidated financial statements).
Typically, we include the total value of EPC services and other major construction contracts in project backlog when we receive a corresponding notice to proceed from the project owner. However, we may include the value of an EPC services contract prior to the receipt of a notice to proceed if we believe that it is probable that the project will commence within a reasonable timeframe, among other factors. Projects that are awarded to us may remain included in our backlog for extended periods of time as customers experience project delays. However, cancellations or reductions may occur that would reduce project backlog and that could adversely affect our expected future revenues.
A meaningful amount of the project backlog amount at April 30, 2022 was represented by the Guernsey Power Station, the largest single-phase, gas-fired, power plant construction project in the U.S. Substantial completion of this project is currently scheduled to occur near the end of Fiscal 2023.
Despite our commitment to the construction of state-of-the-art, natural gas-fired power plants as important elements of our country’s electricity-generation mix in the future, we have been directing certain business development efforts to winning projects for the erection of utility-scale wind farms and solar fields and for the construction of hydrogen-based and other renewable energy projects. We have successfully completed these types of projects in the past and we have renewed efforts to obtain new work in the renewable power sector that will complement our natural gas-fired EPC services projects going forward.
20
These efforts led to our announcement in May 2021 that GPS entered into an EPC services contract with CPV Maple Hill Solar, LLC, an affiliate of Competitive Power Ventures, Inc., to construct the Maple Hill Solar facility, which we believe will be among the largest solar-powered energy plants in Pennsylvania. Project activities were begun by GPS immediately. Project completion is currently scheduled to occur during the second half of Fiscal 2023. The unique Maple Hill Solar project, which is located in Cambria County, is being constructed using over 235,000 photovoltaic modules to generate approximately 100 MW of electrical power.
The business development efforts conducted by our APC operations have resulted in a significant increase in the project backlog of this business. The most significant award occurred in October 2021 as APC entered into an engineering and construction services contract with EPUKI London, U.K., to construct a 2 x 330 MW natural gas-fired power plant in Carrickfergus that is near Belfast, Northern Ireland, and that will replace coal-fired units at the site. The facility, referred to as the “Kilroot” project, is being developed by EPNI Energy Limited. A notice to proceed was received and project activities have commenced. The overall completion of this project is expected to occur in the latter half of Fiscal 2024.
We recently announced that, in May 2022, APC entered into engineering and construction services contracts with the Electricity Supply Board (“ESB”) to construct three 65 MW aero-derivative gas turbine flexible generation power plants in and around Dublin, Ireland. Two of the power plants, the Poolbeg and Ringsend FlexGen Power Plants, will be located on the Poolbeg Peninsula, and the Corduff FlexGen Power Plant will be built in Goddamendy, Dublin. All three projects cleared the applicable capacity auction earlier this year and are expected to operate intermittently during peak periods of electricity demand and as back-up supply options when renewable electricity generation is limited. A full notice to proceed has been received and project activities have commenced. The completion of each power plant is expected to occur near the end of Fiscal 2024.
Market Outlook
The overall growth of our power business has been substantially based on the number of combined cycle gas-fired power plants built by us, as many coal-fired plants have been shut down. In 2010, coal-fired power plants accounted for about 45% of net electricity generation. For 2021, coal fueled approximately 22% of net electricity generation. On the other hand, natural-gas fired power plants provided approximately 38% of the electricity generated by utility-scale power plants in the U.S. in 2021, representing an increase of 60% from the amount of electrical power generated by natural gas-fired power plants in 2010, which provided approximately 24% of net electricity generation for 2010. Undoubtedly, the long-term historic decline in the use of coal as a power source in the U.S. was caused, to a significant extent, by the plentiful supply of domestic and generally inexpensive natural gas which made it the fuel of choice for power plant developers over this period.
In the reference case of its Annual Energy Outlook 2022, the Energy Information Administration (“EIA”) projects average increases to utility-scale electricity generation in the U.S. of slightly less than 1% per year from 2022 through 2050. The shift from coal to natural gas as a power plant energy source in the U.S. is expected to continue as the EIA projects that coal-fired generation will decline by 45% from 2022 through 2050, and will represent only 11% of the net electricity generation mix by the end of this period. The net electricity generation from natural gas-fired power plants is projected to increase by 17% in the U.S. by 2050. The pace of the historic increase in the preference for natural gas as an electricity generating fuel source also was energized, in part, by environmental activism and restrictive regulations targeting coal-fired power plants. Now, the environmentalist opposition against coal-fired power generation has expanded meaningfully to target all fossil fuel energy projects, including power plants and pipelines, and has evolved into powerful support for renewable energy sources.
Protests against fossil-fuel related energy projects continue to garner media attention and stir public skepticism about new projects resulting in delays due to onsite protest demonstrations, indecision by local officials and lawsuits. Various cities, counties and states have adopted clean energy and carbon-free goals or objectives with achievement expected by a certain future date, typically 10 to 30 years out. These aspirational goals may increase the risk of a new power plant becoming a stranded asset long before the end of its otherwise useful economic life, which is a risk that potential equity capital providers may be unwilling to take. The difficulty in obtaining project equity financing and the other factors identified above, may be adversely impacting the planning and initial phases for the construction of new natural gas-fired power plants.
21
Perhaps the most significant uncertainty relates to the policies of the current U.S. Presidential administration. President Biden proposes to make the electricity production in the U.S. carbon free by 2035 and to put the country on the path to achieve net zero carbon emissions by 2050. These policy stances have continued during the war in the Ukraine and the recent surge in oil prices as the administration makes appeals to other countries to increase oil production while domestic production is challenged by supply chain and labor issues and the maintenance of restrictive regulations. Meanwhile, delays continue for the construction of pipelines needed to transport natural gas to liquid natural gas export facilities for shipment to Western Europe. Additionally, lenders, who have become more wary of funding oil-related ventures as environmental, social and governance ideas catch on in financial circles, are generally unwilling to provide capital for energy projects to increase the domestic production and transmission of oil and natural gas.
Accordingly, the net amount of electricity generation in the U.S. provided by utility-scale wind and solar photovoltaic facilities continues to rise. Over the last two years, the net generation has increased by almost 35%. Together, such power facilities provided approximately 9%, 11% and 12% of the net amount of electricity generated by utility-scale power facilities in 2019, 2020 and 2021, respectively. In EIA’s 2022 reference case, net electricity generation from all renewable power sources is expected to increase by more than 161% and represent over 42% of such generation by 2050. Impetus for this growth is provided by both public concerns about climate change and U.S. government subsidies. Environmental activism has resulted in the passage of laws and the establishment of regulations that discourage new fossil-fuel burning power plants and provide income tax advantages that promote the growth of wind and solar power. Declines in the amount of renewable power plant component and power storage costs and an increase in the scale of energy storage capacity (i.e., battery farms) have also occurred.
Over the next few years, EIA projects that new wind and photovoltaic solar capacity will continue to be added to the utility-scale power fleet in the U.S. at a brisk pace substantially attributable to declining equipment costs and the availability of valuable tax credits. As these credits decline and then expire early in the next decade as currently scheduled, the wind capacity additions are expected to slow. Although the special tax incentives related to solar power also expire, the continuing decline in the cost of solar power equipment is predicted to sustain the growth of photovoltaic solar power generation facilities.
Major advances in the safe combination of horizontal drilling techniques and hydraulic fracturing led to the boom in natural gas supplies which have been available generally at consistently low prices. However, reductions in production levels during the pandemic, an increase in the amount of liquid natural gas exports and current heat-wave temperatures in the South, among other factors, are straining domestic natural gas supplies. As a result, the price of natural gas in the U.S. has increased meaningfully since the beginning of the calendar year and is predicted to go higher during the summer.
Nevertheless, we believe that relatively low natural gas prices will persist over the long-term. Together with the lower operating costs of natural gas-fired power plants, the higher energy generating efficiencies of modern gas turbines, and the requirements for grid resiliency should sustain the demand for modern combined cycle and simple cycle gas-fired power plants in the future. Natural gas is relatively clean burning, cost-effective and reliable. New gas-fired power plants incorporate major advances in gas-fired turbine technologies that have provided increased power plant efficiencies while providing the quick starting capabilities and the reliability that are necessary to balance the inherent intermittencies of wind and solar power plants. We believe that its benefits as a source of power are compelling, especially as a complement to the deployment of wind and solar powered energy sources and that the future long-term prospects for natural gas-fired power plant construction remain generally favorable as natural gas continues to be the primary source for power generation in our country. The abundant availability of inexpensive, less carbon-intense and higher efficiency natural gas in the U.S. should continue to be a significant factor in the economic assessment of future power generation capacity additions although the pace of new opportunities emerging may be restrained and the starts of awarded EPC projects may be delayed.
Throughout the U.S., the risk of electricity shortages is rising as traditional power plants are being retired more quickly than they can be replaced by renewable energy and battery storage. Power grids are feeling the strain as the U.S. makes the historic transition from conventional power plants fueled by coal and natural gas to cleaner forms of energy such as wind and solar power, and aging nuclear plants are slated for retirement. Electric-grid operators are warning that power-generating capacity is struggling to keep up with demand, a gap that could lead to additional rolling blackouts during heat waves or other peak periods as soon as this year.
22
California’s grid operator recently stated that it anticipates a shortfall in supplies this summer, especially if extreme heat, wildfires or delays in bringing new power sources online exacerbate the constraints. The Midcontinent Independent System Operator, or “MISO”, which oversees a large regional grid spanning much of the Midwest, expects that capacity shortages may force it to take emergency measures to meet summer demand and flagged the risk of outages. Texas has experienced tight electricity supply conditions during the current Southern heat wave. The challenge is that wind and solar farms do not produce electricity at all times and need large batteries to store their output for later use. While a large amount of battery storage is under development, regional grid operators have lately warned that the pace may not be fast enough to offset the closures of traditional power plants that can work around the clock.
Accelerating the build-out of renewable energy sources and batteries has become an especially difficult proposition amid supply-chain challenges and inflation. For example, the highly publicized probe by the U.S. Commerce Department into whether Chinese solar manufacturers are circumventing trade tariffs on solar panels had the effect of halting imports of key components needed to build new solar farms and effectively brought the U.S. solar industry to a temporary, but virtual, standstill, although work at our solar energy project in Pennsylvania continues.
In its 2022 Summer Reliability Assessment, the North American Electric Reliability Corporation, which presents forward-looking evaluations of power sufficiency, warned that an unprecedented array of risks that threaten electricity generation output demand or demand spikes could imperil the reliability of every North American bulk power system west of MISO this summer. The power generation shortfalls have forced certain grid operators to react by taking measures to keep aging fossil-fueled power plants online to assure adequate supplies of electricity.
Additionally, solar and wind energy plant developers continue to confront the problems caused by grid congestion, often unsuccessfully. Many of these projects have been canceled because renewable plants need to be sited where the resources are optimal, often in remote locations where the transmission systems are not robust. The costs associated with the necessary grid upgrades may be prohibitive.
In February 2022, there were record-breaking sales of six offshore wind leases off the coasts of New York and New Jersey. This was followed by the federal government’s defining up to eight additional areas for possible future offshore wind development off the coast of Oregon and the Mid-Atlantic coast in April 2022. However, U.S. offshore wind projects progress inconsistently, facing challenges in the areas of environmental and fishery impacts, grid connection complexities, transmission planning and federal permitting processes. Further, U.S. projects are confronted by shipping regulations that may limit the ability of developers to replicate successful European erection models. Proponents of clean energy also face political challenges from constituencies who oppose the impacts to wildlife and the environment that may be caused by clean energy infrastructure projects.
Renewed interest in nuclear power could result in the construction of new nuclear powered, carbon-free, electricity generation stations in the U.S. that would use smaller and more economical nuclear reactors. The deployment of small modular reactors could mean lower construction and electricity costs through the use of simpler power plant designs, standardized components and passive safety measures. Such plants could be built in less time than larger plants, utilize less space and represent a viable choice for reliable power to offset the intermittencies of renewable power sources. The increase by the U.S. in its use of nuclear power for electricity generation could have unfavorable effects on the demand for new natural gas-fired and additional renewable energy facilities in the future.
We believe that it is also important to note that the plans for certain natural gas-fired power plant projects include the integration of hydrogen-burning capabilities. While the plants will initially burn natural gas alone, it is planned by the respective project owners that the plants will eventually burn a mixture of natural gas and green hydrogen, thereby establishing power-generation flexibility for these plants. We believe this is a winning combination that provides inexpensive and efficient power, enhances grid reliability and addresses clean-air concerns. The building of state-of-the-art power plants with flex-fuel capability replaces coal-fired power plants in the short term with relatively clean gas-fired electricity generation. Further, such additions to the power generation fleet provide the potential for the plants to burn 100% green hydrogen gas, which would provide both base load power and long duration backup power, when the sun is not shining and the wind is not blowing, for extended periods of time and without certain harmful air emissions.
23
The foregoing discussion in our “Market Outlook” does focus on the state of the domestic power market as the EPC services business of GPS provides the predominant amount of our revenues. However, overseas power markets provide important new power construction opportunities for us especially across Ireland and the U.K.
While both of these countries are committed to the increase in energy consumption sourced from wind and the sun on the pathway to net zero emissions, there is a recognition that these sources of electrical power are inherently variable. Other technologies will be required to support these power sources and to provide electricity when power demands exceed the amount of electricity supplied by these renewables. The existence of the necessary power reserve will require conventional generation sources, typically natural gas-fired power plants. APC was awarded the significant Kilroot project late in Fiscal 2022 to build a clean burning natural gas-fired power plant in Northern Ireland so that existing coal-fired power sources there can be shut down.
The U.K. usually holds auctions for power capacity about four years in advance of the delivery date and another auction for a smaller amount of capacity around a year before delivery. Evidence of the shifting power generation priorities in the U.K. are reflected in the results for Britain's auction to ensure enough electricity capacity for 2022/23 that were released in February 2022. Capacity cleared at a record high price. A total of nearly 5 gigawatts of capacity was procured in this auction, with nearly 70% of the power associated with gas-fired plants.
Last year, the Irish government issued a policy statement on the security of the electricity supply in Ireland which confirms the requirement for the development of new support technologies to deliver on its commitment to have 80% of the country’s electricity generated from renewables by 2030. The report emphasizes that this will require a combination of conventional generation (typically powered by natural gas), interconnection to other jurisdictions, demand flexibility and other technologies such as battery storage and generation from renewable gases. The Irish government has approved that the development of new conventional generation (including gas-fired and gasoil distillate-fired generation) is a national priority and should be permitted and supported in order to ensure the security of electricity supply while supporting the growth of renewable electricity generation.
As noted above, APC recently entered into engineering and construction services contracts with the ESB to construct three 65 MW aero-derivative gas turbine flexible generation power plants in and around Dublin, Ireland. All three projects are expected to operate intermittently during peak periods of electricity demand and as back-up supply options when renewable electricity generation is limited. A full notice to proceed has been received and project activities have commenced.
Further, the Irish government has recognized that the successful development of data centers in the country is a key aspect in promoting Ireland as a digital economy hot-spot in Europe. The stewards of the electricity supply in Ireland recognize that the large increase in electricity demand presented by the growth of the data center industry represents an evolving, significant risk to the security of the supply. Accordingly, guidelines have been published recently with the intent to protect both electricity consumers and the security of supply while continuing to allow data centers to connect to the electricity system. Assessment criteria for applications of data centers to obtain grid connections include, among other items, the ability of data center applicants to bring onsite dispatchable power generation (and/or storage) equivalent to or greater than their demand in order to support the security of supply. It is expected that any dispatchable on-site generation that uses fossil fuel sources developed by data center operators will use natural gas as the fuel source. Currently, APC is completing a project to install natural gas-fired power generation for a major data center in the Dublin area.
In our 2022 Annual Report, we identified that there are risks to our businesses, particularly APC, related to the war in Ukraine. However, our APC business may benefit from an increased focus by European Union countries on the import of liquid natural gas as an alternative to piped supplies from Russia. The construction of new conversion facilities, pipelines and power plants could provide new construction opportunities for the Company.
APC is actively pursuing other new business opportunities in both the renewable and support sectors with its existing and new clients. The governments of Ireland and the U.K. have already made funds available to develop and support specific projects. The engineering and construction teams of APC are engaged in continuous discussions with particular stakeholders in certain of these other projects and APC is confident that it will be part of their eventual execution.
Over the past few years, GPS has provided top management guidance and project management expertise to APC as it completed its subcontract efforts for a biomass-burning power plant and won the awards of the projects to build new gas-fired power plant units near Belfast and Dublin. APC has provided project management manpower to GPS on several of
24
its EPC services contracts. These recent experiences have demonstrated that the two companies can combine resources effectively. Considerations of the manner in which GPS and APC will work together in the future are becoming more substantive in view of emerging new business opportunities in the U.K. and Ireland, the strength of the reputation of GPS for successfully completing large gas-fired power plant projects in the U.S. and the growing recognition in the power community in Ireland and the U.K. that APC is positioned and has the capability to build larger and more complex power projects.
We are committed to the rational pursuit of new construction projects, including those with overseas locations and unique deployments of power-generation turbines, and the future growth of our revenues. This may result in additional decisions to make investments in the development and/or ownership of new projects. Because we believe in the strength of our balance sheet, we are willing to consider certain opportunities that include reasonable and manageable risks in order to assure the award of the related engineering, procurement, construction or equipment installation services contracts to us.
The competitive landscape for our core EPC services business related to natural gas-fired power plants in the U.S. has changed significantly over the last five years. While the domestic market remains dynamic, we are moving into an era where there may be fewer competitors for new gas-fired power plant EPC services project opportunities. Several major competitors have exited the market for a variety of reasons or have been acquired. Others have announced intentions to avoid entering into fixed-price contracts. Nonetheless, the competition for new utility-scale gas-fired power plant construction opportunities is fierce and still includes multiple global firms. We believe that the Company has a reputation as an accomplished, dependable and cost-effective provider of EPC and other large project construction contracting services. With the proven ability to deliver completed power facilities, particularly combined cycle, natural gas-fired power plants, we are focused on expanding our position in the power markets of the U.S., Ireland and the U.K. where we expect investments to be made based on forecasts of electricity demand covering decades into the future. We believe that our expectations are valid and that our plans for the future continue to be based on reasonable assumptions.
Comparison of the Results of Operations for the Three Months Ended April 30, 2022 and 2021
We reported net income attributable to our stockholders of $7.5 million, or $0.50 per diluted share, for the three months ended April 30, 2022. For the comparable period of the prior year we reported net income attributable to our stockholders of approximately $10.8 million, or $0.67 per diluted share.
The following schedule compares our operating results for the three months ended April 30, 2022 and 2021 (dollars in thousands):
| | Three Months Ended April 30, | | | |||||||||
|
| 2022 |
| 2021 |
| $ Change |
| % Change | | | |||
REVENUES |
| |
|
| |
|
| |
|
|
| | |
Power industry services | | $ | 73,949 | | $ | 97,172 | | $ | (23,223) |
| (23.9) | % | |
Industrial fabrication and field services | |
| 22,501 | |
| 26,658 | |
| (4,157) |
| (15.6) | | |
Telecommunications infrastructure services | |
| 3,827 | |
| 2,511 | |
| 1,316 |
| 52.4 | | |
Revenues | |
| 100,277 | |
| 126,341 | |
| (26,064) |
| (20.6) | | |
COST OF REVENUES | |
|
| |
|
| |
|
|
|
| | |
Power industry services | |
| 59,035 | |
| 78,669 | |
| (19,634) |
| (25.0) | | |
Industrial fabrication and field services | |
| 18,680 | |
| 21,969 | |
| (3,289) |
| (15.0) | | |
Telecommunications infrastructure services | |
| 2,824 | |
| 1,989 | |
| 835 |
| 42.0 | | |
Cost of revenues | |
| 80,539 | |
| 102,627 | |
| (22,088) |
| (21.5) | | |
GROSS PROFIT | |
| 19,738 | |
| 23,714 | |
| (3,976) |
| (16.8) | | |
Selling, general and administrative expenses | |
| 10,575 | |
| 9,892 | |
| 683 |
| 6.9 | | |
INCOME FROM OPERATIONS | |
| 9,163 | |
| 13,822 | |
| (4,659) |
| (33.7) | | |
Other income, net | |
| 595 | |
| 712 | |
| (117) |
| (16.4) | | |
INCOME BEFORE INCOME TAXES | |
| 9,758 | |
| 14,534 | |
| (4,776) |
| (32.9) | | |
Income tax expense | |
| (2,273) | |
| (3,768) | |
| 1,495 |
| 39.7 | | |
NET INCOME ATTRIBUTABLE TO | | | | | | | | | | | | | |
THE STOCKHOLDERS OF ARGAN, INC. | | $ | 7,485 | | $ | 10,766 | | $ | (3,281) | | (30.5) | % | |
25
Revenues
Power Industry Services
The revenues of the power industry services segment, representing the businesses of GPS and APC, decreased by 23.9%, or $23.2 million, to $73.9 million for the three months ended April 30, 2022 compared with revenues of $97.2 million for the three months ended April 30, 2021 as the quarterly construction activities associated with the Guernsey Power Station project have passed peak levels and APC completed its construction activities associated with the Teesside Renewable Energy Project (“TeesREP”) last year. The reduction in revenues between the quarters also was impacted by a slowdown in construction activities associated with the Maple Hill solar energy project as it was adversely effected by the disruption in the supply of photovoltaic panels that is expected to be temporary. The revenues of this business segment represented approximately 73.7% of consolidated revenues for the quarter ended April 30, 2022 and 76.9% of consolidated revenues for the corresponding prior year quarter.
The primary driver for the revenues of this segment for the three months ended April 30, 2021 were the revenues associated with the construction of the Guernsey Power Station as the construction activities on this project were at peak levels.
Industrial Fabrication and Field Services
The revenues of our industrial fabrication and field services segment (representing the business of TRC) decreased by $4.2 million, or 15.6%, to $22.5 million for the three months ended April 30, 2022 compared to revenues of $26.7 million for the three months ended April 30, 2021 as the amount of pipe and fabrication declined. For the three months ended April 30, 2022 and 2021, the revenues of this segment represented 22.4% and 21.1% of consolidated revenues for the corresponding periods.
TRC’s performance for the three-month period ended April 30, 2021 was particularly strong as it reflected significant increases in revenues earned on field services activities during the period, as well as increases in revenues associated with pipe and vessel fabrication works. The major customers of TRC include some of North America’s largest fertilizer producers, as well as other chemical, mining, forest products, construction and energy companies with plants, facilities and other sites located primarily in the southeastern region of the U.S.
Telecommunications Infrastructure Services
The revenue results of this business segment (representing the business of SMC) were $3.8 million for the three-month period ended April 30, 2022, an increase of $1.3 million, or 52.4%, from the amount of revenues earned during the three months ended April 30, 2021. The improvement in revenues between the quarters related to increased project activities for both outside-premises and inside-premises customers, including the customers of Lee Telecom, Inc., a company acquired by SMC in December 2021.
Cost of Revenues
With the decrease in consolidated revenues for the three months ended April 30, 2022 compared with last year’s first quarter ended April 30, 2021, the consolidated cost of revenues also decreased between the quarters. These costs were $80.5 million and $102.6 million for the three month periods ended April 30, 2022 and 2021, respectively, representing a decrease of approximately 21.5%.
For the three-month period ended April 30, 2022, we reported a consolidated gross profit of approximately $19.7 million which represented a gross profit percentage of approximately 19.7% of corresponding consolidated revenues. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 20.2%, 17.0% and 26.2%, respectively, for the quarter ended April 30, 2022.
Our consolidated gross profit reported for the three-month period ended April 30, 2021 was $23.7 million, which represented a gross profit percentage of approximately 18.8% of corresponding consolidated revenues. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 19.0%, 17.6% and 20.8%, respectively, for the quarter ended April 30, 2021.
26
Selling, General and Administrative Expenses
These costs were $10.6 million and $9.9 million for the three months ended April 30, 2022 and 2021, respectively, representing an increase of $0.7 million between the quarters, or 6.9%, which occurred within each of our reporting segments primary due to increased professional fees and stock compensation expense.
Other Income
We reported other income, net, in the amount of $0.6 million for the three months ended April 30, 2022 which included primarily earnings associated with our solar fund investments. In April 2021, APC received a research and development credit payment from the government of the U.K. related to certain qualifying works performed on TeesREP during Fiscal 2019. Net of related costs, the payment amount of $0.7 million, much like a grant, was included in other income for the three months ended April 30, 2021.
Income Taxes
We incurred income tax expense for the three months ended April 30, 2022 in the amount of approximately $2.3 million, which reflects an estimated annual effective income tax rate of 23.7% for the current year, before discrete items. This estimated tax rate differs from the statutory federal tax rate of 21% due primarily to the unfavorable effects of state income taxes and estimated permanent differences for the year including certain nondeductible executive compensation and global intangible low taxed income (“GILTI”).
For the three months ended April 30, 2021, we reported income tax expense in the amount of approximately $3.8 million, which reflected an estimated annual effective income tax rate of approximately 25.1% for the year, before discrete items, that was estimated at the time. This tax rate differed from the statutory federal tax rate of 21% due primarily to the unfavorable effects of state income taxes and permanent differences, including certain nondeductible executive compensation and the non-deductible portions of the out-of-pocket travel and living expenses incurred by the large numbers of our project and craft employees who were working at offsite project locations.
Liquidity and Capital Resources as of April 30, 2022
At April 30 and January 31, 2022, our balances of cash and cash equivalents were $192.3 million and $350.5 million, respectively, which represented a decrease of $158.2 million. During the three months between these dates, our working capital decreased by $22.9 million to $261.3 million as of April 30, 2022 from $284.3 million as of January 31, 2022.
The net amount of cash used in operating activities for the three months ended April 30, 2022 was $39.7 million. Our net income for the three months ended April 30, 2022, adjusted favorably by the net amount of non-cash income and expense items, represented a source of cash in the total amount of $9.8 million. However, reductions in the balance of contract liabilities and the combined level of accounts payable and accrued expenses in the amounts of $20.9 million and $15.2 million, respectively, represented uses of cash. Both of these reductions related primarily to the decline in the construction activity of the Guernsey Power Station project. Likewise, the increase in the amounts of accounts receivable, contract assets, prepaid expenses and other assets, in the total amount of $13.3 million, represented a use of cash during the period.
During the three months ended April 30, 2022, we also used cash to increase the level of our short-term investments, which consist entirely of CDs issued by the Bank, by $85.0 million. We also used $30.7 million cash in financing activities during the three months ended April 30, 2022, including $27.1 million used to repurchase shares of our common stock pursuant to our Share Repurchase Plan, and $3.7 million used for the payment of regular cash dividends. As of April 30, 2022, there were no restrictions with respect to inter-company payments between GPS, TRC, APC, SMC and the holding company. However, certain loans made by Argan to APC have been determined to be uncollectible.
During the three months ended April 30, 2021, our balance of cash and cash equivalents increased by a net amount of $30.0 million. The net amount of cash provided by operating activities for the three months ended April 30, 2021 was $17.3 million. Our net income for the period, adjusted favorably by the net amount of non-cash income and expense items, represented a source of cash in the total amount of $13.8 million. The sources of cash from operations also included the temporary increase in the balance of contract liabilities associated with projects at GPS and TRC in the amount of $27.5 million.
27
A reduction in the combined level of accounts payable and accrued expenses and an increase in the amount of accounts receivable, in the respective amounts of $21.6 million and $3.7 million, represented uses of cash for the three months ended April 30, 2021.
Other primary sources of cash for the three months ended April 30, 2021 were the net maturities of short-term investments and the proceeds associated with the exercise of stock options in the amounts of $20.0 million and $1.0 million, respectively. Non-operating activities also used cash during the three months ended April 30, 2021, including the payment of a regular cash dividend in the amount of $3.9 million, payments made to a solar energy investment company in the amount of $3.5 million and capital expenditures in the amount of $0.8 million.
At April 30, 2022, most of our balance of cash and cash equivalents was invested in a money market fund with most of its total assets invested in cash, U.S. Treasury obligations and repurchase agreements secured by U.S. Treasury obligations. The major portion of our domestic operating bank account balances are maintained with the Bank. We do maintain certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the U.K. in support of the operations of APC.
The original term of our Credit Agreement with the Bank was scheduled to expire on May 31, 2021. During April 2021, the Company and the Bank agreed to an amendment to the Credit Agreement which extended the expiration date of the Credit Agreement to May 31, 2024 and reduced the borrowing rate. The Credit Agreement includes the following features, among others: a lending commitment of $50.0 million including a revolving loan with interest at the 30 day LIBOR plus 1.6% (reduced from 2.0%), and an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions. We may also use the borrowing ability to cover other credit instruments issued by the Bank for our use in the ordinary course of business as defined by the Bank. At April 30, 2022, we had no outstanding borrowings, however, the Bank has issued letters of credit in the total outstanding amount of $21.1 million in support of the activities of APC under new customer contracts. In connection with the project development activities of the VIE, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the approximate amount of $3.4 million for which we have provided cash collateral. The Company expects to amend the Credit Agreement again during Fiscal 2023 in order to replace LIBOR with an equivalent benchmark rate. The Company does not expect that the change will materially impact its consolidated financial statements.
We have pledged the majority of our assets to secure the financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Credit Agreement requires that we comply with certain financial covenants at our fiscal year-end and at each fiscal quarter-end, and includes other terms, covenants and events of default that are customary for a credit facility of its size and nature, including a requirement to achieve positive adjusted earnings before interest, taxes, depreciation and amortization, as defined, over each rolling twelve-month measurement period. At April 30, 2022 and January 31, 2022, we were compliant with the covenants of the Credit Agreement.
In the normal course of business and for certain major projects, we may be required to obtain surety or performance bonding, to provide parent company guarantees, or to cause the issuance of letters of credit (or some combination thereof) in order to provide performance assurances to clients on behalf of one of our subsidiaries.
If our services under a guaranteed project would not be completed or would be determined to have resulted in a material defect or other material deficiency, then we could be responsible for monetary damages or other legal remedies. As is typically required by any surety bond, we would be obligated to reimburse the issuer of any surety bond provided on behalf of a subsidiary for any cash payments made thereunder. The commitments under performance bonds generally end concurrently with the expiration of the related contractual obligation. Not all of our projects require bonding.
As of April 30, 2022, the value of the Company’s unsatisfied bonded performance obligations, covering all of its subsidiaries, was approximately $187.0 million. In addition, as of April 30, 2022, there were bonds outstanding in the aggregate amount of approximately $1.1 million covering other risks including warranty obligations related to completed activities; the majority of these bonds expire at various dates over the next two years.
We have also provided a financial guarantee on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million to support project developmental efforts. A liability was established for the estimated loss related to this guarantee during Fiscal 2022.
28
When sufficient information about claims related to our performance on projects would be available and monetary damages or other costs or losses would be determined to be probable, we would record such losses. As our subsidiaries are wholly-owned, any actual liability related to contract performance is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. Any amounts that we may be required to pay in excess of the estimated costs to complete contracts in progress as of April 30, 2022 are not estimable.
Returns on money market instruments and certificates of deposit are currently limited due to market conditions. With the desire to increase the amount of return on its available cash, the Company has invested approximately $6.3 million in limited liability companies that makes equity investments in solar energy projects that are eligible to receive energy tax credits. It is likely that we will evaluate opportunities to make other solar energy investments of this type in the future.
We believe that cash on hand, our cash equivalents, cash that will be provided from the maturities of short-term investments and cash generated from our future operations, with or without funds available under our Credit Agreement, will be adequate to meet our general business needs in the foreseeable future. In general, we maintain significant liquid capital in our consolidated balance sheet to ensure the maintenance of our bonding capacity and to provide parent company performance guarantees for EPC and other construction projects.
However, any significant future acquisition, investment or other unplanned cost or cash requirement, may require us to raise additional funds through the issuance of debt and/or equity securities. There can be no assurance that such financing will be available on terms acceptable to us, or at all.
Earnings before Interest, Taxes, Depreciation and Amortization (“EBITDA”)
The table following immediately below presents the determinations of EBITDA for the three months ended April 30, 2022 and 2021, respectively (amounts in thousands).
| | Three Months Ended | | ||||
| | April 30, | | ||||
|
| 2022 |
| 2021 | | ||
Net income, as reported | | $ | 7,485 | | $ | 10,766 | |
Income tax expense | |
| 2,273 | |
| 3,768 | |
Depreciation | |
| 809 | |
| 882 | |
Amortization of purchased intangible assets | |
| 166 | |
| 228 | |
EBITDA | |
| 10,733 | |
| 15,644 | |
EBITDA of the non-controlling interest | |
| — | |
| — | |
EBITDA attributable to the stockholders of Argan, Inc. | | $ | 10,733 | | $ | 15,644 | |
We believe that EBITDA is a meaningful presentation that enables us to assess and compare our operating performance on a consistent basis by removing from our operating results the impacts of our capital structure, the effects of the accounting methods used to compute depreciation and amortization and the effects of operating in different income tax jurisdictions. Further, we believe that EBITDA is widely used by investors and analysts as a measure of performance.
However, as EBITDA is not a measure of performance calculated in accordance with U.S. GAAP, we do not believe that this measure should be considered in isolation from, or as a substitute for, the results of our operations presented in accordance with U.S. GAAP that are included in our condensed consolidated financial statements. In addition, our EBITDA does not necessarily represent funds available for discretionary use and is not necessarily a measure of our ability to fund our cash needs.
Critical Accounting Policies
Critical accounting policies are those related to the areas where we have made what we consider to be particularly subjective or complex judgments in arriving at estimates and where these estimates can significantly impact our financial results under different assumptions and conditions. These estimates, judgments, and assumptions affect the reported amounts of assets, liabilities and equity, the disclosure of contingent assets and liabilities at the date of financial statements and the reported amounts of revenues and expenses during the reporting periods. We base our estimates on historical experience and various other assumptions that we believe are reasonable under the circumstances, the results of which
29
form the basis for making judgments about the carrying value of assets, liabilities and equity that are not readily apparent from other sources. Actual results and outcomes could differ from these estimates and assumptions. We do periodically review these critical accounting policies and estimates with the audit committee of our board of directors.
We consider the accounting policies related to revenue recognition on long-term construction contracts; income tax reporting; the accounting for business combinations; the subsequent valuation of goodwill, other indefinite-lived assets and long-lived assets; and the financial reporting associated with any significant claims or legal matters to be most critical to the understanding of our financial position and results of operations, as well as the accounting and reporting for special purpose entities including joint ventures and variable interest entities. An expanded discussion of our critical accounting policies is included in Item 7 of Part II of our Annual Report. During the three months ended April 30, 2022, there have been no material changes in the way we apply the critical accounting policies described therein.
Recently Issued Accounting Pronouncements
There are no recently issued accounting pronouncements that have not yet been adopted that we consider material to our consolidated financial statements.
ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK
In the normal course of business, our results of operations may be subject to risks related to fluctuations in interest rates. As of April 30, 2022, we had no outstanding borrowings under our financing arrangements with the Bank (see Note 6 to the accompanying condensed consolidated financial statements), which provide a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2024 with interest at 30-day LIBOR plus 1.6% going forward. During the three months ended April 30, 2022 and 2021, we did not enter into derivative financial instruments for trading, speculation or other purposes that would expose us to market risk.
Financial markets around the globe are preparing for the pending discontinuation of LIBOR, which is the widely used indicator of basis for short-term lending rates. The transition from LIBOR is market-driven, not a change required by regulation. The U.S. and other countries are currently working to replace LIBOR with alternative reference rates. We do not expect that the replacement of LIBOR as the basis for the determination of our short-term borrowing rate will have any significant effects on our financial arrangements with the Bank or our financial reporting.
We maintain a substantial amount of our temporarily investable cash in certificates of deposit and in a money market fund (see Note 3 of the accompanying condensed consolidated financial statements). As of April 30, 2022, the weighted average number of days until maturity for the short-term investments and money market fund is 330 days. The weighted average annual interest rate of our certificates of deposit of $175.0 million, which are classified as short-term investments, and the money market fund of $227.5 million was 0.58%. To illustrate the potential impact of changes in the overall interest rate associated with our investable cash balance at April 30, 2022 on our annual results of operations, we present the following hypothetical analysis. It assumes that our condensed consolidated balance sheet as of April 30, 2022 remains constant, and no further actions are taken to alter our existing interest rate sensitivity, including reinvestments. As the blended weighted average interest rate was 0.58% at April 30, 2022, the largest decrease in the interest rates presented below is 58 basis points (dollars in thousands).
| | Increase (Decrease) in | | Increase (Decrease) in | | Net Increase (Decrease) in | |||
Basis Point Change |
| Interest Income |
| Interest Expense |
| Income (Pre-Tax) | |||
Up 300 basis points | | $ | 10,191 | | $ | — | | $ | 10,191 |
Up 200 basis points | | | 6,794 | | | — | | | 6,794 |
Up 100 basis points | |
| 3,397 | |
| — | |
| 3,397 |
Down 58 basis points | |
| (1,367) | |
| — | |
| (1,367) |
With the consolidation of APC, we are subject to the effects of translating the financial statements of APC from its functional currency (Euros) into our reporting currency (U.S. dollars). Such effects are recognized in accumulated other comprehensive loss, which is net of tax when applicable. APC remeasures transactions and subsidiary financial statements denominated in local currencies to Euros. Gains and losses on the remeasurements are recorded in the other income line of our condensed consolidated statement of earnings.
30
In the “Risk Factors” section of our Annual Report, we included discussion of the risks to our fixed price contracts if actual contract costs rise above the estimated amounts of such costs that support corresponding contract prices. Identified as factors that could cause contract cost overruns, project delays or other unfavorable effects on our contracts, among other circumstances and events, are delays in the scheduled deliveries of machinery and equipment ordered by us or project owners, unforeseen increases in the costs of labor, warranties, raw materials, components or equipment or the failure or inability to obtain resources when needed.
We are subject to fluctuations in prices for commodities including steel products, copper, concrete and fuel. Although we attempt to secure firm quotes from our suppliers, we generally do not hedge against increases in prices for these commodities. Commodity price risks may have an impact on our results of operations due to the fixed-price nature of many of our contracts. We attempt to include the anticipated amounts of price increases or decreases in the costs of our bids. In times of increased supply cost volatility, we may take other steps to reduce our risks. For example, we may hold quotes related to materials in our industrial fabrication and field services segment for very short periods. For major fixed price contracts in our power industry services segment, we may mitigate material cost risks by procuring the majority of the equipment and construction supplies during the early phases of a project. The profitability of our active jobs has not suffered meaningfully from the periodic global surges in non-residential construction material costs.
Our operations have been challenged by the well-publicized global supply chain disruptions. While management of the risks associated with the inability to obtain machinery, equipment and other materials when needed continues to include our best efforts, we are concerned that the supply chain uncertainties may be impacting project owners’ confidence in commencing new work which may adversely affect our expected levels of revenues until the supply chain disruptions dissipate.
ITEM 4. CONTROLS AND PROCEDURES
Evaluation of disclosure controls and procedures. Our management, with the participation of our chief executive officer and chief financial officer, evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934 (the “Exchange Act”)) as of April 30, 2022. Management recognizes that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving their objectives, and management necessarily applies its judgment in evaluating the cost-benefit relationship of possible controls and procedures. Based on the evaluation of our disclosure controls and procedures as of April 30, 2022, our chief executive officer and chief financial officer concluded that, as of such date, our disclosure controls and procedures were effective to provide reasonable assurance that information required to be disclosed in our Exchange Act reports is recorded, processed, summarized, and reported within the time periods specified by the SEC, and the material information related to the Company and its consolidated subsidiaries is made known to management, including the chief executive officer and chief financial officer, to allow timely decisions regarding required disclosure in the reports.
Changes in internal controls over financial reporting. There have been no significant changes in our internal control over financial reporting (as defined in Rules 13a-15 and 15d-15 under the Exchange Act) during the fiscal quarter ended April 30, 2022 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.
PART II
ITEM 1. LEGAL PROCEEDINGS
In the normal course of business, we may have pending claims and legal proceedings. It is our opinion, based on information available at this time, that any other current claim or proceeding will not have a material effect on our condensed consolidated financial statements.
ITEM 1A. RISK FACTORS
There have been no material changes to the risk factors disclosed in our Annual Report.
31
ITEM 2. UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS
On April 13, 2022, we made a filing on Current Report Form 8-K announcing an additional authorized increase in our Share Repurchase Plan, from $50 million to $75 million. The repurchases may occur in the open market or through investment banking institutions, privately-negotiated transactions, or direct purchases, and the timing and amount of stock repurchase transactions will depend on market and business conditions, applicable legal and credit requirements and other corporate considerations. In accordance with the SEC’s Rule 10b5-1, and pursuant to the Share Repurchase Plan, we have allowed, and may in the future allow, the repurchase of our common stock during trading blackout periods by an investment banking firm or other institution agent acting on our behalf pursuant to predetermined parameters.
Information related to our share repurchases for the three months ended April 30, 2022 follows.
| | | | | | Total Number of | | Value of Shares That May Yet | ||
| | | | | | Shares Purchased as Part of | | Be Purchased under the | ||
| | Total Number of | | Average Price per | | Publicly Announced | | Plans or Programs | ||
Period |
| Shares Repurchased |
| Share Paid |
| Plans or Programs |
| (Dollars in Thousands) | ||
February 1 - 28, 2022 |
| 310,100 | | $ | 38.28 |
| 310,100 | | $ | 17,758 |
March 1 - 31, 2022 | | 91,683 | | $ | 39.59 | | 91,683 | | $ | 14,128 |
April 1 - 30, 2022 |
| 309,096 | | $ | 37.45 |
| 309,096 | | $ | 27,552 |
Total |
| 710,879 | | $ | 38.09 |
| 710,879 | | | |
Subsequent to April 30, 2022, we repurchased shares of our common stock pursuant to the Share Repurchase Plan. As of June 8, 2022, the Company had repurchased 383,177 shares since the end of the quarter, all on the open market, for an aggregate price of approximately $14.2 million, or $37.14 per share.
ITEM 3. DEFAULTS UPON SENIOR SECURITIES
None
ITEM 4. MINE SAFETY DISCLOSURES (not applicable)
ITEM 5. OTHER INFORMATION
None
ITEM 6. EXHIBITS
Exhibit No. |
| Title |
Exhibit 31.1 |
| |
Exhibit 31.2 |
| |
Exhibit 32.1 |
| Certification of Chief Executive Officer, pursuant to 18 U.S.C. Section 1350. * |
Exhibit 32.2 |
| Certification of Chief Financial Officer, pursuant to 18 U.S.C. Section 1350. * |
|
|
|
Exhibit 101: Exhibit 101.INS |
| XBRL Instance Document – the instance document does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document. |
Exhibit 101.SCH |
| Inline XBRL Taxonomy Extension Schema. |
Exhibit 101.CAL |
| Inline XBRL Taxonomy Extension Calculation Linkbase. |
Exhibit 101.LAB |
| Inline XBRL Taxonomy Label Linkbase. |
Exhibit 101.PRE |
| Inline XBRL Taxonomy Presentation Linkbase. |
Exhibit 101.DEF |
| Inline XBRLTaxonomy Extension Definition Document. |
Exhibit 104 | | Cover Page Interactive Data File – the cover page interactive data file does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document. |
* | The certification is being furnished and shall not be considered filed as part of this report. |
32
SIGNATURES
Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.
| ARGAN, INC. | |
|
| |
June 8, 2022 | By: | /s/ Rainer H. Bosselmann |
|
| Rainer H. Bosselmann |
|
| Chairman of the Board and Chief Executive Officer |
| ||
June 8, 2022 | By: | /s/ David H. Watson |
|
| David H. Watson |
|
| Senior Vice President, Chief Financial Officer, |
|
| Treasurer and Secretary |
33
Exhibit 31.1
SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION
I, Rainer H. Bosselmann, certify that:
1. I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended April 30, 2022;
2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;
4. The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and
5. The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):
a) All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.
Date: June 8, 2022 | By: | /s/ Rainer H. Bosselmann |
|
| Rainer H. Bosselmann |
| | Chairman of the Board and Chief Executive Officer |
|
| (Principal Executive Officer) |
Exhibit 31.2
SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION
I, David H. Watson, certify that:
1. I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended April 30, 2022;
2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;
4. The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and
5. The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):
a) All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.
Date: June 8, 2022 | By: | /s/ David H. Watson |
|
| David H. Watson |
| | Senior Vice President, Chief Financial Officer, Treasurer and Secretary |
|
| (Principal Financial Officer) |
Exhibit 32.1
CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350,
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002
In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended April 30, 2022, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, Rainer H. Bosselmann, Chairman and Chief Executive Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:
1. The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and
2. Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.
Date: June 8, 2022 | By: | /s/ Rainer H. Bosselmann |
|
| Rainer H. Bosselmann |
| | Chairman of the Board and Chief Executive Officer |
|
| (Principal Executive Officer) |
Exhibit 32.2
CERTIFICATION PURSUANT TO
18 U.S.C. SECTION 1350,
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002
In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended April 30, 2022, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, David H. Watson, Senior Vice President and Chief Financial Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:
1. The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and
2. Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.
Date: June 8, 2022 | By: | /s/ David H. Watson |
|
| David H. Watson |
| | Senior Vice President, Chief Financial Officer, Treasurer and Secretary |
|
| (Principal Financial Officer) |